Repairs to Premises Liens Sample Clauses

Open Split View

Download

Share

Cite

Repairs to Premises Liens 

Sample 1Sample 2Sample 3See All (4)

Save

Copy

Related to Repairs to Premises Liens

• Improvements to Premises Lessee shall take the Premises in its "as-is" condition for the Extended Term except for certain Leasehold Improvements (herein so called) to the Premises which shall be completed in accordance with the specifications attached hereto as Exhibit A (the "Approved Plans"), which have been approved by both Lessor and Lessee. Lessor shall cause the Leasehold Improvements to be installed or constructed in accordance with the Approved Plans by Lessor's contractor. So long as no Event of Default (or event which with notice or lapse of time could become an Event of Default) has occurred under the Lease, Lessor agrees to provide Lessee an allowance equal to One Hundred Fifty-Three Thousand One Hundred Nineteen and No/100 Dollars ($153,119.00) (the "Improvement Allowance"), which allowance is to be used solely for completion of the Leasehold Improvements in accordance with the Approved Plans, and an additional allowance equal to Three Thousand Two Hundred and No/100 Dollars ($3,200.00) (the "Architectural Allowance"), which allowance is to be used solely for space planning and design services for the Premises. In the event that any alterations or modifications to the Premises are required in order to comply with applicable law, including, without limitation, the Americans with Disabilities Act of 1990, as amended, or the State of Texas equivalent laws and regulations, the cost of any such alterations or modifications shall be satisfied out of the Improvement Allowance. The cost of the Leasehold Improvements and the space planning and design fees is to be paid by Lessor out of the Improvement Allowance and the Architectural Allowance, respectively. Any completed work (labor or materials) outside the scope of the Approved Plans or the cost of which is in excess of the Improvement Allowance or the Architectural Allowance, as the case may be, shall be at Lessee's sole cost and will be billed to Lessee by Lessor and will be due and payable within ten (10) days after Lessee's receipt of an invoice therefor. Notwithstanding the foregoing, Lessee will not be liable for work outside the scope of the Approved Plans or excess costs over the amount of the Improvement Allowance or the Architectural Allowance unless Lessee has consented in writing to such work outside the scope of the Approved Plans or excess costs prior to the commencement of such work or the incurring of such excess costs. Any portion of the Improvement Allowance or the Architectural Allowance remaining upon the completion of the Leasehold Improvements shall be deemed forfeited by Lessee. Lessor further acknowledges and agrees that Section 4.07 of the Lease is hereby amended to provide that Lessee shall not be required to surrender possession of the Premises to Lessor "in the same condition as when received", but rather shall be entitled to surrender possession of the Premises in the same condition as exists upon the completion of the Leasehold Improvements described in Paragraph 3 above, subject to any and all other requirements set forth in Section 4.07 of the Lease.

• Alterations to Premises Tenant shall make no structural or interior alterations to the Premises. If Tenant requests such alterations and such alterations are structural in nature, then Tenant shall provide Landlord with a complete set of construction drawings. If Landlord consents to the alterations, then the Landlord shall determine the actual cost of the work to be done. Tenant may then either agree to pay Landlord to have the work done or withdraw its request for alterations; provided, however, that at Tenant’s request, Landlord shall not unreasonably withhold its consent to allowing Tenant and/or Tenant’s contractors to perform such work. All such alterations are subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. Subject to the terms of this paragraph, and notwithstanding any provision of this Lease to the contrary, Landlord agrees to allow Tenant to construct (i) a data center within the Premises and to install equipment (which may include generator, condensers, UPS, etc.) in the Building and around the land surrounding the Building necessary to facilitate the operation of Tenant’s data center, and (ii) an opening in the curtain wall of Floor 1 of Building C, to install two (2) four foot doors within such opening, to improve the outside area for delivery access and to install other improvements (which may include a large dumpster) to the Building and the land surrounding the Building necessary to facilitate the operation of Tenant’s Fulfillment Center. All such alterations shall be performed by Tenant’s contractors (which shall be subject to Landlord’s approval, not to be unreasonably withheld), at Tenant’s sole cost and expense. Notwithstanding the above paragraph, Tenant shall have the right to make nonstructural and nonsystems related alterations (“Tenant Alterations”) up to a value of $15,000.00 per occurrence (not to exceed $60,000 during any 12-month period) without Landlord’s prior written consent (which consent shall not be unreasonably withheld), provided Tenant shall provide notice to Landlord of its intent to make the Tenant Alterations. Such notice shall include a copy of plans and specifications (if such alterations are of a character that would reasonably require plans and specifications) and copies of all permits, if required by the appropriate municipality, and any contracts for such Tenant Alterations. All Tenant Alterations shall be performed by contractors approved by Landlord which approval shall not be unreasonably withheld, and in accordance with all applicable laws and the rules and regulations described in Section 12b.

