Right to Lease Landlord reserves the absolute right to effect such other tenancies in the Project as Landlord in the exercise of its sole business judgment shall determine to best promote the interests of the Building or Project. Tenant does not rely on the fact, nor does Landlord represent, that any specific tenant or type or number of tenants shall, during the Lease Term, occupy any space in the Building or Project.
Demolition The Lessor shall remove existing abandoned electric, telephone, and data cabling and devices, as well as any other improvements or fixtures in place, to accommodate the Government’s requirements. Any demolition of existing improvements that is necessary to satisfy the Government’s layout shall be done at the Lessor’s expense.
Access to Leased Premises Landlord may enter the Leased Premises after business hours, upon twenty-four (24) hour notice to Tenant (and at any time and without notice in case of emergency), for the purposes of (a) inspect the Leased Premises, (b) exhibiting the Leased Premises to prospective purchasers, lenders or, within one hundred eighty (180) days of the end of the Term, prospective, (c) determining whether Tenant is complying with all of its obligations hereunder, (d) supplying janitorial service and any other services to be provided by Landlord to Tenant hereunder, (e) post notices of non-responsibility, and (f) make repairs required of Landlord under the terms hereof or repairs to any adjoining space or utility services or make repairs, alterations or improvements to any other portion of the Building. For such purposes, Landlord shall at all times have and retain a key with which to unlock all of the doors in, on or about the Leased Premises (excluding Tenant’s vaults, safes, storage facilities for sensitive materials, confidential patient files and similar areas designated in writing by Tenant in advance); and Landlord shall have the right to use any and all means which Landlord may deem proper to open said doors in any emergency in order to obtain entry to the Leased Premises. If, as a result of any such inspection or for any reason, Landlord reasonably determines that Tenant has failed to meet its obligations under Section 5.2 hereof, Landlord shall so notify Tenant and Tenant shall immediately commence to cure any such failure. In the event Tenant refuses or neglects to commence and complete such cure within a reasonable time, Landlord may make or cause to be made such repairs. In such event, Landlord’s cost to make such repairs shall constitute an Advance.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Construction of Lease This Lease has been prepared by Landlord and its professional advisors and reviewed by Tenant and its professional advisors. Landlord, Tenant, and their advisors believe that this Lease is the product of all their efforts, that it expresses their agreement, and agree that it shall not be interpreted in favor of either Landlord or Tenant or against either Landlord or Tenant merely because of their efforts in preparing it.
Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.
CONSTRUCTION AND RENOVATION Construction and renovation projects for a state, local, territorial, or Tribal government’s principal Emergency Operations Center (EOC) as defined by the State Administrative Agency are allowable under the EMPG Program. Written approval must be provided by FEMA prior to the use of any EMPG Program funds for construction or renovation. Requests for EMPG Program funds for construction of an EOC must be accompanied by an EOC Investment Justification (located in the Related Documents tab of the EMPG xxxxxx.xxx posting) to their Regional EMPG Manager for review. Additionally, recipients are required to submit a SF-424C Form and Budget detail citing the project costs. When applying for funds to construct communication towers Sub-Recipients must submit evidence that the Federal Communication Commission’s (FCC) Section 106 review process has been completed and submit all documentation resulting from that review to Grants Program Directorate (GPD) prior to submitting materials for EHP review. Sub-Recipients are also encouraged to have completed as many steps as possible for a successful EHP review in support of their proposal for funding (e.g., coordination with their State Historic Preservation Office to identify potential historic preservation issues and to discuss the potential for project effects, compliance with all state and EHP laws and requirements). Projects for which the Sub-Recipient believes an Environmental Assessment (EA) may be needed, as defined in as defined in DHS Instruction Manual 023-01-001-01, Revision 01, FEMA Directive 108-1 and FEMA Instruction 108-1-1, must also be identified to the FEMA EMPG Regional Program Manager within six months of the award, and completed EHP review materials must be submitted no later than 12 months before the end of the period of performance. EHP review packets should be sent to xxxxxxxxxx@xxxx.xxx. EMPG Program Sub-Recipients using funds for construction projects must comply with the Xxxxx-Xxxxx Act (40 U.S.C. §§ 3141 et seq.). Grant Sub-Recipients must ensure that their contractors or subcontractors for construction projects pay workers no less than the prevailing wages for laborers and mechanics employed on projects of a character similar to the contract work in the civil subdivision of the state in which the work is to be performed. Additional information regarding compliance with the Xxxxx- Xxxxx Act, including Department of Labor (DOL) wage determinations, is available from the following website: xxxxx://xxx.xxx.xxx/whd/govcontracts/dbra.htm In general, Sub-Recipients should consult with their Grant Manager prior to making any investment that does not clearly meet the allowable expense criteria established in this Guidance.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
Commencement of Construction Construction of the Project will start within thirty (30) days after notification to the Developer by the Owner, or as soon thereafter as weather and ground conditions permit.
By Lessee Lessee shall indemnify the Lessor, the Lessor’s Representative, and their Board members, directors, officers, employees, agents and authorized volunteers (the “Lessor Indemnitees”) against and will hold and save them and each of them harmless from any and all actions, claims, damages to persons or property, penalties, obligations or liabilities that may be asserted or claimed by any person, firm entity, corporation, political subdivision or other organization (collectively “Losses”) arising out of or in connection with the installation, operation or activities of Lessee, its agents, employees, subcontractors or invitees, provided for herein, whether or not there is concurrent passive or active negligence on the part of the Lessor Indemnitees for injury to or death of persons, including, but not limited to, employees of Lessee or Lessor, and damage or destruction of property, including, but not limited to, property of Lessee, any utility company or Lessor, or other loss or damage incurred by Lessor, but only to the extent caused by (A) the negligence, fraud or willful misconduct of Lessee, its agents, officers, directors, employees or contractors on or at the Premises or the Sites in connection with this Agreement or (B) the material breach by Lessee of any of its obligations under this Agreement, but excluding such actions, claims, damages to persons or property penalties, obligations or liabilities arising from the sole established negligence, fraud or willful misconduct of the Lessor, the Lessor’s Representative, or those who are directly responsible to them. In connection therewith: (a) Lessee will defend any action or actions filed in connection with any of said claims, damages, penalties, obligations or liabilities and will pay all costs and expenses, including attorney's fees incurred in connection therewith; and (b) Lessee will promptly pay any judgment rendered against Lessee, and/or the Lessor Indemnitees covering such claims, damages, penalties, obligations and liabilities arising out of or in connection with such installation, operations, or activities of Lessee hereunder and Xxxxxx agrees to save and hold the Lessor Indemnitees harmless therefore.
A. In the event the Lessor Indemnitees are made a party to any action or proceeding filed or prosecuted against Lessee for such damages or other claims arising out of or in connection with the installation, or operation or activities of Lessee hereunder, Xxxxxx agrees to pay to the Lessor Indemnitees any and all costs and expenses incurred by the Lessor Indemnitees in such action or proceeding together with reasonable attorney’s fees and expert witness fees and other litigation related expenses.
