REMEDIES FOR TELENORTE DELAYS Sample Clauses

REMEDIES FOR TELENORTE DELAYS. For delays caused by TeleNorte ("TeleNorte Delays"), the dates set forth in the Implementation Schedule or other schedules for Ericsson's performance shall be adjusted to later dates. The extent of adjustment shall be as many days as are required to compensate the TeleNorte Delay and the adjustment shall be based on a review of the relevant Ericsson's critical path development and deployment plans ie. planning evaluation and review technique/critical path method ("PERT/CPM" chart). Where additional expenses are incurred by Ericsson in making up for a TeleNorte Delay, Ericsson shall receive an equitable adjustment in its prices to compensate for the additional expenses. If Ericsson is unable to deliver or install Equipment of perform Services because of TeleNorte's failure to satisfy its obligations under this Agreement, then TeleNorte shall (i) furnish suitable temporary storage facilities for such Equipment and reimburse Ericsson for all reasonable cost and out-of-pocket expenses actually incurred by Ericsson attributable to TeleNorte's failure to have the Sites ready and available for the commencement of installation including cost (a) to store such Equipment (including the costs of transporting such Equipment to and from Ericsson's storage facilities if TeleNorte fails to furnish suitable temporary facilities and (b) to redeploy Ericsson's workforce. For the avoidance of doubt, a "TeleNorte Delay" includes but is not limited to any delay resulting from TeleNorte's delay in obtaining interconnection with the PSTN.
Sample 1
AutoNDA by SimpleDocs

Related to REMEDIES FOR TELENORTE DELAYS

  • Remedies for Default (a) Enterprise Services’ rights to suspend and terminate Contractor’s rights under this Master Contract are in addition to all other available remedies. (b) In the event of termination for default, Enterprise Services may exercise any remedy provided by law including, without limitation, the right to procure for all Purchasers replacement goods and/or services. In such event, Contractor shall be liable to Enterprise Services for damages as authorized by law including, but not limited to, any price difference between the Master Contract price and the replacement or cover price as well as any administrative and/or transaction costs directly related to such replacement procurement – e.g., the cost of the competitive procurement.

  • Remedies for Non-Compliance The Recipient agrees that if FTA determines that the Recipient or a Third Party Participant receiving federal assistance under 49 U.S.C. chapter 53 is not in compliance with 49 C.F.R. part 655, the Federal Transit Administrator may bar that Recipient or Third Party Participant from receiving all or a portion of the federal transit assistance for public transportation it would otherwise receive.

  • Remedies for Noncompliance In the event Contractor fails to fulfill its obligations under this Section 21, the Authority shall have available to it appropriate remedies at law or in equity, including the right to withhold amounts due to Contractor for any work until Contractor submits a corrective action plan which has been approved by the Authority or demonstrates to the Authority’s satisfaction that all good faith efforts to comply with the goals set forth herein have been exhausted, together with the ability to disqualify Contractor from future work that may, from time to time, be undertaken by the Authority as well as all unfinished work under this Contract.

