Referral Procedures For Local Unions now having a job referral system as contained in their Collective Bargaining Agreement, the Contractor agrees to utilize such system and it shall be used exclusively by such Contractor, except as it may be modified by this Article. Referrals shall not be affected by obligations of Union membership or the lack thereof. Where airport security clearance requirements apply to work to be performed, the Contractor shall inform the Union’s hiring hall dispatcher of those requirements when requesting workers. For those Local Unions having a Book system as part of their Collective Bargaining Agreement, such system will be honored in regards to lay-off of workers from covered projects.
Section 2. In the event that Local Unions are unable to fill any request for employees within the time specified by the local CBAs the Contractor may employ applicants from any other available source. The Contractor shall inform the Union of the name and social security number of any applicants hired from other sources and shall refer the applicant to the Local Union for dispatch to the Covered Project prior to the commencement of work, and make trust fund contributions for every hour worked.
Section 3. There shall be no discrimination against any employee or applicant for employment because of his/her membership or non-membership in the Union or based upon race, creed, color, sex, age or national origin, or any other legally protected class of such employee or applicant.
Section 4. No employee covered by this PLA shall be required to join any Union as a condition of being employed on the Covered Project; provided, however, that an employee who is a member of the referring Union at the time of the referral shall maintain that membership while employed under the PLA. All employees shall, however, be required to comply with the union security provision of the applicable Collective Bargaining Agreement, for the period during which they are performing on-site work, except as modified by this PLA. The Contractor agrees to deduct union dues or representation fees, whichever is applicable, from the pay of any employee who executes a voluntary authorization for such deductions and to remit the dues to the Union or Council. Initiation fees shall be waived for those employees who are not members of any signatory Union when they begin work on this Covered Project. The dues obligations of such employees shall be confined to that portion of union membership dues directly related to representation of workers in collective bargaining, and in enforcement of the Unions’ collective bargaining agreements. Nothing in this Section is intended to eliminate or affect the right of any employee to join the Union or the right of any union to collect full dues from its member.
Section 5. The Parties agree that where a Contractor is not party to a current Collective Bargaining Agreement with the Union having jurisdiction over the affected work, the Contractor may request by name, and the Local will honor, referral of up to a maximum of five (5) persons per each contractor (“core” employees), provided that the Contractor first demonstrate that those persons possess the following qualifications:
(1) Any license required by state or federal law for the Project work to be performed;
(2) Have worked a total of at least one thousand two hundred (1,200) hours in the construction craft during the prior two (2) years;
(3) Were on the Contractor’s active payroll for at least sixty (60) out of the ninety (90) calendar days prior to the contract award;
(4) Have the ability to perform the work safely. The Contractor may elect to hire its first “core” employee to be a xxxxxxx. After the Contractor hires his first core employee, the Union will refer to such Contractor one journeyman employee from the hiring hall out-of-work list for the affected trade or craft, then refer one of such Contractor’s “core” employees as a journeyman, and shall alternate one core employee and one employee from the out-of-work list, until such Contractor’s crew requirements are met or until such Contractor has hired five (5) “core” employees, whichever occurs first. Thereafter, all additional employees in the affected trade or craft shall be hired exclusively from the hiring hall out-of-work list(s). For the duration of the Contractor’s work the ratio of “core” employees to hiring hall referrals shall be maintained and when the Contractor’s workforce is reduced, employees shall be reduced in the same ratio as was applied in the initial hiring. All employees, core and union, shall be dispatched from the appropriate union. Trust benefits shall be paid on all employees, core and union.
Section 6. Upon referral or dispatch from a Union, “turnaround” or refusal of any worker by the Contractors, requires written explanation from the Contractor that shall be communicated through the Prime Contractor to the Port and affected Union within 48 hours.
Section 7. Individual seniority will not be recognized or applied to employees working on the Project. This provision will not interfere with or supersede the use by individual Contractors of “call lists” maintained by such Contractor pursuant to addenda to the local Collective Bargaining Agreement between such Contractor and a Union signatory to this PLA.
Section 8. The selection of craft foremen and/or general foremen and the number of such foremen and/or general foremen required shall be entirely the responsibility of the Contractor. Craft foremen shall be designated working foremen at the request of the Contractor. Craft workers covered by this PLA will, in the normal day- to-day operations, take their direction and supervision from their xxxxxxx.
Referral Procedure Section 4.01 In the interest of maintaining an efficient system of production in the Industry, providing for an orderly procedure of referral of applicants for employment, preserving the legitimate interests of the employees in their employment status within the area and of eliminating discrimination in employment because of membership or non-membership in the Union, the parties hereto agree to the following system of referral of applicants for employment.
Section 4.02 The Union shall be the sole and exclusive source of referral of applicants for employment.
Section 4.03 The Employer shall have the right to reject any applicant for employment.
