Rents Reserved Upon Contract Sample Clauses

Rents Reserved Upon Contract. In addition to the production royalty specified in Section 5.1 and the minimum royalty specified in Section 6.1 and 6.2 hereof, any and all payments which Lessee is required to make hereunder to or for the benefit of Lessor shall be deemed additional rents and royalties and considered as rents reserved by Lessor upon contract and all remedies now or hereunder given to landlords by the laws of the Commonwealth of Kentucky for collection of such rents shall exist in favor of Lessor, in addition to any rights and remedies specified herein. If any of the royalties, rentals or other payments shall remain unpaid for thirty (30) days after the same shall become due and payable, as herein provided, and thirty (30) days after notice of such default has been given to Lessee in writing, Lessor shall have the right to enforce the payment thereof by remedies given by law to landlords against delinquent tenants for non-payment of rent; and not only shall the personal property of Lessee on the Property be subject to distress as contemplated and directed by law, but Lessor may also enter upon the Property and sell the interest of Lessee hereunder, or any part thereof together with improvements thereon, for the default in the payment of the royalties, rentals, and other payments as aforesaid, and at any sale of this leasehold, or any part thereof, or of the improvements or the personal property made or placed by Lessee on said leasehold, Lessor shall have the right to become the purchaser thereof free from any and all claims of Lessee. Lessor's entitlement to royalties and minimum advance royalties shall not be impaired by Lessor's re-entry. The remedies for the collection of unpaid royalties herein provided are in addition and supplemental to all other provisions and remedies of Lessor in this Lease for the redress of defaults hereunder. The obligation of Lessee to pay royalties and rents are indivisible obligations and continuing defaults of any payments can be sued on in one cumulative action with the balance due continually accruing.
Sample 1
AutoNDA by SimpleDocs

Related to Rents Reserved Upon Contract

  • Award of Construction Contract and Other Future Contracts 6.2.1 A-E is hereby informed that provisions of the Public Contract Code, the Political Reform Act of 1974, other statutes, regulations, and COUNTY policy prohibit, as an impermissible conflict of interest, the award of a contract for the construction of the project(s) on which A-E performed architectural-engineering services under this A-E CONTRACT. A-E is hereby informed that these statutes and regulations could also prohibit the award to A-E of design or other contracts on future phases related to tasks performed by A-E under this CONTRACT. This prohibition applies also to a subcontractor of or parent company of the firm that performed architectural-engineering tasks under this CONTRACT.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • ASSIGNMENT AND SUB-CONTRACTING The benefit and burden of this Contract may not be assigned or sub-contracted in whole or in part by the Contractor without the prior written consent of the Department. Such consent may be given subject to any conditions which the Department considers necessary. The Department may withdraw its consent to any sub-contractor where it no longer has reasonable grounds to approve of the sub-contractor or the sub-contracting arrangement and where these grounds have been presented in writing to the Contractor.

  • Construction Contracts Item A: Enter the total dollar amount of all contacts awarded on the project/ program. Item B: Enter the total dollar amount of contracts connected with this project/program that were awarded to Section 3 businesses.

  • ASSIGNMENT AND SUB-LETTING Tenant shall not assign this Agreement, or sub-let or grant any license to use the Premises or any part thereof without the prior written consent of Landlord. A consent by Landlord to one such assignment, sub-letting or license shall not be deemed to be a consent to any subsequent assignment, sub-letting or license. An assignment, sub-letting or license without the prior written consent of Landlord or an assignment or sub-letting by operation of law shall be absolutely null and void and shall, at Landlord's option, terminate this Agreement.

  • Assignment of Contracts GSAM agrees to assign (or cause to be assigned) to GSRP or OpCo without recourse, representation or warranty (except as expressly set forth in this Agreement), all of GSAM’s or such Affiliate’s right, title and interest in and to, and GSRP agrees to assume, or cause OpCo to agree to assume, the obligations of GSAM or such Affiliate’s obligations under, each of the Contracts set forth on Section 6.18 of the GSRP Disclosure Letter (collectively the “Assigned Contracts”), pursuant to documentation (the “Assigned Contracts Documentation”) in form and substance consistent with this Section 6.18 and otherwise in form and substance satisfactory to the Parties. GSAM has made available, or caused to be made available, to GSRP true and correct copies of the Assigned Contacts. Except as provided below, GSAM shall remain responsible for paying and satisfying, and shall protect, defend, indemnify and hold harmless GSRP from, all Liabilities related to or arising from the Assigned Contracts, to the extent such Liabilities relate to or arise from the period prior to the Closing. GSRP shall be responsible for paying and satisfying, and shall protect, defend, indemnify and hold harmless GSAM from, all Liabilities related to or arising from the Assigned Contracts, to the extent such Liabilities relate to or arise from the period on or after the Closing. Notwithstanding the second preceding sentence, in the case of any Assigned Contract that prior to the Closing was for the benefit of the GSRP Entities, from and after the Closing GSRP shall protect, defend, indemnify and hold harmless GSAM from, all Liabilities, related to or arising from such Assigned Contract, to the extent GSRP is required to do so under the Management Agreement. Without limiting the foregoing, OpCo shall remain responsible for, and shall pay and discharge when due all Liabilities that constitute Company Expenses (as defined in the OpCo LLC Agreement) that were incurred prior to the Closing.

