Damage and Destruction If all or any part of the Premises shall be damaged or destroyed by fire or other casualty, this Lease shall continue in full force and effect, unless terminated as hereinafter provided, and Landlord shall repair, restore or rebuild the Premises to the condition existing at the time of the occurrence of the loss; provided, however, Landlord shall not be obligated to commence such repair, restoration or rebuilding until insurance proceeds are received by Landlord, and Landlord’s obligation hereunder shall be limited to the proceeds actually received by Landlord under any insurance policy or policies, if any, less those amounts (i) which have been required to be applied towards the reduction of any indebtedness secured by a mortgage covering the Premises or any portion thereof, and (ii) which are used to reimburse Landlord for all costs and expenses, including but not limited to attorneys’ fees, incurred by Landlord to recover any such insurance proceeds. Tenant agrees to notify Landlord in writing not less than thirty (30) days prior, to the date Tenant opens for business in the Premises of the actual cost of all permanent leasehold improvements and betterments installed or to be installed by Tenant in the Premises (whether same have been paid for entirely or partially by Tenant), but exclusive of Tenant’s personal property, movable trade fixtures and inventory. Similar notifications shall be given to Landlord not less than thirty (30) days prior to the commencement of any proposed alterations, additions or improvements to the Premises. If Tenant fails to comply, with the foregoing provisions, any loss or damage Landlord shall sustain by reason thereof shall be borne by Tenant and shall be paid immediately by Tenant upon receipt of a xxxx therefore and evidence of such loss, and in addition to any other rights or remedies reserved by Landlord under this Lease, Landlord’s obligations under this Article to repair, replace and/or rebuild the Premises shall be deemed inapplicable, and in lieu thereof, Landlord may, at its election, either restore or require Tenant to restore the Premises to the condition which existed prior to such loss, and in either case Tenant shall pay the cost of such restoration. Tenant covenants and agrees to repair or replace Tenant’s fixtures, furniture, furnishings, floor coverings, equipment and stock in trade and reopen for business in the Premises within thirty (30) days after notice from Landlord that the Premises are ready for re-occupancy. No damage or destruction to the Premises shall allow Tenant to surrender possession of the Premises nor affect Tenant’s liability for the payment of rents or charges or any other covenant herein contained, except as may be specifically provided in this Lease. Notwithstanding anything to the contrary contained in this Section or elsewhere in this Lease, Landlord, at its option, may terminate this Lease by giving Tenant notice thereof within one hundred and eighty (180) days from the date of the casualty if:
(a) The Premises or the building in which the Premises are located shall be damaged or destroyed as a result of an occurrence which is not covered by Landlord’s insurance; or
(b) The Premises shall be damaged or destroyed during the last two (2) years of the Term or any renewals thereof; or
(c) The Premises are damaged or destroyed to the extent of twenty five-percent (25%) or more of the replacement cost thereof, in which event Landlord will have the option of terminating this Lease or any renewal thereof by serving written notice upon Tenant and any prepaid Rent or Additional Rent will be prorated as of the date of destruction and the unearned portion of such Rent will be refunded to Tenant without interest. If the Premises shall be damaged or destroyed and in the event that Landlord has elected to continue this Lease, Landlord and Tenant shall commence their respective obligations under this Article as soon as is reasonably possible and prosecute the same to completion with all due diligence. Except where the damage or destruction results from the wrongful or negligent act or omission of Tenant, the Minimum Rent shall be abated proportionately with the degree to which Tenant’s use of the Premises is impaired during the period of any damage, repair or restoration provided for in this Article; provided further, that in the event Landlord elects to repair any damages as herein contemplated, any abatement of Minimum Rent shall end ten (10) days after notice by Landlord to Tenant that the Premises have been repaired. Tenant shall continue the operation of its business on the Premises during any such period to the extent reasonably practicable from the standpoint of prudent business management, and any obligation of Tenant under the Lease to apply charges reserved as Additional Rent shall remain in full force and nothing in the Section shall be construed to xxxxx Additional Rent. Except for the abatement of Minimum Rent hereinabove provided, Tenant shall not be entitled to any compensation or damage for loss in the use of the whole or any part of the Premises and/or any inconvenience or annoyance occasioned by any damage, destruction, repair or restoration. If Minimum Rent is abated there shall be all corresponding and appropriate reduction made to the Minimum Annual Volume. Unless this Lease is terminated by Landlord, Tenant shall repair, restore and re-fixture all parts of the Premises not insured under any insurance policies insuring Landlord in a manner and to a condition equal to that existing prior to its destruction or damage, including, without limitation, all exterior signs, trade fixtures, equipment, display cases, furniture, furnishings and other installations of personality of Tenant. The proceeds of all insurance carried by Tenant on its property and improvements shall be held in trust by Tenant for the purpose of said repair and replacement. Tenant shall give to Landlord prompt written notice of, any damage to or destruction of any portion of the Premises resulting from fire or other casualty.
