Construction In First Offer Space Tenant shall take the First Offer Space in its “as is” condition, subject to any improvement allowance granted as a component of the Fair Rental Value, and the construction of improvements in the First Offer Space shall comply with the terms of Article 8 of this Lease.
Premises Parking and Common Areas 2.1 Letting Lessor hereby leases to Lessee, and Lessee hereby leases from Lessor, the Premises, for the term, at the rental, and upon all of the terms covenants and conditions set forth in this Lease. Unless otherwise provided herein, any statement of square footage set forth in this Lease, or that may have been used in calculating rental and/or Common Area Operating Expenses, is an approximation which Lessor and Lessee agree is reasonable and the rental and Lessee's Share (as defined in Paragraph 1.6(b)) based thereon is not subject to revision whether or not the actual square footage is more or less.
Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.
Monument Signage Tenant shall have the right to have its logo listed on the monument sign for the Building (the “Monument Sign”), subject to the terms of this Section 23. The design, size and color of Tenant’s signage with Tenant’s logo to be included on the Monument Sign, and the manner in which it is attached to the Monument Sign, shall comply with all Applicable Laws and shall be subject to the reasonable approval of Landlord and any applicable governmental authorities. Landlord reserves the right to withhold consent to any signage that, in the reasonable judgment of Landlord, is not harmonious with the design standards of the Building and Monument Sign. Landlord shall have the right to require that all names or logos on the Monument Sign be of the same size and style. Tenant must obtain Landlord’s written consent to any proposed signage and lettering or logo design prior to its fabrication and installation. The location of Tenant’s logo on the Monument Sign shall be subject to Landlord’s reasonable approval. To obtain Landlord’s consent, Tenant shall submit design drawings to Landlord showing the type and sizes of all lettering; the colors, finishes and types of materials used; and (if applicable and Landlord consents in its reasonable discretion) any provisions for illumination. Although the Monument Sign will be maintained by Landlord, Tenant shall pay its proportionate share of the cost of any maintenance and repair associated with the Monument Sign. Tenant’s signage on the Monument Sign shall be designed, constructed, installed, insured, maintained, repaired and removed from the Monument Sign all at Tenant’s sole risk, cost and expense. Landlord shall be responsible for the maintenance, repair or replacement of Tenant’s signage on the Monument Sign, the cost of which shall be included in Operating Expenses. Landlord may, at any time during the Term (or any extension thereof), upon five (5) business days prior written notice to Tenant, relocate the position of Tenant’s signage on the Monument Sign (provided that if Tenant is the sole tenant on the monument sign, Landlord shall make no such relocation without Tenant’s prior written consent, which consent shall not be unreasonably withheld) without materially impairing its visibility. The cost of such relocation shall be at the cost and expense of Landlord. The rights provided in this Section 23 shall be non-transferable unless otherwise agreed by Landlord in writing in its sole discretion.
Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.
Landlord’s Notice Address The Landlord’s Notice Address set forth in Section 1.12 of the Lease is hereby deleted in its entirety and replaced with the following:
Property Insurance Building Improvements and Rental Value 9.2.1 Lessor shall obtain and keep in force a policy or policies of insurance in the name of Lessor, with loss payable to Lessor, any ground-lessor, and to any Lender insuring loss or damage to the Premises. The amount of such insurance shall be equal to the full insurable replacement cost of the Premises, as the same shall exist from time to time, or the amount required by any Lender, but in no event more than the commercially reasonable and available insurable value thereof. If the coverage is available and commercially appropriate, such policy or policies shall insure against all types of direct physical loss or damage (except the perils of flood and/or earthquake unless required by a Lender), including coverage for debris removal and the enforcement of any Applicable Requirements requiring the upgrading, demolition, reconstruction or replacement of any portion of the Premises as the result of a covered loss. Said policy or policies shall also contain an agreed valuation provision in lieu of any coinsurance clause, waiver of subrogation, and inflation guard protection causing an increase in the annual property insurance coverage amount by a factor of not less than the adjusted U.S. Department of Labor Consumer Price Index for All Urban Consumers for the city nearest to where the Premises are located. Lessee Owned Alterations and Utility Installations, Trade Fixtures, and Lessee’s personal property shall be insured by Lessee not by Lessor unless the item in question has become the property of Lessor under the terms of this Lease.
Tenants Selection of Contractors Tenant hereby agrees to the retention by Landlord of Erland Construction, Inc., on behalf of Tenant, for the construction of the Tenant Improvements ("Contractor"). Tenant further agrees that Contractor will be retained on a construction management basis at a fee equal to three and nine-tenths percent (3.9%) of the cost of Tenant Improvements. Contractor shall retain only subcontractors designated by Landlord in connection with any structural, fire sprinkler, or heating, air-conditioning or ventilation work to be performed in the Premises or for any work to be done to the Base Building or the Building Systems.
