Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Historic Preservation Subrecipient agrees to comply with the Historic Preservation requirements set forth in the National Historic Preservation Act of 1966, as amended (16 U.S.C. 470) and the procedures set forth in 36 CFR 800, Protection of Historic Properties, insofar as they apply to the performance of this Contract. In general, this requires concurrence from the State Historic Preservation Officer for all rehabilitation and demolition of historic properties that are fifty years old or older or that are included on a Federal, State, or local historic property list.
Cloud Computing State Risk and Authorization Management Program In accordance with Senate Bill 475, Acts 2021, 87th Leg., R.S., pursuant to Texas Government Code, Section 2054.0593, Contractor acknowledges and agrees that, if providing cloud computing services for System Agency, Contractor must comply with the requirements of the state risk and authorization management program and that System Agency may not enter or renew a contract with Contractor to purchase cloud computing services for the agency that are subject to the state risk and authorization management program unless Contractor demonstrates compliance with program requirements. If providing cloud computing services for System Agency that are subject to the state risk and authorization management program, Contractor certifies it will maintain program compliance and certification throughout the term of the Contract.
Monitoring and Risk Assessment of Securities Depositories Prior to the placement of any assets of the Fund with a non-U.S. Securities Depository, the Custodian: (a) shall provide to the Fund or its authorized representative an assessment of the custody risks associated with maintaining assets within such Securities Depository; and (b) shall have established a system to monitor the custody risks associated with maintaining assets with such Securities Depository on a continuing basis and to promptly notify the Fund or its Investment Adviser of any material changes in such risk. In performing its duties under this subsection, the Custodian shall use reasonable care and may rely on such reasonable sources of information as may be available including but not limited to: (i) published ratings; (ii) information supplied by a Subcustodian that is a participant in such Securities Depository; (iii) industry surveys or publications; (iv) information supplied by the depository itself, by its auditors (internal or external) or by the relevant Foreign Financial Regulatory Authority. It is acknowledged that information procured through some or all of these sources may not be independently verifiable by the Custodian and that direct access to Securities Depositories is limited under most circumstances. Accordingly, the Custodian shall not be responsible for errors or omissions in its duties hereunder provided that it has performed its monitoring and assessment duties with reasonable care. The risk assessment shall be provided to the Fund or its Investment Advisor by such means as the Custodian shall reasonably establish. Advices of material change in such assessment may be provided by the Custodian in the manner established as customary between the Fund and the Custodian for transmission of material market information.
Standard Hazard Insurance and Flood Insurance Policies (a) For each Mortgage Loan, the Master Servicer shall enforce any obligation of the Servicers under the related Servicing Agreements to maintain or cause to be maintained standard fire and casualty insurance and, where applicable, flood insurance, all in accordance with the provisions of the related Servicing Agreements. It is understood and agreed that such insurance shall be with insurers meeting the eligibility requirements set forth in the applicable Servicing Agreement and that no earthquake or other additional insurance is to be required of any Mortgagor or to be maintained on property acquired in respect of a defaulted loan, other than pursuant to such applicable laws and regulations as shall at any time be in force and as shall require such additional insurance. (b) Pursuant to Section 4.01 and 4.02, any amounts collected by the Servicers or the Master Servicer, or by any Servicer, under any insurance policies (other than amounts to be applied to the restoration or repair of the property subject to the related Mortgage or released to the Mortgagor in accordance with the applicable Servicing Agreement) shall be deposited into the Master Servicer Collection Account, subject to withdrawal pursuant to Section 4.02 and 4.03. Any cost incurred by the Master Servicer or any Servicer in maintaining any such insurance if the Mortgagor defaults in its obligation to do so shall be added to the amount owing under the Mortgage Loan where the terms of the Mortgage Loan so permit; provided, however, that the addition of any such cost shall not be taken into account for purposes of calculating the distributions to be made to Certificateholders and shall be recoverable by the Master Servicer or such Servicer pursuant to Section 4.02 and 4.03.
Standard Hazard and Flood Insurance Policies For each Mortgage Loan (other than a Cooperative Loan), the Master Servicer shall maintain, or cause to be maintained by each Servicer, standard fire and casualty insurance and, where applicable, flood insurance, all in accordance with the provisions of this Agreement and the related Servicing Agreement, as applicable. It is understood and agreed that such insurance shall be with insurers meeting the eligibility requirements set forth in the applicable Servicing Agreement and that no earthquake or other additional insurance is to be required of any Mortgagor or to be maintained on property acquired in respect of a defaulted loan, other than pursuant to such applicable laws and regulations as shall at any time be in force and as shall require such additional insurance. Pursuant to Section 4.01, any amounts collected by the Master Servicer, or by any Servicer, under any insurance policies maintained pursuant to this Section 9.16 or any Servicing Agreement (other than amounts to be applied to the restoration or repair of the property subject to the related Mortgage or released to the Mortgagor in accordance with the applicable Servicing Agreement) shall be deposited into the Collection Account, subject to withdrawal pursuant to Section 4.02. Any cost incurred by the Master Servicer or any Servicer in maintaining any such insurance if the Mortgagor defaults in its obligation to do so shall be added to the amount owing under the Mortgage Loan where the terms of the Mortgage Loan so permit; provided, however, that the addition of any such cost shall not be taken into account for purposes of calculating the distributions to be made to Certificateholders and shall be recoverable by the Master Servicer or such Servicer pursuant to Section 4.02.
Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.
Maintenance of Hazard Insurance; Maintenance of Primary Insurance Policies (a) The Master Servicer shall maintain, for each Mortgage Loan, hazard insurance with extended coverage in an amount that is at least equal to the lesser of (i) the maximum insurable value of the improvements securing the Mortgage Loan and (ii) the greater of (y) the outstanding principal balance of the Mortgage Loan and (z) an amount such that the proceeds of the policy are sufficient to prevent the Mortgagor or the mortgagee from becoming a co-insurer. Each policy of standard hazard insurance shall contain, or have an accompanying endorsement that contains, a standard mortgagee clause. Any amounts collected under the policies (other than the amounts to be applied to the restoration or repair of the related Mortgaged Property or amounts released to the Mortgagor in accordance with the Master Servicer's normal servicing procedures) shall be deposited in the Certificate Account. Any cost incurred in maintaining any insurance shall not, for the purpose of calculating monthly distributions to the Certificateholders or remittances to the Trustee for their benefit, be added to the principal balance of the Mortgage Loan, notwithstanding that the Mortgage Loan so permits. Such costs shall be recoverable by the Master Servicer out of late payments by the related Mortgagor or out of Liquidation Proceeds to the extent permitted by Section 3.09. No earthquake or other additional insurance is to be required of any Mortgagor or maintained on property acquired in respect of a Mortgage other than pursuant to any applicable laws and regulations in force that require additional insurance. If the Mortgaged Property is located at the time of origination of the Mortgage Loan in a federally designated special flood hazard area and the area is participating in the national flood insurance program, the Master Servicer shall maintain flood insurance for the Mortgage Loan. The flood insurance shall be in an amount equal to the least of (i) the original principal balance of the related Mortgage Loan, (ii) the replacement value of the improvements that are part of the Mortgaged Property, and (iii) the maximum amount of flood insurance available for the related Mortgaged Property under the national flood insurance program. If the Master Servicer obtains and maintains a blanket policy insuring against hazard losses on all of the Mortgage Loans, it shall have satisfied its obligations in the first sentence of this Section 3.10. The policy may contain a deductible clause on terms substantially equivalent to those commercially available and maintained by comparable servicers. If the policy contains a deductible clause and a policy complying with the first sentence of this Section 3.10 has not been maintained on the related Mortgaged Property, and if a loss that would have been covered by the required policy occurs, the Master Servicer shall deposit in the Certificate Account, without any right of reimbursement, the amount not otherwise payable under the blanket policy because of the deductible clause. In connection with its activities as Master Servicer of the Mortgage Loans, the Master Servicer agrees to present, on behalf of itself, the Depositor, and the Trustee for the benefit of the Certificateholders, claims under any blanket policy. (b) The Master Servicer shall not take any action that would result in non-coverage under any applicable Primary Insurance Policy of any loss that, but for the actions of the Master Servicer, would have been covered thereunder. The Master Servicer shall not cancel or refuse to renew any Primary Insurance Policy that is in effect at the date of the initial issuance of the Certificates and is required to be kept in force hereunder unless the replacement Primary Insurance Policy for the canceled or non-renewed policy is maintained with a Qualified Insurer. The Master Servicer need not maintain any Primary Insurance Policy if maintaining the Primary Insurance Policy is prohibited by applicable law. The Master Servicer agrees, to the extent permitted by applicable law, to effect the timely payment of the premiums on each Primary Insurance Policy, and any costs not otherwise recoverable shall be recoverable by the Master Servicer from the related liquidation proceeds. In connection with its activities as Master Servicer of the Mortgage Loans, the Master Servicer agrees to present, on behalf of itself, the Trustee and the Certificateholders, claims to the insurer under any Primary Insurance Policies and, in this regard, to take any reasonable action in accordance with the Servicing Standard necessary to permit recovery under any Primary Insurance Policies respecting defaulted Mortgage Loans. Any amounts collected by the Master Servicer under any Primary Insurance Policies shall be deposited in the Certificate Account or the Collection Account (as applicable).
OFFICE OF MANAGEMENT AND BUDGET (OMB) AUDIT REQUIREMENTS The parties shall comply with the requirements of the Single Audit Act of 1984, P.L. 98-502, ensuring that the single audit report includes the coverage stipulated in 2 CFR 200.