Section 4.04 The Union shall select and refer applicants for employment without discrimination against such applicants by reason of membership or non-membership in the Union and such selection and referral shall not be affected in any way by rules, regulations, by-laws, constitutional provisions or any other aspect or obligation of Union membership policies or requirements. All such selection and referral shall be in accord with the following procedure.
Section 4.05 The Union shall maintain a register of applicants for employment established on the basis of the Classifications and Groups listed below. Each applicant for employment shall be registered in the highest priority Group in the classification or classifications for which he qualifies. GROUP - I. All applicants for employment who have three and one-half (3 1/2) or more years’ experience in the trade, are residents of the geographical area constituting the normal construction labor market, have passed a Journeyman Lineman's examination given by a duly constituted Outside Construction Local Union of the IBEW or have been certified as a Journeyman Lineman by any Outside Joint Apprenticeship and Training Committee, and who have been employed in the trade for a period of at least one (1) year in the last three and one-half (3 1/2) years in the geographical area covered by the collective bargaining agreement. Group I status shall be limited to one Local Union at one time. An applicant who qualifies for Group I in a local union shall be so registered electronically and remain on Group I in that local union unless and until the applicant designates another local union as his or her Group I local union. If an applicant qualifies for Group I status in a local union other than his or her home local union and designates that local as his or her Group I local union, the business manager of the new group 1 status local union shall by electronic means notify the business manager of the applicant’s former Group I status local union.
Access to PHI Business Associate shall provide access to PHI in a Designated Record Set to Covered Entity or as directed by Covered Entity to an Individual to meet the requirements under 45 CFR § 164.524. Business Associate shall provide such access in the time and manner reasonably designated by Covered Entity. Within three (3) business days, Business Associate shall forward to Covered Entity for handling any request for access to PHI that Business Associate directly receives from an Individual.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action.
B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities.
C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients.
D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel.
E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation.
F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Medical Procedures 21.01 The Board shall distribute a copy of its Operating Procedures for administration of prescribed medication to pupils in schools and Procedures for health support services to each Teacher.
21.02 In accordance with Operating Procedure Special Education Services 8, a Teacher may refuse without prejudice a request to administer medications except in life-threatening situations.
Access to Services Subject to and in accordance with the terms of this Agreement, including any Schedules, Company grants You a non-exclusive, non-sublicensable, nontransferable, non-assignable, revocable license for the term of this Agreement to access and use the Services. Services may only be used by Your Users for internal business purposes only. You agree to comply with the terms and conditions of this Agreement, including any Schedules, and with all applicable Company procedures and policies that further define use of the Services. You acknowledge and agree that the actions of any of Your Users with respect to the Services will be deemed to be actions by You and that any breach by any of Your Users of the terms of this Agreement, including any Schedule, will be deemed to be a breach by You.
Services to Other Clients; Certain Affiliated Activities (a) The relationship between the Asset Manager and the Series is as described in this Agreement and nothing in this Agreement, none of the services to be provided pursuant to this Agreement, nor any other matter, shall oblige the Asset Manager to accept responsibilities that are more extensive than those set forth in this Agreement.
(b) The Asset Manager’s services to the Series are not exclusive. The Asset Manager may engage in other activities on behalf of itself, any other Managing Party and other clients (which, for the avoidance of doubt, may include other series of the Company). The Series acknowledges and agrees that the Asset Manager may, without prior notice to the Series, give advice to such other clients. The Asset Manager shall not be liable to account to the Series for any profits, commission or remuneration made or received in respect of transactions effected pursuant to the Asset Manager’s advice to another client and nor will the Asset Manager’s fees be abated as a result.
Routing for Operator Services and Directory Assistance Traffic For a Verizon Telecommunications Service dial tone line purchased by VarTec for resale pursuant to the Resale Attachment, upon request by VarTec, Verizon will establish an arrangement that will permit VarTec to route the VarTec Customer’s calls for operator and directory assistance services to a provider of operator and directory assistance services selected by VarTec. Verizon will provide this routing arrangement in accordance with, but only to the extent required by, Applicable Law. Verizon will provide this routing arrangement pursuant to an appropriate written request submitted by VarTec and a mutually agreed-upon schedule. This routing arrangement will be implemented at VarTec's expense, with charges determined on an individual case basis. In addition to charges for initially establishing the routing arrangement, VarTec will be responsible for ongoing monthly and/or usage charges for the routing arrangement. VarTec shall arrange, at its own expense, the trunking and other facilities required to transport traffic to VarTec’s selected provider of operator and directory assistance services.
Customer Service, Dispute Resolution If you have a question about your XOOM charges or service you may contact XOOM directly by calling 0-000-000-0000 Monday – Friday 8 (eight) a.m. to 11 (eleven)p.m.
Hosting Services NCR Voyix shall furnish facilities, equipment, computer programs and services, as specified from time to time by NCR Voyix, that NCR Voyix deems necessary for operation and maintenance of the System (collectively, the “Hosting Services”).