  • Remedies for Contractor Breach Pertaining to contract-related issues, it is the responsibility of both CMHA and the contractor to communicate with each other in as clear and complete a manner as possible. If at any time during the term of this contract CMHA or the contractor is not satisfied with any issue, it is the responsibility of that party to deliver to the other party communication, in writing, fully detailing the issue and corrective action (please note that CMHA has the right to issue unilateral addendums to this contract, but the contractor does not have the same right). The other party shall, within 10 days, respond in writing to the other party (however, CMHA shall retain the right to, if conditions warrant, require the contractor to respond in a shorter period of time). Further, CMHA shall, at a minimum, employ the following steps in dealing with the contractor as to any performance issues: 20.16.1.1. If the contractor is in material breach of the contract, CMHA may promptly invoke the termination clause detailed within Section No. 3, form HUD-5370-C, General Conditions for Non-Construction Contracts, Section I—(With or without Maintenance Work), which is attached hereto, and terminate the contract for cause. Such termination must be delivered to the contractor in writing and shall fully detail all pertinent issues pertaining to the cause of and justification for the termination. 20.16.1.2. Prior to termination, CMHA may choose to warn 20.16.1.3. After termination, if the contractor does not agree with CMHA’s justification for the termination, the contractor shall have 10 days to dispute, in writing, such action; if he/she does not do so within the 10-day period, he/she shall have no recourse but to accept and agree with CMHA’s position on the issue. The written protest must detail all pertinent information pertaining to the dispute, including justification detailing CMHA’s alleged incorrect action(s). 20.16.1.4. The response to any protest received shall be conducted in accordance with Section No. 4.0 of this document. 20.16.1.5. It is CMHA’s policy to resolve all contractual issues informally and without litigation. Disputes will not be referred to HUD unless all administrative remedies have been exhausted. When appropriate, a mediator may be used to help resolve differences. 20.16.1.6. For contracts of $100,000 or less, the bidder/contractor may request to meet with the Procurement Officer. 20.16.1.7. All claims by a contractor relating to performance of a contract shall be submitted in writing to the Procurement Officer or designee for a written decision. The contractor may request a conference on the claim. The Procurement Officer’s decision shall inform the contractor of its appeal rights to the next higher level of authority in CMHA. Contractor claims shall be governed by the Changes clause in the form HUD-5370-C.

  • Remedies for Events of Default If an Event of Default, as defined in the Indenture, occurs and is continuing, the Trustee or the Holders of not less than 25% in principal amount of the Notes then outstanding may declare all the Notes to be immediately due and payable. If a bankruptcy or insolvency default with respect to the Company or any of its Significant Subsidiaries occurs and is continuing, the Notes automatically become immediately due and payable. Holders may not enforce the Indenture or the Notes except as provided in the Indenture. The Trustee may require indemnity satisfactory to it before it enforces the Indenture or the Notes. Subject to certain limitations, Holders of at least a majority in principal amount of the Notes then outstanding may direct the Trustee in its exercise of any trust or power.

  • Remedies for Environmental Defects (a) If any Environmental Defect described in a notice delivered in accordance with Section 4.03 is not cured on or before the Closing, and Seller has not elected to exclude the affected Assets from this sale or Buyer and Seller have not agreed for Seller to indemnify Buyer for the Environmental Defect, then the Purchase Price shall be reduced by the Environmental Defect Value of such Environmental Defect as agreed by the Parties. (b) If Buyer and Seller have not agreed as to the validity of any asserted Environmental Defect, or if the Parties have not agreed on the Environmental Defect Value therefor, and if Seller shall not have elected to exclude the affected Assets from this sale pursuant to Section 4.03(b)(ii), then either Party shall have the right to elect to have the validity of the asserted Environmental Defect, and/or the Environmental Defect Value for such Environmental Defect, determined by an Independent Expert pursuant to Section 16.03. If the validity of any such asserted Environmental Defect or the amount of any such Environmental Defect Value is not determined by the Closing, the Asset affected by such disputed Environmental Defect shall be excluded from the Closing and the Purchase Price paid at the Closing shall be reduced by the Allocated Value of that Asset. Upon resolution of such dispute, the Allocated Value of that Asset less the Environmental Defect Value, if any, found to be attributable to such Environmental Defect shall, subject to this Section 4.04, be paid by Buyer to Seller and the Asset conveyed to Buyer, if that is part of the mutually agreed settlement. Notwithstanding the foregoing, either Buyer or Seller shall have the right to exclude an Asset from the sale if the Environmental Defect Value exceeds the Allocated Value of the Asset(s) affected thereby. (c) Notwithstanding anything to the contrary in this Agreement, (i) if the Environmental Defect Value for a given individual Environmental Defect does not exceed $50,000, then no adjustment to the Purchase Price shall be made for such Environmental Defect; (ii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects does not exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then no adjustment of the Purchase Price shall be made therefore and (iii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects does exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then the Purchase Price shall only be adjusted by the amount of such excess.

  • Tenant’s Remedies/Limitation of Liability Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlord’s obligations hereunder. All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term “Landlord” in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owner’s ownership.

