Construction Standards The Developer shall construct the Subdivision in accordance with the Subdivision Plan, as approved by the Planning Commission, and if applicable, the requirements of the Design Review Committee, and in accordance with the requirements of
(a) the Millington Subdivision Regulations; (b) standards and specifications contained in “Local Public Works Standard, and Specifications”, as amended to include specific requirements for construction in Millington, TN; (c) the Building Code (as adopted by Shelby County); (d) the Fire Code (as adopted by Shelby County); (e) the Millington Zoning Ordinance; and (f) the applicable Ordinances of the City. Items (a) through (f) are hereby made a part of this Agreement by reference and are hereinafter referred to collectively as the “Codes”. References herein to the Codes are to those in effect on the Effective Date unless amendments are hereafter made which apply to all improvements or subdivisions regardless of their date of commencement and/or completion of construction. The Conditions of Approval established by the Planning Commission, and, as applicable, the Design Review Committee (any or all of which as may have been modified by the Board of Mayor and Aldermen) are set forth in Exhibit “A” to this Agreement and are incorporated herein by reference and made a part hereof.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Applicable Law and Construction This Lease may be executed in counterparts, shall be construed as a sealed instrument, and shall be governed exclusively by the provisions hereof and by the laws of the state where the Property is located without regard to principles of choice of law or conflicts of law. A facsimile signature to this Lease shall be sufficient to prove the execution by a party. If any provisions shall to any extent be invalid, the remainder shall not be affected. Other than contemporaneous instruments executed and delivered of even date, if any, this Lease contains all of the agreements between Landlord and Tenant relating in any way to the Premises and supersedes all prior agreements and dealings between them. There are no oral agreements between Landlord and Tenant relating to this Lease or the Premises. This Lease may be amended only by instrument in writing executed and delivered by both Landlord and Tenant. The provisions of this Lease shall bind Landlord and Tenant and their respective successors and assigns, and shall inure to the benefit of Landlord and its successors and assigns and of Tenant and its permitted successors and assigns, subject to Article 13. The titles are for convenience only and shall not be considered a part of this Lease. This Lease shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared primarily by counsel for one of the parties, it being recognized that both Landlord and Tenant have contributed substantially and materially to the preparation of this Lease. If Tenant is granted any extension or other option, to be effective the exercise (and notice thereof) shall be unconditional; and if Tenant purports to condition the exercise of any option or to vary its terms in any manner, then the purported exercise shall be ineffective. The enumeration of specific examples of a general provision shall not be construed as a limitation of the general provision. Unless a party’s approval or consent is required by the express terms of this Lease not to be unreasonably withheld, such approval or consent may be withheld in the party’s sole discretion. The submission of a form of this Lease or any summary of its terms shall not constitute an offer by Landlord to Tenant; but a leasehold shall only be created and the parties bound when this Lease is executed and delivered by both Landlord and Tenant and approved by the holder of any mortgage of the Premises having the right to approve this Lease. Nothing herein shall be construed as creating the relationship between Landlord and Tenant of principal and agent, or of partners or joint venturers or any relationship other than landlord and tenant. This Lease and all consents, notices, approvals and all other related documents may be reproduced by any party by any electronic means or by facsimile, photographic, microfilm, microfiche or other reproduction process and the originals may be destroyed; and each party agrees that any reproductions shall be as admissible in evidence in any judicial or administrative proceeding as the original itself (whether or not the original is in existence and whether or not reproduction was made in the regular course of business), and that any further reproduction of such reproduction shall likewise be admissible. If any payment in the nature of interest provided for in this Lease shall exceed the maximum interest permitted under controlling law, as established by final judgment of a court, then such interest shall instead be at the maximum permitted interest rate as established by such judgment.
Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.
Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:
1. Coordination and providing supervision to all Subcontractor and workers;
2. Posting of the prevailing wage scale;
3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel;
4. Conducting weekly on-site safety meetings;
5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day.
a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day.
b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered.
c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation.
6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.
ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.
Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
