Opinion of Probable Cost Any opinions of probable Project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer’s experience and qualifications and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s’) methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual Project or construction cost will not vary from opinions of probable cost Engineer prepares.
Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted at the end of each design phase in accordance with this Agreement. The Construction Cost Budget does not include the compensation of the Architect and the Architect’s Consultants, the cost of land, rights-of-way, financing or other costs which are the responsibility of the District, including construction management.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Reports of Foreclosures and Abandonment of Mortgaged Property The Master Servicer or the Subservicers shall file information returns with respect to the receipt of mortgage interests received in a trade or business, the reports of foreclosures and abandonments of any Mortgaged Property and the information returns relating to cancellation of indebtedness income with respect to any Mortgaged Property required by Sections 6050H, 6050J and 6050P, respectively, of the Code, and deliver to the Trustee an Officers' Certificate on or before March 31 of each year stating that such reports have been filed. Such reports shall be in form and substance sufficient to meet the reporting requirements imposed by Sections 6050H, 6050J and 6050P of the Code.
Construction Warranty At the Closing, Seller shall assign to Buyer all construction warranties with respect to the Hotel, which assignment shall be in form and substance reasonably satisfactory to Buyer, including a warranty by the Contractor, for the period ending not sooner than one (1) year after the date the Hotel is Substantially Completed, in the form of the warranty attached hereto as Exhibit H (the “Construction Warranty”).
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
Environmental Assessment Buyer shall have the right for a period commencing upon execution of this Agreement by both parties and ending on November 28, 2012, to conduct an environmental assessment of the Assets, at Buyer’s sole risk, liability and expense. Seller shall make available to Buyer, during the environmental assessment period described above, Seller’s historical files regarding prior operations on the Assets, and provide Buyer and its representatives with reasonable access to the Assets to conduct the environmental assessment. Buyer shall provide Seller three (3) days prior written notice of a desired date(s) for such assessment and Seller shall have the right to be present during any assessment and, if any testing is conducted pursuant to Seller’s express prior written consent, Seller may require splitting of all samples. Notwithstanding any other provision of this Agreement to the contrary, Buyer shall not have the right to drill any test, monitor or other xxxxx or to extract samples of any air, soil, water or other substance from the Assets without Seller’s express prior written consent. If Buyer proposes a reasonable request to drill a test well or extract a sample pursuant to a systematic and customary procedure for the assessment of the environmental condition of the Assets and Seller refuses to grant its consent to such a well or sampling, then Buyer shall have the right, for a period of seventy-two (72) hours following notification of Seller’s refusal to consent, to deliver written notice to Seller of Buyer’s election to exclude from this transaction the portion of the Assets affected by such proposed test well or sample, and the Purchase Price shall be adjusted accordingly by the Allocated Value of such portion of the Assets so excluded. Under no circumstances whatsoever shall Seller ever be obligated to grant its consent to any such test xxxxx or sampling proposed by Buyer, and Buyer’s sole and exclusive remedy for any refusal by Seller to grant its consent shall be the limited right contained in the preceding sentence to exclude the affected Assets from the transactions contemplated by this Agreement. If Buyer fails to exercise the right to exclude such Assets by written notice to Seller delivered prior to the expiration of the seventy-two hour period described above, then Buyer shall be conclusively deemed to have waived such right and shall be obligated to purchase the affected Assets without conducting such testing or sampling or any adjustment of the Purchase Price unless otherwise provided in this Agreement.
Initial Contribution of Trust Property; Organizational Expenses The Property Trustee acknowledges receipt in trust from the Depositor in connection with the Original Trust Agreement of the sum of $10, which constituted the initial Trust Property. The Depositor shall pay organizational expenses of the Trust as they arise or shall, upon request of any Trustee, promptly reimburse such Trustee for any such expenses paid by such Trustee. The Depositor shall make no claim upon the Trust Property for the payment of such expenses.
Production Report and Lease Operating Statements Within 60 days after the end of each fiscal quarter, a report setting forth, for each calendar month during the then current fiscal year to date, the volume of production and sales attributable to production (and the prices at which such sales were made and the revenues derived from such sales) for each such calendar month from the Oil and Gas Properties, and setting forth the related ad valorem, severance and production taxes and lease operating expenses attributable thereto and incurred for each such calendar month.
Maintenance of Tangible Net Worth The Borrower shall maintain during each Fiscal Quarter a Tangible Net Worth of not less than the Minimum Tangible Net Worth.