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement.
(b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of:
(i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or
(ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election.
(c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral.
(b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies.
(c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in
(i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
DAMAGES, DESTRUCTION AND EMINENT DOMAIN (a) If, prior to closing, the Property or any part thereof be destroyed or further damaged by fire, the elements, or any cause, due to events occurring subsequent to the date of this Agreement to the extent that the cost of repair exceeds $10,000.00, this Agreement shall become null and void, at Buyer's option exercised, if at all, by written notice to Seller within ten (10) days after Buyer has received written notice from Seller of said destruction or damage. Seller, however, shall have the right to adjust or settle any insured loss until (i) all contingencies set forth in Paragraph 6 hereof have been satisfied, or waived; and (ii) any ten-day period provided for above in this Subparagraph 16a for Buyer to elect to terminate this Agreement has expired or Buyer has, by written notice to Seller, waived Buyer's right to terminate this Agreement. If Buyer elects to proceed and to consummate the purchase despite said damage or destruction, there shall be no reduction in or abatement of the purchase price, and Seller shall assign to Buyer the Seller's right, title, and interest in and to all insurance proceeds (pro-rata in relation to the Entire Property) resulting from said damage or destruction to the extent that the same are payable with respect to damage to the Property, subject to rights of any Tenant of the Entire Property. If the cost of repair is less than $10,000.00, Buyer shall be obligated to otherwise perform hereinunder with no adjustment to the Purchase Price, reduction or abatement, and Seller shall assign Seller's right, title and interest in and to all insurance proceeds pro-rata in relation to the Entire Property, subject to rights of any Tenant of the Entire Property.
(b) If, prior to closing, the Property, or any part thereof, is taken by eminent domain, this Agreement shall become null and void, at Buyer's option. If Buyer elects to proceed and to consummate the purchase despite said taking, there shall be no reduction in, or abatement of, the purchase price, and Seller shall assign to Buyer the Seller's right, title, and interest in and to any award made, or to be made, in the condemnation proceeding pro-rata in relation to the Entire Property, subject to rights of any Tenant of the Entire Property. In the event that this Agreement is terminated by Buyer as provided above in Subparagraph 16a or 16b, the First Payment shall be immediately returned to Buyer (after execution by Buyer of such documents reasonably requested by Seller to evidence the termination hereof).
DESTRUCTION OF PREMISES (A) If, during the term of this Lease, the Leased Premises are totally or partially destroyed by fire or the elements, so as to render the premises wholly unfit for occupancy, or make it impossible in the opinion of a licensed third party arbitrator knowledgeable in the child care business reasonably acceptable to Lessee and Lessor, for Lessee to conduct its business therein, then either Lessor or Lessee shall have the right to terminate this Lease from the date of such damage or destruction by giving written notice. The parties agree to use reasonable promptness to obtain the opinion of such licensed third party arbitrator. Upon the giving of such notice, Lessee shall immediately surrender the Leased Premises and all interest therein to Lessor, and in case of any such termination, Lessor may re-enter and repossess the Leased Premises and may dispossess all parties then in possession thereof. If not otherwise terminated, in the event the Leased Premises shall be repaired, restored, and rebuilt by Lessee with the use of insurance proceeds (which Lessor shall cooperate to make available), but otherwise at its own sole cost and expense, within one hundred eighty (180) days from the date of destruction (subject to force majuere as set forth in paragraph C hereof, then all rents payable by Lessee shall be abated during the period of repair and restoration to the extent Lessor shall be compensated by the proceeds of rents loss insurance. In no event shall Lessor be required to provide its own money for the repair or restoration of the Leased Premises other than the net proceeds of moneys received by it from any insurance policy or policies covering such loss or damages. Lessee shall be liable for repair of the Leased Premises with all reasonable speed, and the rents shall recommence on the date that the repairs are completed. Lessee shall be under no obligation to so repair during the last five (5) years of the term of the Lease, or as extended, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above.
