Violation; liability for unpaid wages; liquidated damages In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
Penalties Business Associate understands that: (a) there may be civil or criminal penalties for misuse or misappropriation of PHI and (b) violations of this Agreement may result in notification by Covered Entity to law enforcement officials and regulatory, accreditation, and licensure organizations.
Liquidated damages, attorney's fees, waiver of vendor's liability, and waiver of statutes of limitations clauses should also be deleted or qualified with "to the extent permitted by the Constitution and laws of State of Texas." Not a negotiable term. Failure to agree will render your proposal non-responsive and it will not be considered. Do you agree to these terms? 64 Remedies The parties shall be entitled to exercise any right or Yes, I Agree remedy available to it either at law or in equity, subject to the choice of law, venue and service of process clauses limitations agreed herein. Nothing in this agreement shall commit the TIPS to an arbitration resolution of any disagreement under any circumstances. Any Claim arising out of or related to the Contract, except for those specifically waived under the terms of the Contract, may, after denial of the Board of Directors, be subject to mediation at the request of either party. Any issues not resolved hereunder MAY be referred to non-binding mediation to be conducted by a mutually agreed upon mediator as a prerequisite to the filing of any lawsuit over such issue(s). The parties shall share the mediator’s fee and any associated filing fee equally. Mediation shall be held in Camp or Xxxxx County, Texas. Agreements reached in mediation shall be reduced to writing, and will be subject to the approval by the District's Board of Directors, signed by the Parties if approved by the Board of Directors, and, if signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Do you agree to these terms? 65 Remedies Explanation of No Answer 66 Choice of Law The agreement between the Vendor and TIPS/ESC Yes Region 8 and any addenda or other additions resulting from this procurement process, however described, shall be governed by, construed and enforced in accordance with the laws of the State of Texas, regardless of any conflict of laws principles. THIS DOES NOT APPLY to a vendor's agreement entered into with a TIPS Member, as the Member may be located outside Texas. Not a negotiable term. Failure to agree will render your proposal non-responsive and it will not be considered. Do you agree to these terms?
Judgments; Penalties One or more fines, penalties or final judgments, orders or decrees for the payment of money in an amount, individually or in the aggregate, of at least Two Hundred Fifty Thousand Dollars ($250,000.00) (not covered by independent third-party insurance as to which liability has been accepted by such insurance carrier) shall be rendered against Borrower by any Governmental Authority, and the same are not, within ten (10) days after the entry, assessment or issuance thereof, discharged, satisfied, or paid, or after execution thereof, stayed or bonded pending appeal, or such judgments are not discharged prior to the expiration of any such stay (provided that no Credit Extensions will be made prior to the satisfaction, payment, discharge, stay, or bonding of such fine, penalty, judgment, order or decree);
Damages Should the registration or the effectiveness thereof required by Sections 5.1 and 5.2 hereof be delayed by the Company or the Company otherwise fails to comply with such provisions, the Holder(s) shall, in addition to any other legal or other relief available to the Holder(s), be entitled to obtain specific performance or other equitable (including injunctive) relief against the threatened breach of such provisions or the continuation of any such breach, without the necessity of proving actual damages and without the necessity of posting bond or other security.
INDEMNIFICATION FOR DAMAGES, TAXES AND CONTRIBUTIONS CONTRACTOR shall exonerate, indemnify, defend, and hold harmless COUNTY (which for the purpose of paragraphs 5 and 6 shall include, without limitation, its officers, agents, employees and volunteers) from and against:
A. Any and all claims, demands, losses, damages, defense costs, or liability of any kind or nature which COUNTY may sustain or incur or which may be imposed upon it for injury to or death of persons, or damage to property as a result of, arising out of, or in any manner connected with the CONTRACTOR'S performance under the terms of this Agreement, excepting any liability arising out of the sole negligence of the COUNTY. Such indemnification includes any damage to the or of CONTRACTOR and third persons.
B. Any and all Federal, State and Local taxes, charges, fees, or contributions required to be paid with respect to CONTRACTOR and CONTRACTOR'S officers, employees and agents engaged in the performance of this Agreement (including, without limitation, unemployment insurance, social security and payroll tax withholding).
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
B. Such liquidated damages shall be calculated as an amount equaling the difference between:
1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and
2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract.
C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.
Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.
