Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
Market Adjustments 22. Neither this Article nor any other in this Collective Agreement prevents the Employer from using other funds to increase a Member’s salary in response to offers received from other employers or to accommodate other market forces.
Non pre-priced Adjustment Factor To be applied to Work deemed not to be included in the CTC but within the general scope of the work:
C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Market Adjustment The parties to this Agreement recognize the appropriateness of market pay adjustments in rare instances for compelling reasons. To effectuate judgments in such cases, the President and AAUP Chapter President, in consultation, shall each name three (3) individuals to a university Market Evaluation Committee. Deans may submit recommendations for market pay adjustments with supporting written reasons to the committee. Said Committee shall consult with the President concerning proposed market pay adjustments reporting its advice not later than May 15 in each year. Upon the favorable recommendation of the President and the Chancellor, market pay adjustments may be approved effective at the beginning of that pay period including September 1 of the following year. Not more than one (1) market pay adjustment per one hundred (100) full-time members, or fraction thereof, may be recommended in any contract year. A member’s salary may not be increased beyond the maximum for the rank. Funding for this program shall be governed by Article 12.10.2.
CPI Adjustment In this Agreement, “CPI-Adjusted” in reference to an amount means that amount is adjusted under the following formula: N C (1 CPIn CPIc ) CPIc where: ”N” is the new amount being calculated; and “C” is the current amount being adjusted; and
Salary Adjustments At any time during the term of this Contract, the Board may, in its discretion, review and adjust the salary of the Superintendent, but in no event shall the Superintendent be paid less than the salary set forth in Section 3.1 of this Contract except by mutual agreement of the two parties. Such adjustments, if any, shall be made pursuant to a lawful Board resolution. In such event, the parties agree to provide their best efforts and reasonable cooperation to execute a new contract incorporating the adjusted salary.
Contract Term Adjustment “Contract Term Adjustment” means adjustment only as provided for in the three circumstances described in this Subsection. Under these circumstances, the contract term shall be adjusted in writing to include additional calendar days in one or more Normal Operating Seasons equal to the actual time lost, except as limited by paragraph (b) in this Subsection. To qualify for such adjustment, Purchaser shall give written notice of the lost time not later than 30 days after end of Normal Operating Season in which time was lost and at least 10 days before Termination Date. Contracting Officer shall make prompt written acknowledgment of such notice, indicating concurrence with the number of days in the notice or the number of days Forest Service considers as qualifying for the adjustment. Lost portions of days shall be disregarded in computing time lost. The three circumstances qualifying for a Contract Term Adjustment are:
Contingent Price Adjustment It is the policy of the State of Oregon that unprocessed timber shall not be exported from lands owned or managed by the STATE or any of its political subdivisions or agencies, in accordance with the terms of current federal law and the Constitution and the laws of the State of Oregon. PURCHASER specifically agrees that Section 1 is a material term of this contract and is part of the consideration offered to STATE in return for STATE's performance. In the event that any federal law or state constitutional provision or law or any provision of this contract concerning export of unprocessed timber is declared invalid by any court or administrative tribunal, PURCHASER agrees to pay to STATE a contingent price in the amount of the difference between the purchase price set forth in this section and the price obtained by PURCHASER for the exported unprocessed timber. The default provisions of OAR 629-032-0000 through 629-032-0070 shall not apply to exported unprocessed timber. In the event that timber made available under this contract is exported in violation of this contract, PURCHASER shall be in material breach of the contract. STATE shall be entitled to cease performance of the contract and recover, in addition to the adjusted price set out above, a further sum estimated to compensate for administrative expense and the economic impact of the violation upon the State and its citizens. In no case shall this additional amount be less than $10,000 per incident.
