Proposed Change Order Certification Sample Clauses

Proposed Change Order Certification. In submitting a PCO, Developer certifies and affirms that the cost and/or time request is submitted in good faith, that the cost and/or time request is accurate and in accordance with the provisions of the Contract Documents, and Developer submits the cost and/or request for extension of time recognizing the significant civil penalties and treble damages which follow from making a false claim or presenting a false claim under Government Code section 12650 et seq. It is expressly understood that the value of the extra Work or changes expressly includes any and all of Developer’s costs and expenses, direct and indirect, resulting from additional time required on the Project or resulting from delay to the Project including, without limitation, cumulative impacts. Developer is not entitled to separately recover amounts for overhead or other indirect costs. Any costs, expenses, damages, or time extensions not included are deemed waived.
AutoNDA by SimpleDocs
Proposed Change Order Certification. In submitting a PCO, Developer certifies and affirms that the cost and/or time request is submitted in good faith, that the cost and/or time request is accurate and in accordance with the provisions of the Contract Documents, and the Developer submits the cost and/or request for extension of time recognizing the significant civil penalties and treble damages which follow from making a false claim or presenting a false claim under Government Code section 12650 et seq.

Related to Proposed Change Order Certification

  • Owner Certification During the term of this Contract, the Owner certifies that: a) The Owner will, at all times, maintain the Unit and premises, including common areas accessible to the Tenant, in decent, safe, and sanitary condition and compliant with applicable state or local codes and rental housing requirements; and b) The Owner will comply in all material respects with this Contract; and c) The Unit is leased to and, to the best of the Owner’s knowledge, is occupied by the Tenant; and, d) Owner has taken no action and will not take any action to terminate the Lease and cause the Tenant to vacate the Unit without providing written notice of such action to the Tenant and the Program Administrator; and e) Other than the Tenant’s Contribution, the Owner has not received and will not receive any payments or other consideration (from the Tenant, HUD, or any other public or private source) for rental of the Unit during the Term of this Contract except as identified in Exhibit A; and f) To the best of the Owner’s knowledge, the Unit is used solely as the Tenant’s principal place of residence; and g) The Tenant does not own or have any interest in the Unit; and h) The Owner (including a principal or other interested party) is not the parent, child, grandparent, grandchild, sister, or brother of any member of the family of the Tenant, unless the Program Administrator has determined (and has notified the Owner and the Tenant of such determination) that approving rental of the unit, notwithstanding such relationship, would provide reasonable accommodation for a family member who is a person with disabilities.

  • Exhibit D - Debarment Certification By signing and submitting this Contract, the Contractor is agreeing to abide by the debarment requirements as set out below.

  • Auction Schedule The Auction Agent shall conduct Auctions in accordance with the schedule set forth below. Such schedule may be changed by the Auction Agent with the consent of the Company, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to each Broker-Dealer. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- ----- By 9:30 A.M. Auction Agent advises the Company and the Broker-Dealers of the Reference Rate and the Maximum Applicable Rate as set forth in Section 2.2(e)(i) hereof.

  • AS9100 Certification ‌ AS9100 Certification, specifies requirements for a quality management system to demonstrate the Contractor’s ability to consistently meet the customer requirements as well as statutory and regulatory requirements for the aerospace industry. An AS9100 Certification, is not mandatory; however, Contractors who desire to compete for work within the aerospace industry are encouraged to have AS9100 Certification, during the entire term of OASIS. The Contractor shall notify the OASIS CO, in writing, if there are any changes in the status of their AS9100 Certification, and provide the reasons for the change and copies of audits from an AS9100 Certification Body, as applicable. If only part of a Contractor’s organization is AS9100, certified, the Contractor shall make the distinction between which business units or sites and geographic locations have been certified.

  • Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof. 6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement. 6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement. 6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER. 6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing. 6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8. 6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • Drug-Free Workplace Certification As required by Executive Order No. 90-5 dated April 12, 1990, issued by the Governor of Indiana, the Company hereby covenants and agrees to make a good faith effort to provide and maintain a drug-free workplace at the Project Location. The Company will give written notice to the IEDC within ten (10) days after receiving actual notice that the Company, or an employee of the Company in the State of Indiana, has been convicted of a criminal drug violation occurring in the workplace. False certification or violation of this certification may result in sanctions including, but not limited to, suspension of payments under the Agreement, termination of the Agreement and/or debarment of contracting opportunities with the State for up to three (3) years. In addition to the provisions of the above paragraph, if the total amount set forth in the Agreement is in excess of $25,000.00, the Company agrees that it will provide a drug-free workplace by: A. Publishing and providing to all of its employees a statement notifying them that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Company’s workplace, and specifying the actions that will be taken against employees for violations of such prohibition;

  • Lobbying Certification This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by section 1352, title 31, U.S.C. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.

  • CONTRACT EXHIBIT I PREFERRED PRICING AFFIDAVIT This preferred-pricing affidavit is entered into in accordance with section 216.0113, F.S., and as required by Contract No. 80101507-21-STC-ITSA (“Contract”) between (“Contractor”) and the Department of Management Services. As the person authorized by Contractor to sign this affidavit, I attest that the Contractor is in full compliance with the preferred-pricing clause of the Contract. Contractor’s Name: By: Signature Printed Name/Title Date: STATE OF COUNTY OF Sworn to (or affirmed) and subscribed before me this day of , by Vendor Name: FEIN# Vendor’s Authorized Representative Name and Title: Address: City, State, and Zip code: Phone Number: ( ) - E-mail: CORPORATE SEAL (IF APPLICABLE) (Print, Type, or Stamp Commissioned Name of Notary Public) [Check One] Personally Known OR Produced the following I.D.

  • New Certifications If a participating Employer is newly certified by ONA at one of its owned nursing homes for its registered nurses, the existing standard non-monetary provisions in the central ONA/RN agreements will automatically apply to the nurses effective nine (9) months after the Employer receives notice to bargain from the Union or a Memorandum of Agreement or Interest Arbitration Award is received, whichever is earlier. These provisions include: Article 1 Article 2.03 Articles 2.05, 2.07-2.12 Articles 3-8 Articles 9.01(d) only, 9.03-9.13, 9.15, 9.16, 9.17 Article 10

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!