Prohibition Against Transfer of Project and Assignment of Agreement Sample Clauses

Prohibition Against Transfer of Project and Assignment of Agreement. The Developer represents and agrees that prior to the Termination Date, except as otherwise permitted herein, the Developer shall not transfer the Project or any part thereof, without the prior written approval of the EDA, which approval shall not be unreasonably condition or delayed, as long as the following conditions are met to the EDA’s reasonable satisfaction: (1) Any proposed transferee has the qualifications and financial responsibility, necessary and adequate to fulfill the obligations undertaken in this Agreement by the Developer; (2) Any proposed transferee, by instrument in writing satisfactory to the EDA shall, for itself and its successors and assigns, and expressly for the benefit of the EDA, have expressly assumed all of the obligations of the Developer under this Agreement and agreed to be subject to all the conditions and restrictions to which the Developer is subject; and (3) There is submitted to the EDA for review and prior written approval all instruments and other legal documents involved in effecting the transfer of any interest in this Agreement or the Project.
Sample 1Sample 2
AutoNDA by SimpleDocs
Prohibition Against Transfer of Project and Assignment of Agreement. The Developer represents and agrees that prior to the Termination Date the Developer shall not transfer this Agreement, the Tax Abatement Note, or the Development Property or the Project or any part thereof or any interest therein, except to an Affiliate, with written notice to the City Administrator, and to tenants in the ordinary course, without the prior written approval of the City Administrator, or their designee, which approval shall not be unreasonably withheld, conditioned or delayed. The City Administrator, or their designee, shall be entitled to require as conditions to any such approval that: (1) Any proposed transferee, by instrument in writing satisfactory to the City Administrator, or their designee, shall, for itself and its successors and assigns, and expressly for the benefit of the City, have expressly assumed all of the obligations of the Developer under this Agreement and agreed to be subject to all the conditions and restrictions to which the Developer is subject. (2) There shall be submitted to the City Administrator, or their designee, for review and prior written approval the legal document(s) evidencing the transfer of any interest in this Agreement or the Project. (3) Any proposed transferee of the Tax Abatement Note shall execute and deliver to the City an acknowledgment demonstrating that such transfer is exempt from registration and prospectus delivery requirements of federal and applicable state securities laws and the transferee understands the limited source of payment of the Tax Abatement Note, in a form satisfactory to the City Administrator, or their designee. (4) The Developer shall have paid all reasonable legal fees and expenses of the City, including fees of the City Attorney’s office and outside counsel retained by the City to review the documents submitted to the City in connection with any transfer. If the City Administrator, or their designee, rejects the request for approval of an assignment as inadequate, they will do so in writing specifying the basis for the rejection. Notwithstanding the foregoing, the Developer may elect to transfer the Development Property without the consent of the City and the sole remedy exercised by the City upon such an Event of Default is that the City may terminate this Agreement and the Abatement Note. In the event the foregoing conditions are satisfied, then the Developer will be released from its obligations under this Agreement.
Sample 1Sample 2
Prohibition Against Transfer of Project and Assignment of Agreement. The Developer represents and agrees that prior to the Termination Date the Developer shall not transfer the Project or any part thereof or any interest therein, without the prior written approval of the City. The City shall be entitled to require as conditions to any such approval that: (1) Any proposed transferee shall have the qualifications and financial responsibility, in the reasonable judgment of the City, necessary and adequate to fulfill the obligations undertaken in this Agreement by the Developer. (2) Any proposed transferee, by instrument in writing satisfactory to the City shall, for itself and its successors and assigns, and expressly for the benefit of the City, have expressly assumed all of the obligations of the Developer under this Agreement and agreed to be subject to all the conditions and restrictions to which the Developer is subject. (3) There shall be submitted to the City for review and prior written approval all instruments and other legal documents involved in effecting the transfer of any interest in this Agreement or the Project.
Sample 1
Prohibition Against Transfer of Project and Assignment of Agreement. The Developer represents and agrees that prior to the Termination Date the Developer shall not transfer the Project (except for leased to tenants in the ordinary course of Developer’s business) or any part thereof or any interest therein, without the prior written approval of the City. The conditions to any such City approval are: (1) Any proposed transferee shall have the qualifications and financial responsibility, in the reasonable judgment of the City, necessary and adequate to fulfill the obligations undertaken in this Agreement by the Developer. (2) Any proposed transferee, by instrument in writing satisfactory to the City shall, for itself and its successors and assigns, and expressly for the benefit of the City, have expressly assumed all of the obligations of the Developer under this Agreement and agreed to be subject to all the conditions and restrictions to which the Developer is subject. (3) There shall be submitted to the City for review and prior written approval all instruments and other legal documents involved in effecting the transfer of any interest in this Agreement or the Project.
Sample 1

Related to Prohibition Against Transfer of Project and Assignment of Agreement

  • Prohibition Against Assignment During the Vesting Period, the Restricted Shares may not be transferred or encumbered by the Recipient by means of sale, assignment, mortgage, transfer, exchange, pledge, or otherwise. The levy of any execution, attachment, or similar process upon the Restricted Shares shall be null and void.

  • Amendment and Assignment of Agreement This Agreement may not be amended or assigned without the affirmative vote of a majority of the outstanding voting securities of the Fund, and this Agreement shall automatically and immediately terminate in the event of its assignment.

