Partial Disposal During Term of Service Agreement Throughout the Term of the Service Agreement, LEA may request partial disposal of Student Data obtained under the Service Agreement that is no longer needed. Partial disposal of data shall be subject to LEA’s request to transfer data to a separate account, pursuant to Article II, section 3, above.
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
(ii) Notwithstanding anything to the contrary contained in this Agreement, in the event of default by the Contractor in discharging the obligations specified in Clause 10.4 (i) above, the Authority shall get these maintenance works completed in the manner recommended by the Authority’s Engineer to avoid public inconvenience at the risk and cost of the Contractor in order to keep the road in traffic worthy condition.
Landlords Right to Cure Default Payments by Tenant All covenants and agreements to be kept or performed by Tenant under this Lease shall be performed by Tenant at Tenant’s sole cost and expense and without any reduction of rent. If Tenant shall fail to perform any of its obligations under this Lease, within a reasonable time after such performance is required by the terms of this Lease, Landlord may, but shall not be obligated to, after three (3) days prior written notice to Tenant, make any such payment or perform any such act on Tenant’s behalf without waiving its rights based upon any default of Tenant and without releasing Tenant from any obligations hereunder. Tenant shall pay to Landlord, within ten (10) days after delivery by Landlord to Tenant of statements therefore, an amount equal to the expenditures reasonably made by Landlord in connection with the remedying by Landlord of Tenant’s defaults pursuant to the provisions of this Section 14.
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant of this Tenant Work Letter or the Lease has occurred at any time on or before the Substantial Completion of the Premises and remains after the expiration of applicable notice and cure periods, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to cause the Contractor to suspend the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 4.2 above), and (ii) all other obligations of Landlord under the terms of this Tenant Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to a default by Tenant as described in Section 19.1 of the Lease or under this Tenant Work Letter, in addition to any other remedies available to Landlord under the Lease, at law and/or in equity, Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) business days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Allocations During the Early Amortization Period During the Early Amortization Period, an amount equal to the product of (A) the Principal Allocation Percentage and (B) the Series 1997-1 Allocation Percentage and (C) the aggregate amount of Collections of Principal Receivables deposited in the Collection Account on such Deposit Date, shall be allocated to the Series 1997-1 Certificateholders and retained in the Collection Account until applied as provided herein; provided, however, that after the date on which an amount of such Collections equal to the Adjusted Invested Amount has been deposited into the Collection Account and allocated to the Series 1997-1 Certificateholders, such amount shall be first, if any other Principal Sharing Series is outstanding and in its amortization period or accumulation period, retained in the Collection Account for application, to the extent necessary, as Shared Principal Collections on the related Distribution Date, and second paid to the Holders of the Transferor Certificates only if the Transferor Amount on such date is greater than the Required Transferor Amount (after giving effect to all Principal Receivables transferred to the Trust on such day) and otherwise shall be deposited in the Special Funding Account.
Warranty Period Except as may be otherwise specified or agreed, Contractor shall repair all defects in materials, equipment, or workmanship appearing within one year from the date of Substantial Completion of the Work. If Substantial Completion occurs by phase, then the warranty period for that the Work performed for each phase begins on the date of Substantial Completion of that phase, or as otherwise stipulated on the Certificate of Substantial Completion for the particular phase.
