Procedure for Relief and Compensation Sample Clauses

Procedure for Relief and Compensation. Subject to Clause 15.8 (Late Provision of Information) to obtain relief and/or claim compensation the Contractor must:-
AutoNDA by SimpleDocs
Procedure for Relief and Compensation. Subject to Section 12.2(d) (Late Provision of Notice or Information), any claim made by the Development Entity pursuant to Section 12.2(a) must:
Procedure for Relief and Compensation. Subject to Section 12.2.4 (Late Provision of Notice or Information), any claim made by Developer pursuant to Section 12.2.1 must:
Procedure for Relief and Compensation. Developer shall not be entitled to any extension of time, compensation or relief from its obligations under this Agreement with respect to the relevant Compensation Event.
Procedure for Relief and Compensation then the Contractor shall not be entitled to any extension of time, compensation, or relief from its obligations under the Contract in respect of the period for which the information is delayed.
Procedure for Relief and Compensation give full details of the Compensation Event and the extension of time and/or relief from its obligations under this Contract and/or any Change in Costs claimed; and
Procedure for Relief and Compensation. To obtain relief, extension and/or claim compensation the Contractor must:
AutoNDA by SimpleDocs
Procedure for Relief and Compensation give full details of the Compensation Event and the extension of time and/or relief from its obligations under this Contract and/or any Change in Costs claimed; and 15.2.3.1 the Compensation Event was the direct cause of:
Procedure for Relief and Compensation give full details of the Compensation Event and the extension of time amendment to the relevant Milestone(s) and/or any Estimated Change in Project Costs and/or loss of revenue claimed; and

Related to Procedure for Relief and Compensation

  • Procedure for Rebate The Association represents to the Board that an internal rebate procedure has been established in accordance with Section 4117.09(C) of the Revised Code and that a procedure for challenging the amount of the representation fee has been established and will be given to each member of the bargaining unit who does not join the Association and that such procedure and notice shall be in compliance with all applicable state and federal laws and the Constitutions of the United States and the State of Ohio.

  • Procedure for claiming relief Without prejudice to Clause 17.3, an Affected Party is only entitled to claim force majeure relief under this Clause 17 if it complies with the obligations to give Force Majeure Notices, Force Majeure Reports and provide other information under Clause 17.5 and to perform its obligations under Clause 17.6.

  • CLASSIFICATION AND COMPENSATION The parties hereto agree that the employees covered by this Agreement shall be considered engaged in the type of work and classification as set forth on Schedule A attached hereto and made a part hereof by reference.

  • Procedure for taking possession - The Promoter, upon obtaining the occupancy certificate* from the competent authority shall offer in writing the possession of the [Apartment/Plot], to the Allottee in terms of this Agreement to be taken within two months from the date of issue of occupancy certificate. [Provided that, in the absence of local law, the conveyance deed in favour of the allottee shall be carried out by the promoter within 3 months from the date of issue of occupancy certificate]. The Promoter agrees and undertakes to indemnify the Allottee in case of failure of fulfilment of any of the provisions, formalities, documentation on part of the Promoter. The Allottee, after taking possession, agree(s) to pay the maintenance charges as determined by the Promoter/association of allottees, as the case may be after the issuance of the completion certificate for the project. The promoter shall hand over the occupancy certificate of the apartment/plot, as the case may be, to the allottee at the time of conveyance of the same.

  • Expropriation and Compensation 1. Neither Contracting Party shall expropriate or nationalise investments in its Area of investors of the other Contracting Party or take any measure equivalent to expropriation or nationalisation (hereinafter referred to as "expropriation") except:

  • GRIEVANCE PROCEDURE AND ARBITRATION 8.01 For purposes of this Agreement, a grievance is defined as a difference arising between the parties relating to the interpretation, application, administration or alleged violation of the Agreement including any question as to whether a matter is arbitrable.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!