Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
REQUIRED FOR PART 2 JOC - PRICING OF Regular Hours Coefficient What is your regular hours coefficient for the RS Means Price Book? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION)
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Escrow Format Specification Deposit’s Format. Registry objects, such as domains, contacts, name servers, registrars, etc. will be compiled into a file constructed as described in draft-xxxxx-xxxxxxx-registry-data-escrow, see Part A, Section 9, reference 1 of this Specification and draft-xxxxx-xxxxxxx-dnrd-objects-mapping, see Part A, Section 9, reference 2 of this Specification (collectively, the “DNDE Specification”). The DNDE Specification describes some elements as optional; Registry Operator will include those elements in the Deposits if they are available. If not already an RFC, Registry Operator will use the most recent draft version of the DNDE Specification available at the Effective Date. Registry Operator may at its election use newer versions of the DNDE Specification after the Effective Date. Once the DNDE Specification is published as an RFC, Registry Operator will implement that version of the DNDE Specification, no later than one hundred eighty (180) calendar days after. UTF-8 character encoding will be used.
Equipment Specifications All equipment must meet the contract specifications and all federal and State safety codes and regulations in effect at the date of manufacture. All equipment must be Original Equipment Manufacturer (OEM) equipment unless otherwise stated in the contract. All products, materials, supplies, replacement parts, and equipment offered and furnished must be new, of current manufacturer production, and must have been formally announced by the manufacturer as being commercially available, unless otherwise stated in this Contract.
JOC - PRICING OF Regular Hours Coefficient What is your regular hours coefficient for the RS Means Price Book? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION)
ODUF Packing Specifications 6.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Tax Matters Partner; Tax Elections; Special Basis Adjustments (a) The General Partner shall be the Tax Matters Partner of the Partnership within the meaning of Section 6231(a)(7) of the Code. As Tax Matters Partner, the General Partner shall have the right and obligation to take all actions authorized and required, respectively, by the Code for the Tax Matters Partner. The General Partner shall have the right to retain professional assistance in respect of any audit of the Partnership by the Service and all out-of-pocket expenses and fees incurred by the General Partner on behalf of the Partnership as Tax Matters Partner shall constitute Partnership expenses. In the event the General Partner receives notice of a final Partnership adjustment under Section 6223(a)(2) of the Code, the General Partner shall either (i) file a court petition for judicial review of such final adjustment within the period provided under Section 6226(a) of the Code, a copy of which petition shall be mailed to all Limited Partners on the date such petition is filed, or (ii) mail a written notice to all Limited Partners, within such period, that describes the General Partner’s reasons for determining not to file such a petition.
(b) All elections required or permitted to be made by the Partnership under the Code or any applicable state or local tax law shall be made by the General Partner in its sole and absolute discretion.
(c) In the event of a transfer of all or any part of the Partnership Interest of any Partner, the Partnership, at the option of the General Partner, may elect pursuant to Section 754 of the Code to adjust the basis of the Partnership’s assets. Notwithstanding anything contained in Article 5 of this Agreement, any adjustments made pursuant to Section 754 of the Code shall affect only the successor in interest to the transferring Partner and in no event shall be taken into account in establishing, maintaining or computing Capital Accounts for the other Partners for any purpose under this Agreement. Each Partner will furnish the Partnership with all information necessary to give effect to such election.