  • REMEDIES, ETC CUMULATIVE. Each and every right, power and remedy of the Pledgee provided for in this Agreement or in any other Secured Debt Agreement, or now or hereafter existing at law or in equity or by statute shall be cumulative and concurrent and shall be in addition to every other such right, power or remedy. The exercise or beginning of the exercise by the Pledgee or any other Secured Creditor of any one or more of the rights, powers or remedies provided for in this Agreement or any other Secured Debt Agreement or now or hereafter existing at law or in equity or by statute or otherwise shall not preclude the simultaneous or later exercise by the Pledgee or any other Secured Creditor of all such other rights, powers or remedies, and no failure or delay on the part of the Pledgee or any other Secured Creditor to exercise any such right, power or remedy shall operate as a waiver thereof. No notice to or demand on any Pledgor in any case shall entitle it to any other or further notice or demand in similar or other circumstances or constitute a waiver of any of the rights of the Pledgee or any other Secured Creditor to any other or further action in any circumstances without notice or demand. The Secured Creditors agree that this Agreement may be enforced only by the action of the Pledgee, in each case acting upon the instructions of the Required Lenders (or, after the date on which all Credit Document Obligations have been paid in full, the holders of at least a majority of the outstanding Other Obligations) and that no other Secured Creditor shall have any right individually to seek to enforce or to enforce this Agreement or to realize upon the security to be granted hereby, it being understood and agreed that such rights and remedies may be exercised by the Pledgee for the benefit of the Secured Creditors upon the terms of this Agreement.

  • Remedies for Title Defects (a) With respect to each Title Defect that Seller does not cure on or before the Closing, except as otherwise provided in this Section 3.05, the Purchase Price shall be reduced by an amount equal to the Title Defect Value agreed upon in writing by Buyer and Seller or, if Buyer agrees, Seller shall indemnify Buyer pursuant to Section 14.04 against all costs which Buyer may incur in connection with such Title Defect. If any Title Defect is in the nature of an unobtained consent to assignment or other restriction on assignability, the provisions of Section 3.08 shall apply. (b) Except for those affected Assets which Seller elects to exclude from this transaction pursuant to Section 3.04(b)(ii), if on or before Closing the Parties have not agreed upon the validity of any asserted Title Defect or have not agreed on the Title Defect Value attributable thereto, either Party shall have the right to elect to have the validity of such Title Defect and/or such Title Defect Value determined by an Independent Expert pursuant to Section 16.03; provided that if the validity of any asserted Title Defect, or the Title Defect Value attributable thereto, is not determined before Closing, the affected Asset shall be excluded from the sale and the Purchase Price shall be reduced by the Allocated Value of such affected Asset as set forth on Exhibit C. Upon resolution of such dispute, the Allocated Value of that Asset less the Title Defect Value, if any, found to be attributable to such Title Defect shall, subject to this Section 3.05, be paid by Buyer to Seller and the Asset conveyed to Buyer, if that is part of the mutually agreed settlement. (c) Notwithstanding anything to the contrary in this Agreement, (i) if the value of a given individual Title Defect (or individual Title Benefit (as defined in Section 3.09(a)) does not exceed $50,000 then no adjustment to the Purchase Price shall be made for such Title Defect (or Title Benefit), (ii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects (as hereinafter defined) does not exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then no adjustment of the Purchase Price shall be made therefor and (iii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects does exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then the Purchase Price shall only be adjusted by the amount of such excess.

  • Remedies; Specific Performance The Company stipulates that there would be no adequate remedy at law to the Holder of this Warrant in the event of any default or threatened default by the Company in the performance of or compliance with any of the terms of this Warrant and accordingly, the Company agrees that, in addition to any other remedy to which the Holder may be entitled at law or in equity, the Holder shall be entitled to seek to compel specific performance of the obligations of the Company under this Warrant, without the posting of any bond, in accordance with the terms and conditions of this Warrant in any court of the United States or any State thereof having jurisdiction, and if any action should be brought in equity to enforce any of the provisions of this Warrant, the Company shall not raise the defense that there is an adequate remedy at law. Except as otherwise provided by law, a delay or omission by the Holder hereto in exercising any right or remedy accruing upon any such breach shall not impair the right or remedy or constitute a waiver of or acquiescence in any such breach. No remedy shall be exclusive of any other remedy. All available remedies shall be cumulative.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!