• Access to Premises Section 14.1 Tenant shall permit Landlord, Landlord’s agents and public utilities servicing the Building to erect, use and maintain concealed ducts, pipes and conduits in and through the Premises, provided that Landlord will not thereby reduce the rentable area of the Premises, other than to a de minimis extent. Landlord or Landlord’s agents shall have the right to enter the Premises at all reasonable times upon reasonable prior notice (except no such prior notice shall be required in case of emergency), which notice may be oral, to examine the same, to show them to prospective purchasers, Mortgagees, Lessors or lessees of the Building and their respective agents and representatives or prospective tenants of the Premises, and to make such repairs, alterations, improvements or additions (a) as Landlord may deem necessary or desirable to the Premises or to any other portion of the Building, or (b) which Landlord may elect to perform following Tenant’s failure to make repairs or perform any work which Tenant is obligated to make or perform under this Lease, or (c) for the purpose of complying with Legal Requirements, and Landlord shall be allowed to take all material into and upon the Premises that may be required therefor without the same constituting an eviction or constructive eviction of Tenant in whole or in part and Fixed Rent and Additional Rent will not be abated while said repairs, alterations, improvements or additions are being made, by reason of loss or interruption of business of Tenant, or otherwise. Section 14.2 If Tenant shall not be present when for any reason entry into the Premises shall be necessary or permissible, Landlord or Landlord’s agents may enter the same without rendering Landlord or such agents liable therefor (if during such entry Landlord or Landlord’s agents shall accord reasonable care to Tenant’s property), and without in any manner affecting this Lease. Nothing herein contained, however, shall be deemed or construed to impose upon Landlord any obligation, responsibility or liability whatsoever for the care, supervision or repair of the Building or any part thereof, other than as herein provided. Section 14.3 Landlord shall have the right from time to time to alter the Building and, without the same constituting an actual or constructive eviction and without incurring any liability to Tenant therefor, to change the arrangement or location of entrances or passageways, doors and doorways, and corridors, elevators, stairs, toilets, or other public parts of the Building and to change the name, number or designation by which the Building is commonly known; provided, however, that Landlord shall not make any permanent alterations which will deny or substantially interfere with Tenant’s access to the Premises from the public areas of the Building. All parts (except surfaces facing the interior of the Premises) of all walls, windows and doors bounding the Premises (including exterior Building walls, exterior core corridor walls, exterior doors and entrances other than doors and entrances solely servicing the Premises), all balconies, terraces and roofs adjacent to the Premises, all space in or adjacent to the Premises used for shafts, stacks, stairways, chutes, pipes, conduits, ducts, fan rooms, heating, air cooling, plumbing and other mechanical facilities, service closets and other Building facilities are not part of the Premises, and Landlord shall have the use thereof, as well as access thereto through the Premises for the purposes of operation, maintenance, alteration and repair. Landlord shall use reasonable efforts to minimize interference with Tenant’s access to and use and occupancy of the Premises in connection with any actions by Landlord permitted under this Section 14.3; provided, however, that Landlord shall have no obligation to employ contractors or labor at overtime or other premium pay rates or to incur any other overtime costs or additional expenses whatsoever.

• LANDLORD'S ACCESS TO PREMISES Landlord reserves and shall at any time upon reasonable notice and in compliance with Tenant’s reasonable security measures have the right to enter the Premises to inspect the same, to supply any service to be provided by Landlord to Tenant hereunder to service and repair HVAC units, water pipes and sprinkler mains, and electrical and telephone risers servicing other parts of the Building, to show said Premises to prospective purchasers or tenants, to alter or repair the Premises or any portion of the Building, and to place “for sale” or “for rent” signs on the Building, all without being deemed guilty of an eviction of Tenant and without abatement of Rent, provided that the business of Tenant shall be interfered with as little as is reasonably practicable. Tenant hereby waives any claim for damages or any inconvenience to or interference with Tenant’s business, any loss of quiet enjoyment of the Premises and any other loss occasioned thereby. For each of the aforesaid purposes, Landlord shall at all times have and retain a key with which to unlock the main door to the Premises but not Tenant’s vaults and safes, and Landlord shall have the right to use any and all means which Landlord may deem proper to open said door in an emergency in order to obtain entry to the Premises, and any entry to the Premises obtained by Landlord by any of said means shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of the Premises, or any eviction of Tenant from the Premises or any portion thereof. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decoration except as otherwise expressly agreed to be performed by Landlord.

