Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work.
Section 5.2 Prior to commencing any Tenant’s Work other than purely Cosmetic Alterations, Tenant shall, at Tenant’s expense, deliver to Landlord detailed plans and specifications, for Tenant’s Work, in form reasonably satisfactory to Landlord, prepared, certified, signed and sealed by an architect or engineer licensed to practice in the State of New York, and suitable for filing with the applicable Authority, if filing is required by applicable Laws (such plans and specifications together with revisions thereto, collectively, “Tenant’s Plans”), and obtain Landlord’s approval of Xxxxxx’s Plans. Xxxxxxxx’s approval of Xxxxxx’s Plans shall not be unreasonably withheld or delayed to the extent Xxxxxxxx’s consent to Xxxxxx’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article. Before commencing Tenant’s Work, Tenant shall (a) obtain (and deliver to Landlord copies of) all required permits and authorizations of any Authority for such work, and (b) deliver to Landlord such security as shall be reasonably satisfactory to Landlord, and (c) deliver to Landlord certificates (in form reasonably acceptable to Landlord) evidencing the following insurance coverages from each contractor and subcontractor: (i) worker’s compensation insurance covering all persons to be employed in the performance of any Tenant’s Work, and
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
Tenant's Improvements If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.
Completion of Improvements Within 90 days of completion of any construction herein permitted, Company will cause to be prepared and delivered to Authority record documents as required under the Tenant Work Permit process, including but not limited to as-builts, legal descriptions, boundary surveys, and certified final cost of construction. The submission of record document electronic media will be in accordance with Authority’s Standard Procedure for computer aided design and drafting and drawings, as may be revised from time to time.
Construction of Improvements Lessee shall construct its planned facilities and install therein all necessary fixtures, equipment, and accessories, all of which shall be in accordance with the terms and conditions of this Lease and any applicable city code or FAA requirements. Lessee shall complete construction of the new improvements within one (1) year after the Effective Date of this Lease. Existing improvements shall be deemed to have been appropriately constructed so long as they are well-maintained and meet all applicable city code and FAA requirements. It is expressly understood that upon the expiration of the Lease, all hangar improvements shall become property of Lessor.
8.1 Lessee agrees to reimburse Lessor for the apportioned costs of roadway improvements including, but not limited to: excavation, paving, drainage, and fencing required for all extensions of the access road to the Leased Premises. Lessee shall be responsible for the cost of all extensions, as applicable, of all water, sewer, and other utilities to the Leased Premises, as well as any fees for obtaining service. Lessee shall be responsible for payment at the time improvements are completed. Lessee shall remit payment to Lessor within thirty (30) days from the date of invoice.
8.2 Lessee agrees to construct, at Lessee’s expense, aircraft access improvements, including without limitation driveways, taxi lanes, aprons, and ramps to its planned facility. Construction and location of the access improvements shall comply with specifications set forth by Lessor at the time of plan’s approval. Lessee understands that those portions of the constructed Airport access improvements situated outside the boundaries of the Leased Premises shall become, immediately upon their completion to Lessor’s satisfaction, the property of Lessor. All construction and any connections to the runway of any apron or taxi lane shall in addition be governed by any rules or regulations regarding Airport operations and must be approved of and overseen by Airport management. Constructed facilities shall not be occupied until access is completed and accepted by Lessor.
8.3 Upon completion of improvements, Lessee shall provide an 8 ½” x 11” site plan detailing a scaled drawing of the Leased Premises, hangar foot print, office area, parking, landscaping, and any other improvements.
8.4 The provisions provided above do not relieve Lessee from compliance with all applicable building code requirements and acquiring all necessary licenses and permits from any governmental authority.
8.5 If the aircraft hangar or other improvements on the Leased Premises are damaged or destroyed, Lessee shall do whatever is necessary to repair, rebuild, or restore the structure and other improvements to substantially the same condition existing prior to the damage or destruction within 180 days of the date of destruction. Upon written request from Lessee, Lessor may extend the 180-day timeline to the extent reasonably necessary due to conditions beyond the control of Lessee.
Removal of Improvements Grantor shall not demolish or remove any Improvements from the Real Property without Lender's prior written consent. As a condition to the removal of any Improvements, Lender may require Grantor to make arrangements satisfactory to Lender to replace such Improvements with Improvements of at least equal value.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
RELOCATION OF TENANT Upon prior written notice to Tenant, Landlord shall have the right to relocate Tenant to new space (the “Relocation Space”) within the Project that is comparable in size, utility, and condition to the Premises, including similar Tenant Improvements. Such relocation will be effective on a date specified by Landlord in its relocation notice, which date will not be less than ninety (90) days after the date of such notice. If Landlord relocates Tenant, Landlord will reimburse Tenant for Tenant’s reasonable out-of-pocket expenses for moving Tenant’s furniture, equipment, and supplies from the Premises to the Relocation Space, and other reasonable relocation costs. Tenant shall be entitled to concurrently occupy both the Premises and Relocation Space for a period not to exceed twenty (20) days in order to effectuate its relocation in a minimally non-disruptive manner. Upon such relocation, the Relocation Space will be deemed to be the Premises and the terms of this Lease will remain in full force and effect and apply to the Relocation Space. No amendment or other instrument shall be necessary to effectuate the relocation contemplated by this Section; however, if requested by Landlord, Tenant shall execute and deliver to Landlord an appropriate amendment document within twenty (20) days after Landlord’s request therefor. If Tenant fails to execute and deliver such relocation amendment within such time period, or if Tenant fails to relocate within the time period stated in Landlord’s relocation notice to Tenant (or, if the Relocation Space is not available on the date specified in Landlord’s relocation notice, as soon thereafter as the Relocation Space becomes available and is tendered to Tenant in the condition required by this Lease), then, in addition to Landlord’s other remedies set forth in this Lease, at law and/or in equity, Landlord may terminate this Lease by notifying Tenant in writing thereof at least sixty (60) days prior to the termination date contained in Landlord’s termination notice. Landlord’s exercise of its rights as permitted by this Section shall not (a) constitute a constructive eviction, an interference with Tenant’s right of quiet enjoyment, or a disturbance of Tenant’s right to use the Premises; and (b) subject Landlord to damages, including, but not limited to, damages for loss of goodwill, business, or profits. Time is of the essence with respect to Tenant’s obligations under this Section.