  • SUB-CONTRACTS (a) The Administrator may sub-contract or delegate the performance of all or any of its powers and obligations under this Agreement, provided that (but subject to Clause 3.2(b) herein): (i) the prior written consent of the Mortgages Trustee and Funding to the proposed arrangement (including, if Funding considers it necessary after consulting with the Security Trustee, approving any contract which sets out the terms on which such arrangements are to be made) has been obtained, the Security Trustee has been consulted and notification has been given to each of the Rating Agencies; (ii) where the arrangements involve the custody or control of any Mortgage Loan Files and/or Title Deeds relating to the Mortgage Portfolio for the purpose of performing any delegated Services, the sub-contractor or delegate has executed an acknowledgement in writing acceptable to Funding and the Security Trustee to the effect that any such Mortgage Loan Files and/or Title Deeds are and will be held to the order of the Mortgages Trustee (as trustee for the Beneficiaries); (iii) where the arrangements involve or may involve the receipt by the sub-contractor or delegate of monies belonging to the Beneficiaries which, in accordance with this Agreement, are to be paid into the relevant Collection Account, the sub-contractor or delegate has executed a declaration in writing acceptable to the Beneficiaries that any such monies held by it or to its order are held on trust for the Beneficiaries and will be paid forthwith into the relevant Collection Account in accordance with the terms of the Mortgages Trust Deed; (iv) any such sub-contractor or delegate has executed a written waiver of any Security Interest arising in connection with such delegated Services (to the extent that such Security Interest relates to the Mortgage Portfolio or any amount referred to in (iii) above); and (v) neither the Mortgages Trustee, the Security Trustee nor the Beneficiaries shall have any liability for any costs, charges or expenses payable to or incurred by such sub-contractor or delegate or arising from the entering into, the continuance or the termination of any such arrangement. (b) The provisos to Clause 3.2(a) (i), (ii) and (iii) herein shall not apply: (i) to the engagement by the Administrator of: (1) any receiver, solicitor, insurance broker, valuer, surveyor, accountant, estate agent, insolvency practitioner, auctioneer, bailiff, debt counsellor, tracing agent, property management agent, licensed or qualified conveyancer or other professional adviser acting as such; or (2) any locksmith, builder or other contractor acting as such in relation to a Mortgaged Property, in any such case being a person or persons whom the Administrator would be willing to appoint in respect of its own mortgages in connection with the performance by the Administrator of any of its obligations or functions or in connection with the exercise of its powers under this Agreement; or (ii) to any delegation to any wholly-owned subsidiary of the Seller from time to time. (c) The Mortgages Trustee and/or Funding and the Security Trustee may require the Administrator to assign to the Mortgages Trustee any rights which the Administrator may have against any sub-contractor or delegate arising from the performance of services by such person in association with any matter contemplated by this Agreement and the Administrator acknowledges that such rights assigned to the Mortgages Trustee will be exercised by the Mortgages Trustee as trustee for the Beneficiaries subject to the terms of the Mortgages Trust Deed. (d) Notwithstanding any sub-contracting or delegation of the performance of the Administrator's obligations under this Agreement: (i) the Administrator shall not thereby be released or discharged from any liability hereunder; (ii) the Administrator shall remain responsible for the performance of the obligations of the Administrator under this Agreement; (iii) the performance or non-performance or the manner of performance of any sub-contractor or delegate of any of the Services shall not affect the Administrator's obligations under this Agreement; (iv) any breach in the performance of the Services by any sub-contractor or delegate shall, subject to the Administrator being entitled for a period of twenty (20) Business Days from receipt of notice of the breach to remedy such breach by any sub-contractor or delegate, be treated as a breach of this Agreement by the Administrator; and (v) the Security Trustee shall have no liability for any act or omission of the sub-contractor or delegate and shall have no responsibility for monitoring or investigating the suitability of any such sub-contractor or delegate.

  • Construction of Contract Both parties have participated fully in the review and revision of this contract. Any rule of construction to the effect that ambiguities are to be resolved against the drafting party shall not apply to the interpretation of this contract.

  • Construction Contract If federal funds are included as part of the financing of the non-OPWC portion of the Project, federal law may prevail, including, but not limited to, application of Xxxxx Xxxxx prevailing wage rates, the Xxxxxxxx “Anti-Kickback” Act, the Contract Work Hours and Safety Standards Act, and any federal environmental regulations. Recipient is solely responsible for ensuring compliance with federal requirements applicable to its Local Subdivision Contribution. Notwithstanding the above, the following provisions apply to construction contracts under this Agreement:

  • Assignment of Contract A. Unless expressly agreed to elsewhere in the Contract, no assignment by a party hereto of any rights under or interests in the Contract will be binding on another party hereto without the written consent of the party sought to be bound; and, specifically but without limitation, money that may become due and money that is due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!