Lessor's Default It shall be a breach of this Lease if Lessor fails to observe or perform any term, covenant or condition of this Lease on its part to be performed and such failure continues for a period of 30 days after Notice thereof from Lessee, unless such failure cannot with due diligence be cured within a period of 30 days, in which case such failure shall not be deemed a breach if Lessor proceeds within such 30-day period, with due diligence, to cure the failure and thereafter diligently completes the curing thereof. The time within which Lessor shall be obligated to cure any such failure also shall be subject to extension of time due to the occurrence of any Unavoidable Delay. If Lessor does not cure any such failure within the applicable time period as aforesaid, Lessee may declare the existence of a "Lessor Default" by a second Notice to Lessor. Thereafter, Lessee may forthwith cure the same in accordance with the provisions of Article 32, subject to the provisions of the following paragraph. Lessee shall have no right to terminate this Lease for any Lessor Default and no right, for any such Lessor Default, to offset or counterclaim against any Rent or other charges due hereunder. If Lessor shall in good faith dispute the occurrence of any Lessor Default and Lessor, before the expiration of the applicable cure period, shall give Notice thereof to Lessee, setting forth, in reasonable detail, the basis therefor, no Lessor Default shall be deemed to have occurred and Lessor shall have no obligation with respect thereto until final adverse determination thereof, whether through arbitration or otherwise; provided, however, that in the event of any such adverse determination, Lessor shall pay to Lessee interest on any disputed funds at the Base Rate, from the date demand for such funds was made by Lessee until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. If Lessee and Lessor shall fail, in good faith, to resolve any such dispute within ten (10) days after Lessor's Notice of dispute, either may submit the matter for determination by arbitration, but only if such matter is required to be submitted to arbitration pursuant to any provision of this Lease, or otherwise by a court of competent jurisdiction.
Lessor's Remedies on Default If Lessee defaults in the payment of rent or defaults in the performance of any of the other covenants or conditions hereof, Lessor may give Lessee notice of such default and if Lessee does not cure any such default within thirty (30) days after the giving of such notice (or if the default is of a nature that it cannot be completely cured within such period, if Lessee does not commence such cure within such thirty (30) days and thereafter proceed with reasonable diligence and in good faith to cure such default), then Lessor may terminate this Lease on not less than thirty (30) days' notice to Lessee. On the date specified in such notice, the term of this Lease shall terminate and Lessee shall then quit and surrender the Premises to Lessor, without extinguishing Lessee’s liability. If this Lease shall have been so terminated by Lessor, Lessor may at any time thereafter resume possession of the Premises by any lawful means and remove Lessee or other occupants and their effects.
Withdrawals during Concession Period 27.3.1 The Concessionaire shall, at the time of opening the Escrow Account, give irrevocable instructions, by way of an Escrow Agreement, to the Escrow Bank instructing, inter alia, that deposits in the Escrow Account shall be appropriated in the following order every month, or at shorter intervals as necessary, and if not due in a month then appropriated proportionately in such month and retained in the Escrow Account and paid out therefrom in the month when due:
(a) all taxes due and payable by the Concessionaire for and in respect of the Project;
(b) all payments relating to construction of the Project, subject to and in accordance with the conditions, if any, set forth in the Financing Agreements;
(c) O&M Expenses, subject to the ceiling, if any, set forth in the Financing Agreements;
(d) O&M Expenses and other costs and expenses incurred by the Authority in accordance with the provisions of this Agreement, and certified by the Authority as due and payable to it;
(e) Concession Fee or Annual Concession Fee, as the case may be, due and payable to the Authority;
(f) monthly proportionate provision of Debt Service due in an Accounting Year;
(g) all payments and Damages certified by the Authority as due and payable to it by the Concessionaire;
(h) monthly proportionate provision of debt service payments due in an Accounting Year in respect of Subordinated Debt;
(i) any reserve requirements set forth in the Financing Agreements; and
(j) balance, if any, in accordance with the instructions of the Concessionaire.
27.3.2 The Concessionaire shall not in any manner modify the order of payment specified in Clause 27.3.1, except with the prior written approval of the Authority.
Landlord’s Right to Cure Defaults Landlord may, but shall not be obligated to, cure, at any time, without notice, any default by Tenant under this Lease; and whenever Landlord so elects, all costs and expenses incurred by Landlord, including reasonable attorneys’ fees, in curing a default shall be paid, as Additional Rent, by Tenant to Landlord on demand, together with lawful interest thereon from the date of payment by Landlord to the date of payment by Tenant.
