ADMINISTRATION OF THE CONTRACT 2.2.1 The Architect will provide administration of the Contract as hereinafter described.
2.2.2 The Architect will be the State's representative during construction and until final payment is due. The Architect will advise and consult with the State. The State's instructions to the Contractor shall be forwarded through the Architect. The Architect will have authority to act on behalf of the State only to the extent provided in the Contract Documents, unless otherwise modified by written instrument in accordance with Subparagraph 2.2.10.
2.2.3 The Architect will visit the site at intervals appropriate to the stage of construction to familiarize himself or herself generally with the progress and quality of the Work and to determine in general if the Work is proceeding in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of his or her on-site observations as an architect, he or she will keep the State informed of the progress of the Work, and will endeavor to guard the State against defects and deficiencies in the Work of the Contractor.
2.2.4 The Architect will not be responsible for and will not have control or charge of construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, and he or she will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. The Architect will not be responsible for or have control or charge over the acts or omissions of the Contractor,
2.2.5 The Architect shall at all times have access to the Work wherever it is in preparation and progress. The Contractor shall provide facilities for such access so the Architect may perform his or her functions under the Contract Documents.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Administration of the Mortgage Loans (a) Each of the Master Servicer and the Special Servicer shall service and administer the Mortgage Loans that it is obligated to service and administer pursuant to this Agreement on behalf of the Trustee, and in the best interests and for the benefit of the Certificateholders, in accordance with any and all applicable laws and the terms of this Agreement, the Insurance Policies and the respective Mortgage Loans and, to the extent consistent with the foregoing, in accordance with the Servicing Standard. Without limiting the foregoing, and subject to Section 3.21, (i) the Master Servicer shall service and administer all Mortgage Loans as to which no Servicing Transfer Event has occurred and all Corrected Mortgage Loans, and (ii) the Special Servicer shall service and administer (x) each Mortgage Loan (other than a Corrected Mortgage Loan) as to which a Servicing Transfer Event has occurred, and (y) each REO Property; provided, however, that the Master Servicer shall continue to collect information and prepare all reports to the Trustee required hereunder with respect to any Specially Serviced Mortgage Loans and REO Properties (and the related REO Loans), and further to render such incidental services with respect to any Specially Serviced Mortgage Loans and REO Properties as are specifically provided for herein.
(b) Subject to Section 3.01(a), the Master Servicer and the Special Servicer each shall have full power and authority, acting alone, to do or cause to be done any and all things in connection with such servicing and administration which it may deem necessary or desirable. Without limiting the generality of the foregoing, each of the Master Servicer and the Special Servicer, in its own name, with respect to each of the Mortgage Loans it is obligated to service hereunder, is hereby authorized and empowered by the Trustee to execute and deliver, on behalf of the Certificateholders and the Trustee or any of them: (i) any and all financing statements, continuation statements and other documents or instruments necessary to maintain the lien created by any Mortgage or other security document in the related Mortgage File on the related Mortgaged Property and related collateral; (ii) in accordance with the Servicing Standard and subject to Sections 3.08 and 3.20, any and all modifications, waivers, amendments or consents to or with respect to any documents contained in the related Mortgage File; and (iii) any and all instruments of satisfaction or cancellation, or of partial or full release or discharge, and all other comparable instruments. Subject to Section 3.10, the Trustee shall, at the written request of a Servicing Officer of the Master Servicer or the Special Servicer, furnish, or cause to be so furnished, to the Master Servicer and the Special Servicer, as the case may be, any limited powers of attorney and other documents necessary or appropriate to enable them to carry out their servicing and administrative duties hereunder; provided, however, that the Trustee shall not be held liable for any misuse of any such power of attorney by the Master Servicer or the Special Servicer.
(c) The relationship of each of the Master Servicer and Special Servicer to the Trustee under this Agreement is intended by the parties to be that of an independent contractor and not that of a joint venturer, partner or agent.
(d) In the event that any two or more Mortgage Loans are cross-collateralized with each other, the Master Servicer or Special Servicer, as applicable, in accordance with the terms of this Agreement, shall service and administer such Mortgage Loans as a single Mortgage Loan as and when it deems necessary and appropriate, consistent with the Servicing Standard. If any Cross-Collateralized Mortgage Loan becomes a Specially Serviced Mortgage Loan, then each other Mortgage Loan that is cross-collateralized with it shall also become a Specially Serviced Mortgage Loan. Similarly, no Cross-Collateralized Mortgage Loan shall subsequently become a Corrected Mortgage Loan, unless and until all Servicing Transfer Events in respect of each other Mortgage Loan that is cross-collateralized with it, are remediated or otherwise addressed as contemplated in the definition of "Specially Serviced Mortgage Loan".
Medicaid Notification of Termination Requirements Party shall follow the Department of Vermont Health Access Managed-Care-Organization enrollee-notification requirements, to include the requirement that Party provide timely notice of any termination of its practice.
CONDITIONS FOR EMERGENCY/HURRICANE OR DISASTER - TERM CONTRACTS It is hereby made a part of this Invitation for Bids that before, during and after a public emergency, disaster, hurricane, flood, or other acts of God that Orange County shall require a “first priority” basis for goods and services. It is vital and imperative that the majority of citizens are protected from any emergency situation which threatens public health and safety, as determined by the County. Contractor agrees to rent/sell/lease all goods and services to the County or other governmental entities as opposed to a private citizen, on a first priority basis. The County expects to pay contractual prices for all goods or services required during an emergency situation. Contractor shall furnish a twenty-four (24) hour phone number in the event of such an emergency.