• Additional Premises Landlord shall use commercially reasonable efforts to expand the Premises to include an additional fifteen thousand four hundred ten (15,410) square feet of Rentable Area located on the first (1st) floor, as shown on Exhibit A attached hereto (the “Additional Premises”) on July 1, 2012 (the “Additional Premises Delivery Date”). In the event Landlord determines the Additional Premises will be ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, within ten (10) business days prior to the Additional Premises Delivery Date, Landlord and Tenant shall enter into a written amendment to the Lease, which amendment shall provide, unless otherwise agreed in writing, (a) that the commencement date of the Additional Premises shall be the Additional Premises Delivery Date (the “Additional Premises Commencement Date”), (b) that, as of the Additional Premises Commencement Date, the Premises under the Lease shall be increased to include the Additional Premises for a total of sixty-one thousand four hundred forty-four (61,444) square feet of Rentable Area (together, the Premises and the Additional Premises shall be referred to hereinafter as the “Total Premises”), (c) the new Basic Annual Rent applicable to the Total Premises, which shall commence on the Additional Premises Commencement Date and shall be as further described in Section 4.2 of this Amendment, (d) Tenant’s new Pro Rata Share of Operating Expenses as of the Additional Premises Commencement Date, which Pro Rata Share shall equal one hundred percent (100%) of the Building and thirty-three and 51/100 percent (33.51%) of the Project and (e) that, in addition to the parking which Tenant is entitled to under the terms of the Lease with respect to the original Premises, Tenant, for so long as Tenant leases the Additional Premises, shall have a non-exclusive license to use the parking facilities serving the Building in common on an unreserved basis with other tenants of the Building and the Project at a ratio of 3.3 parking spaces per 1,000 rentable square feet of Additional Premises, which amounts to fifty-one (51) additional parking spaces, which number shall include three (3) additional Reserved Spaces. In the event the Additional Premises is not ready for delivery to Tenant in the Required Condition on the Additional Premises Delivery Date, then (x) this Amendment and the Lease shall not be void or voidable, (y) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom and (z) the new Basic Annual Rent applicable to the Premises shall be as further described in Section 4.3 of this Amendment.

• Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.

• Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.

• Construction Liens (1) If any lien under the Construction Act, R.S.O. 1990, c. C30, or any like statute shall at any time be registered against the Demised Premises by reason of work done or materials supplied for or to the Tenant or for or to anyone holding an interest in the Demised Premises through the Tenant or if the Landlord is given notice of any such lien, the lien shall be discharged or vacated from the title to the Demised Premises by the Tenant within ninety (90) days after the lien is filed or sooner if the Demised Premises are in jeopardy of forfeiture or sale by the party performing the Work in respect of which the lien was filed even if the validity of the lien is being contested, if requested by the Landlord, or by a Leasehold Mortgagee. If the Tenant wishes to contest the amount or validity of any lien and has so notified the Landlord and if the Tenant has deposited with the Landlord or paid into court to the credit of the lien action the amount of the lien plus a reasonable amount for costs and has registered a discharge of such lien, the Tenant may defer payment of such lien for a period of time sufficient to enable the Tenant to contest the lien with due diligence, provided always that the Demised Premises shall not thereby become liable to forfeiture or sale. (2) The Landlord may, but shall not be obligated to, discharge or vacate any construction lien if in the Landlord's judgment, exercised reasonably, the Demised Premises become liable to immediate forfeiture or sale or the Demised Premises is otherwise in jeopardy, and any amount paid by the Landlord in so doing, shall be reimbursed to the Landlord by the Tenant as Additional Rent within thirty (30) days after demand. If a construction lien is not discharged and vacated within three (3) months of registration, notwithstanding that the lien may be contested, the Landlord shall have the right, on written notice to the Tenant, to terminate the Lease. (3) Nothing herein contained shall authorize Tenant, or imply any consent or agreement or request on the part of the Landlord to subject the Landlord's estate or interest in the Demised Premises and/or the Building to any construction lien or any other lien of any nature or kind whatsoever. Notice is hereby given to all parties that the Landlord expressly refuses and denies any consent or agreement or request to permit their estate or interest in the Demised Premises and/or the Building to be subject to any construction lien or other lien of any nature or kind whatsoever without the express written agreement of the Landlord to this effect. Tenant acknowledges that the Landlord is not, and should not be held to be, an owner as that term is defined in the Construction Act with respect to the construction of any work on the Demised Premises by, or on behalf of Tenant.

• Access to Premises and Records Between the date of this Agreement ------------------------------ and the Closing Date, Seller will give Buyer and its counsel, accountants and other representatives full access during normal business hours upon reasonable notice to all the premises and books and records of the Business and to all the Assets and to the System personnel and will furnish to Buyer and such representatives all such documents, financial information, and other information regarding the Business and the Assets as Buyer from time to time reasonably may request; provided that no such investigation will affect or limit the scope of any of Seller's representations, warranties, covenants and indemnities in this Agreement or any Transaction Document or limit liability for any breach of any of the foregoing.

• Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above. (b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01. (c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,. (d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions: 1. Actual cost of the Landlord Improvements: $100,000.00 2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75 (e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements: (i) Replace all stained, damaged or missing ceiling tiles, (ii) Paint all walls in the Leased Premises, the color to be designated by Tenant, (iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C, (iv) Shampoo all carpets in the office areas and hallways and (v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use. (vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface (vii) Repair any existing alligator or pothole areas.