(B) If the damage does not, in the opinion of a licensed third party arbitrator reasonably acceptable to Lessee and Lessor, render the Leased Premises unfit for occupancy, then Lessor agrees that the damage shall be repaired as soon as practicable and in that case, Lessee shall pay full rent during the repair period. All repairs shall be paid for by Lessee out of any insurance proceeds received (which Lessor shall cooperate to make available), but if the insurance proceeds are insufficient to rebuild or repair the Leased Premises according to the original plans and specifications, whether repair or restoration is commenced pursuant to paragraph A or B hereof, then Lessee agrees to pay all additional amounts that are required to rebuild the building in accordance with the original plans and specifications. All improvements or betterments placed by Lessee on the demised premises shall, however, in any event, be repaired and replaced by Lessee at its own expense and not at the expense of Lessor. The purpose of this Article is to require Lessee to carry insurance coverage on the Leased Premises sufficient to rebuild the improvements in the event of damage or destruction. Lessee shall be under no obligation to so rebuild during the last five (5) years of the term, as extended, as the case may be, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above. Risk that the insurance company shall be insolvent or shall refuse to make insurance proceeds available shall be with Lessee. The Leased Premises shall be so restored or rebuilt so as to be of at least equal value and substantially the same character as prior to such damage or destruction. If the insurance proceeds are less than $100,000 they shall be paid to Lessee for such repair and restoration. If the insurance proceeds are greater than or equal to $100,000 they shall be deposited by Lessee and Lessor into a customary construction escrow at a nationally recognized title insurance company, or at Lessee's option, with Lessor ("Escrowee") and shall be made available from time to time to Lessee for such repair and restoration. Such proceeds shall be disbursed in conformity with the terms and conditions of a commercially reasonable construction loan agreement. Lessee shall, in either instance, deliver to Lessor or Escrowee (as the case may be) satisfactory evidence of the estimated cost of completion together with such architect's certificates, waivers of lien, contractor's sworn statements and other evidence of cost and of payments as the Lessor or Escrowee may reasonably require and approve. If the estimated cost of the work exceeds One Hundred Thousand Dollars ($100,000), all plans and specifications for such rebuilding or restoration shall be subject to the reasonable approval of Lessor.
(C) Lessee shall comply with the time period stated above for restoration of the Leased Premises as set forth in this Article; provided, however, that said period of time shall be extended for a period or periods of time equal to any period or periods of delay caused by strikes, lockouts, fire, or other casualty, the elements, acts of God, delay by or refusal or failure of governmental authorities to grant necessary permits and approvals for the reconstruction of the Leased Premises (Lessee agreeing to use reasonable diligence to procure the same), or other causes other than financial, beyond Lessee's reasonable control or the reasonable control of Lessee's contractor.
Cancellation and Destruction All Debentures shall forthwith after payment thereof be delivered to the Trustee and cancelled by it. All Debentures cancelled or required to be cancelled under this or any other provision of this Indenture shall be destroyed by the Trustee and, if required by the Corporation, the Trustee shall furnish to it a destruction certificate setting out the designating numbers of the Debentures so destroyed.
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Data Destruction When no longer needed, all County PHI or PI must be cleared, purged, or destroyed consistent with NIST Special Publication 800-88, Guidelines for Media Sanitization such that the PHI or PI cannot be retrieved.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