REASONS FOR AND BENEFITS OF THE TRANSACTIONS Jiaogong Maintenance and Zhejiang Shunchang fully understand business and operating needs of LongLiLiLong Co, and maintain effective communication to provide more quality services to LongLiLiLong Co. Both Jiaogong Maintenance and Zhejiang Shunchang has the relevant qualifications and experience to provide the Maintenance Services to LongLiLiLong Co. In addition, LongLiLiLong Co went through a tender process and obtained the relevant quotations from other independent service providers to select the service provider of the Maintenance Services. Zhejiang Shunchang and Jiaogong Maintenance finally won the respective tenders. The transactions contemplated under the Agreements are and will be conducted in the ordinary and usual course of business of the Group, and the consideration paid by LongLiLiLong Co to Jiaogong Maintenance and Zhejiang Shunchang, respectively, will not be higher than the average market price and will not be less favourable than those provided by other independent service providers to LongLiLiLong Co for similar services. Given the above, the Directors (including the independent non-executive Directors) are of the view that the terms of the Agreements are on normal commercial terms, in the ordinary and usual course of business of the Group and are fair and reasonable and in the interests of the Company and the Shareholders as a whole. As at the date of this announcement, LongLiLiLong Co is a wholly owned subsidiary of the Company. As at the date of this announcement, Communications Group holds approximately 67% of the issued share capital of the Company. By virtue of this shareholding interest, Communications Group is a controlling shareholder (as defined under the Listing Rules) of the Company. As at the date of this announcement, each of Jiaogong Maintenance and Zhejiang Shunchang is an indirect subsidiary of Communications Group. Therefore, Zhejiang Shunchang and Jiaogong Maintenance are connected persons of the Company and as a result, the respective transactions contemplated under the Dedicated Road Maintenance Agreements constitute continuing connected transactions for the Company under Chapter 14A of the Listing Rules. Pursuant to Rule 14A.81 to Rule 14A.83 of the Listing Rules, the respective transactions contemplated under the Dedicated Road Maintenance Agreements are required to be aggregated with the respective transactions contemplated under the Previous Road Maintenance Agreements which were continuing connected transactions entered into with the same connected persons. As the applicable percentage ratios in respect of the aggregated annual cap for transactions contemplated under the Dedicated Road Maintenance Agreements and the Previous Road Maintenance Agreements are more than 0.1% but less than 5%, the transactions contemplated under the Dedicated Road Maintenance Agreements and the Previous Road Maintenance Agreements will be subject to the reporting, announcement and annual review requirements but exempt from the independent Shareholders’ approval requirement under Chapter 14A of the Listing Rules. Xx. Xx Xxxxxxx, Xx. Xxx Xxxxxxx, Xx. Xxxx Xxxxxxx and Mr. Xxx Xx, being Directors, are deemed to have material interests in the Dedicated Road Maintenance Agreements as they are also employed by the Communications Group as at the date of Board meeting on April 30, 2021 and have abstained from voting on the relevant Board resolutions. Other than those Directors mentioned above, none of the Directors have a material interest in the transactions contemplated under the Dedicated Road Maintenance Agreements, and none are required to abstain from voting on the relevant resolutions of the Board.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
REASONS FOR AND BENEFITS OF THE TRANSACTION The New Transportation Contract has been entered into for the purpose of transportation. The Company considers that the transactions contemplated under the New Transportation Contract are for the benefit of the Company, as the services provided are required in the production process of the Group and the service provider offered a competitive price and are capable of meeting the Group’s transportation needs. The Directors (including the independent non-executive Directors) consider that the New Transportation Contract is on normal commercial terms which are fair and reasonable and the transactions contemplated under the New Transportation Contract are in the ordinary and usual course of business of the Group and in the interests of the Company and its shareholders as a whole. None of the Directors has a material interest in the transactions contemplated under the New Transportation Contract, save for Xx. Xxxxxxx Xxxxxxxxx, who is general director of JSC EuroSibEnergo, a company which is owned by En+, and deputy general director — financial director of En+; and Mr. Xxxxxxxx Xxxxxxxxxx, who is the first deputy chief executive officer for technical policy and executive officer of International limited liability company En+ Holding, and deputy CEO — executive officer of En+, being the holding company of KraMZ-Auto LLC. Mr. Xxxxxxxx Xxxxxxxxxx is also the head of technical supervision of JSC EuroSibEnergo, a company which is owned by En+. Accordingly, Xx. Xxxxxxx Xxxxxxxxx and Mr. Xxxxxxxx Xxxxxxxxxx did not vote on the Board resolution approving the New Transportation Contract.
Conditions to Obligation of the Depositor The obligation of the Depositor to purchase the Receivables is subject to the satisfaction of the following conditions:
Payment of Non-compliance Penalties Subject to Clause (i) above, the Service Provider shall pay the Non-compliance Penalty indicated in the Non-compliance Penalty Certificate within 10 (ten) Business Days of Transnet issuing a valid Tax Invoice to the Service Provider for the amount set out in that certificate. If Transnet does not issue a valid Tax Invoice to the Service Provider for Non-compliance Penalties accrued during any relevant period, those Non-compliance Penalties shall be carried forward to the next period.