  • Assignment of Agreement The following conditions must be satisfied in order to effectuate any assignment of this Agreement: (i) This Agreement may only be transferred through a book entry system maintained by Principal Life, or an agent designated by it, within the meaning of Temporary Treasury Regulations Section 5f.103-1(c) and Treasury Regulations Section 1.871-14(c)(1)(i). (ii) The Agreement Holder, and any assignee, must comply with applicable securities laws. (iii) Principal Life has consented in writing to the proposed assignment, such consent not to be unreasonably withheld. (iv) Principal Life shall have received from the proposed assignee a duly executed certificate containing, in substance, the information, representations, warranties, acknowledgments and agreements set forth in this Agreement. Any attempted sale, transfer, anticipation, assignment, hypothecation, or alienation not in accordance with this Section 6 shall be void and of no effect. Until such time, if any, as Principal Life has consented in writing to a proposed assignment, Principal Life shall not be obligated to make any payments to or at the direction of anyone other than the person shown on Principal Life’s books and records as the Agreement Holder. Once the foregoing conditions have been satisfied with respect to an assignment, the assignee or its successor shall be deemed to be the sole Agreement Holder for all purposes of this Agreement and Principal Life shall promptly amend its records to reflect the assignee’s status as Agreement Holder.

  • Alienability and Assignment Prohibition Neither the Executive, nor the Executive's surviving spouse, nor any other beneficiary(ies) under this Executive Plan shall have any power or right to transfer, assign, anticipate, hypothecate, mortgage, commute, modify or otherwise encumber in advance any of the benefits payable hereunder nor shall any of said benefits be subject to seizure for the payment of any debts, judgments, alimony or separate maintenance owed by the Executive or the Executive's beneficiary(ies), nor be transferable by operation of law in the event of bankruptcy, insolvency or otherwise. In the event the Executive or any beneficiary attempts assignment, commutation, hypothecation, transfer or disposal of the benefits hereunder, the Bank's liabilities shall forthwith cease and terminate.

  • Successors and Assigns; Assignment of Agreement This Agreement shall bind and inure to the benefit of and be enforceable by the Primary Servicer and the Master Servicer and the respective successors and assigns of the Primary Servicer and the Master Servicer. This Agreement shall not be assigned, pledged or hypothecated by the Primary Servicer to a third party except as otherwise specifically provided for herein. If the Master Servicer shall for any reason no longer act in such capacity under the Pooling and Servicing Agreement (including, by reason of Servicer Termination Event), any successor to the Master Servicer under Pooling and Servicing Agreement (including the Trustee if the Trustee has become such successor pursuant to Section 7.02 of the Pooling and Servicing Agreement) may thereupon assume all of the rights and, except to the extent they arose prior to the date of assumption, obligations of the Master Servicer under this Agreement.

  • Non-Assignment of Agreement The Grantee may not assign, sublicense or otherwise transfer its rights, duties or obligations under this Agreement without the prior written consent of the Division, which shall not unreasonably be withheld. The agreement transferee must demonstrate compliance with the requirements of the project. If the Division approves a transfer of the Grantee’s obligations, the Grantee shall remain liable for all work performed and all expenses incurred in connection with this Agreement. In the event the Legislature transfers the rights, duties and obligations of the Division to another governmental entity, pursuant to Section 20.06, Florida Statutes or otherwise, the rights, duties and obligations under this Agreement shall be transferred to the succeeding governmental agency as if it was the original party to this Agreement.

  • Successors and Assigns; Assignment of Purchase Agreement This Agreement shall bind and inure to the benefit of and be enforceable by the Seller and the Purchaser and the respective permitted successors and assigns of the Seller and the successors and assigns of the Purchaser. This Agreement shall not be assigned, pledged or hypothecated by the Seller to a third party without the prior written consent of the Purchaser, which consent may be withheld by the Purchaser in its sole discretion. This Agreement may be assigned, pledged or hypothecated by the Purchaser in whole or in part, and with respect to one or more of the Mortgage Loans, without the consent of the Seller. There shall be no limitation on the number of assignments or transfers allowable by the Purchaser with respect to the Mortgage Loans and this Agreement. In the event the Purchaser assigns this Agreement, and the assignee assumes any of the Purchaser's obligations hereunder, the Seller acknowledges and agrees to look solely to such assignee, and not to the Purchaser, for performance of the obligations so assumed and the Purchaser shall be relieved from any liability to the Seller with respect thereto.

  • Assignment of Agreements Each applicable Borrower shall have executed and delivered to Lender the Assignments of Agreements, and the Assignments of Agreements shall, to the extent prudent pursuant to local practice, have been irrevocably delivered to an authorized title agent for the Title Insurer for such recordation in the appropriate filing offices in the jurisdiction in which the applicable Individual Property is located.

  • Binding Effect; Assignment; No Third Party Benefit This Agreement shall be binding upon and inure to the benefit of the parties hereto and their respective heirs, legal representatives, successors, and permitted assigns. Except as otherwise expressly provided in this Agreement, neither this Agreement nor any of the rights, interests, or obligations hereunder shall be assigned by any of the parties hereto without the prior written consent of the other parties. Except as provided in Section 8.5 and Article XI, nothing in this Agreement, express or implied, is intended to or shall confer upon any Person other than the parties hereto, and their respective heirs, legal representatives, successors, and permitted assigns, any rights, benefits, or remedies of any nature whatsoever under or by reason of this Agreement.

  • Successors and Assigns; Assignment of Servicing Agreement This Agreement shall bind and inure to the benefit of and be enforceable by the Servicer, the Seller, the NIMS Insurer and the Master Servicer and their respective successors and assigns. This Agreement shall not be assigned, pledged or hypothecated by the Servicer to a third party except in accordance with Section 7.03 and shall not be assigned, pledged or hypothecated by the Seller without the prior written consent of the NIMS Insurer except as to the extent provided in Section 9.12.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!