Unforeseeable difficulties Except as otherwise stated in the Agreement: (a) the Contractor accepts complete responsibility for having foreseen all difficulties and costs of successfully completing the Works; (b) the Contract Price shall not be adjusted to take account of any unforeseen difficulties or costs; and (c) the Scheduled Completion Date shall not be adjusted to take account of any unforeseen difficulties or costs.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence: a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
FORCE MAJEURE CIRCUMSTANCES Lithium Hosting, llc CANNOT and WILL NOT be liable for any failure or delay in doing its professional duties resulting from circumstances beyond its physical control. Such circumstances may represent acts of any governmental body, war, rebellion, sabotage, embargo, fire, flood or other natural disaster, strike or other labor disturbances, interruption of or delay in transportation, unavailability of, interruption or delay in telecommunications or third party services (including DNS propagation), failure of third party software or hardware, or inability to obtain raw materials, supplies or power used in or equipment needed for provisioning of the Services.
Extra Work At any time during the Term of this Agreement, City may request that Consultant perform Extra Work. As used herein, “Extra Work” means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Consultant shall not perform, nor be compensated for, Extra Work without written authorization from City’s Representative.
Force Majeure Report Following the giving of a Force Majeure Notice: (a) the Affected Party shall give a Force Majeure Report as soon as practicable, and in any event within 7 days of service of the Force Majeure Notice; and (b) the Force Majeure Report shall constitute a full report on the Relevant Force Majeure Event, amplifying the information provided in the Force Majeure Notice and containing such information as may reasonably be required by the Non-affected Party, including the effect which the Relevant Force Majeure Event is estimated to have on the Affected Party’s performance of the Relevant Obligations.
Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following: i) acts of God; ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities; iii) acts of war (whether declared or undeclared), invasion or civil unrest; iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement); v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals; vi) earthquakes, explosions, accidents, landslides; fire; vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality; viii) chemical or radioactive contamination or ionizing radiation; or ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs; x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.
Project Work PURCHASER shall complete the following projects in accordance with the specifications provided in Exhibits B, C, D, E, and F and written instructions from STATE. Project locations are shown on Exhibit A unless otherwise described. PURCHASER shall furnish all material unless otherwise specified.
Uncontrollable Forces 12.1 Section 14.1 of the CAISO Tariff shall be incorporated by reference into this Agreement except that all references in Section 14.1 of the CAISO Tariff to Market Participants shall be read as a reference to the Scheduling Coordinator and references to the CAISO Tariff shall be read as references to this Agreement.
Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:
Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.