Term Extension It is understood and agreed that the State may extend the Term an additional period of time, not to exceed one hundred-eighty (180) days beyond the expiration date of this Grant Contract, under the same terms and conditions. In no event, however, shall the maximum Term, including all extensions or renewals, exceed a total of sixty (60) months.
Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.
Territorial Extension At the time of signature of this Agreement, or at any time thereafter, the provisions of this Agreement may be extended to such territories for whose international relations the Government of the United Kingdom are responsible as may be agreed between the Contracting Parties in an Exchange of Notes.
Renewal, Extension The renewal or extension of any Letter of Credit shall, for purposes hereof, be treated in all respects the same as the issuance of a new Letter of Credit hereunder.
Patent Extensions Subject to the remainder of this Section 6.6, if any election for patent term restoration or extension, supplemental protection certificate or any of their equivalents may be made with respect to any Patent within the Licensed IP, after consultation with Celgene, the Parties will discuss and seek to reach mutual agreement whether or not to take such action. If the Parties are not able to reach mutual agreement, (a) Celgene will have the sole right to make the final decision whether or not to seek such patent term restoration or extension, supplemental protection certificate or any of their equivalents with respect to Specific Patents and Patents within the Collaboration IP licensed to Celgene hereunder and (b) Bluebird will have the sole right to make the final decision whether or not to seek such patent term restoration or extension, supplemental protection certificate or any of their equivalents with respect to all other Patents within the Licensed IP.
Modification, Extension The issuance of any supplement, modification, amendment, renewal, or extension to any Letter of Credit shall, for purposes hereof, be treated in all respects the same as the issuance of a new Letter of Credit hereunder.
Patent Term Extension The Parties will cooperate in selecting a patent within the Patent Rights to seek a term extension for or supplementary protection certificate under in accordance with the applicable laws of any country. Each Party agrees to execute any documents and to take any additional actions as the other Party may reasonably request in connection therewith.
Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).
Patent Term Extensions The Parties shall use reasonable efforts to obtain all available supplementary protection certificates, patent term restorations, and other extensions (collectively, “Extensions”) of the Acceleron Patent Rights and Joint Patent Rights (including those available under the Xxxxx-Xxxxxx Act). Each Party shall execute such authorizations and other documents and take such other actions as may be reasonably requested by the other Party to obtain such Extensions. The Parties shall cooperate with each other in gaining Extensions wherever applicable to Acceleron Patent Rights or Joint Patent Rights. The holder of the applicable NDA may determine what Extensions of any such Patent Rights shall be made; provided that, if in any country such holder has an option to extend the patent term for only one of several patents, the first Party shall consult with the other Party before making the election. If more than one patent is eligible for such an Extension, the Parties shall select in good faith a strategy that shall maximize patent protection and commercial value for each Licensed Product. All filings for such Extensions, as determined by the holder of the applicable NDA, shall be made by the Party to whom responsibility for Prosecution of the Acceleron Patent Rights or Joint Patent Rights are assigned, and the owner of record of the applicable Patent Right shall assist with such filings; provided that, in the event that the Party to whom such responsibility is assigned elects not to file for an Extension, such Party shall (a) inform the other Party of its intention not to file, (b) grant the other Party the right to file for such Extension in the Patent Rights’ owner’s name, and (c) provide all necessary assistance in connection therewith. The Parties acknowledge and agree that (i) pursuant to the Shire Agreement, Shire and Acceleron will consult in selecting Patent Rights to extend the patent term with respect to “Licensed Products” under the Shire Agreement, and Shire shall make the decision in all countries of the world other than those of North America with respect to such “Licensed Products” under the Shire Agreement, and the filings for Extensions with respect thereto will be made by the party who is responsible for Prosecuting Patent Rights under the Shire Agreement, and, as such, Celgene’s rights under this Section 8.9 are subject to Shire’s prior rights; and (ii) Acceleron shall keep Celgene informed of all elections with respect to Extensions made pursuant to the Shire Agreement that affect Acceleron Patent Rights, and, to the extent that Shire is making any such elections, Acceleron shall use commercially reasonable efforts to cause Shire to take the actions specified by this Section 8.9 in a manner consistent with the Shire Agreement; provided that Acceleron will not be in breach of its obligations under this Section 8.9 if, after using such commercially reasonable efforts, it is unable to comply with such obligations because of actions taken or not taken by Shire.
Contract Term Extension “Contract Term Extension” means an extension of the term of this contract, at the request of Purchaser, under this Subsection. This Subsection does not obligate Contracting Officer to grant Contract Term Extension.
