Replacement of Plant Manager. NAES shall inform Owner of its intent to replace the Plant Manager. Prior to employment of the replacement Plant Manager, NAES shall obtain Owner’s written approval.
Replacement of Plant Manager Sample Clauses
Related to Replacement of Plant Manager
Replacement of Key Personnel The Engineer must notify the State in writing as soon as possible, but no later than three business days after a project manager or other key personnel is removed from association with this contract, giving the reason for removal.
Replacement of Manager If at any time after any Action is brought the Manager settles the Action on a basis that results in the settlement of such Action against it and fewer than all the Underwriters (whether or not such settlement complies with Section 9.7 hereof), the Manager will, at such time, for purposes of Sections 9.3, 9.4, 9.5, 9.6, and 9.7 hereof, cease to be the Manager. The non-settling Underwriters will, by vote of holders of a majority of the Underwriting Percentage of such non-settling Underwriters, select a new Manager, which will become the new “Manager” for all purposes of Sections 9.3, 9.4., 9.5, 9.6, and 9.7 hereof as well as this section; provided that the non-settling Underwriter(s) with the largest Underwriting Percentage will act as Manager until such vote occurs and a new Manager is selected. 4 Notwithstanding such a settlement, the Manager and the other settling Underwriters will remain obligated to the non-settling Underwriters to assist and cooperate fully, in good faith, and at their own expense, in the defense of any Actions, including, without limitation, by providing, upon reasonable request of any non-settling Underwriter, and without the necessity of court process, access to or copies of all relevant records, and reasonable access to all witnesses under control of the Manager or the other settling Underwriters, for the purpose of interviews, depositions, and testimony at trial, subject in each case to the applicable legal and procedural obligations of such Manager and such other settling Underwriter. In addition, if at any time, the Manager is unwilling or unable for any reason to assume or discharge its duties as Manager under the applicable AAU, whether resulting from its insolvency (voluntary or involuntary), resignation or otherwise, to the extent permitted by applicable law, the remaining Underwriters will, by vote of holders of a majority of the Underwriting Percentage of such Underwriters, be entitled to select a new Manager, which will become the new Manager for all purposes under this Agreement. 5 Notwithstanding the foregoing, a Manager replaced pursuant to this Section 9.9 shall continue to benefit from and be subject to all other terms and conditions of this Agreement applicable to an Underwriter.
Replacement of Parts Except as otherwise provided herein, so long as the Airframe or Engine is subject to the Lien of this Indenture, Owner, at its own cost and expense, will, or will cause a Permitted Lessee to, at its own cost and expense, promptly replace (or cause to be replaced) all Parts which may from time to time be incorporated or installed in or attached to the Aircraft, Airframe or any Engine and which may from time to time become worn out, lost, stolen, destroyed, seized, confiscated, damaged beyond repair or permanently rendered unfit for use for any reason whatsoever. In addition, Owner may, at its own cost and expense, or may permit a Permitted Lessee at its own cost and expense to, remove (or cause to be removed) in the ordinary course of maintenance, service, repair, overhaul or testing any Parts, whether or not worn out, lost, stolen, destroyed, seized, confiscated, damaged beyond repair or permanently rendered unfit for use; provided, however, that Owner, except as otherwise provided herein, at its own cost and expense, will, or will cause a Permitted Lessee at its own cost and expense to, replace such Parts as promptly as practicable. All replacement parts shall be free and clear of all Liens, except for Permitted Liens and pooling arrangements to the extent permitted by Section 4.04(c) below (and except in the case of replacement property temporarily installed on an emergency basis) and shall be in good operating condition and have a value and utility not less than the value and utility of the Parts replaced (assuming such replaced Parts were in the condition required hereunder).
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Procurement of Small Works Works estimated to cost $250,000 equivalent or less per contract, up to an aggregate amount not to exceed $800,000 equivalent, may be procured under lump-sum, fixed-price contracts awarded on the basis of quotations obtained from three (3) qualified domestic contractors in response to a written invitation. The invitation shall include a detailed description of the works, including basic specifications, the required completion date, a basic form of agreement acceptable to the Bank, and relevant drawings, where applicable. The award shall be made to the contractor who offers the lowest price quotation for the required work, and who has the experience and resources to complete the contract successfully. Part D: Review by the Bank of Procurement Decisions
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Commencement of Services The Services will be commenced immediately upon receipt of the signed Proposal (the “Agreement”). If after commencement of the Services, the Project is delayed for any reason beyond Xxxxxxxxx’x control for more than 60 days, the terms and conditions contained herein will be subject to revision by Xxxxxxxxx. Subsequent modifications to this Agreement must be in writing and signed by the parties to the Agreement.
Quality Management Grantee will: 1. comply with quality management requirements as directed by the System Agency. 2. develop and implement a Quality Management Plan (QMP) that conforms with 25 TAC § 448.504 and make the QMP available to System Agency upon request. The QMP must be developed no later than the end of the first quarter of the Contract term. 3. update and revise the QMP each biennium or sooner, if necessary. Xxxxxxx’s governing body will review and approve the initial QMP, within the first quarter of the Contract term, and each updated and revised QMP thereafter. The QMP must describe Xxxxxxx’s methods to measure, assess, and improve - i. Implementation of evidence-based practices, programs and research-based approaches to service delivery; ii. Client/participant satisfaction with the services provided by Xxxxxxx; iii. Service capacity and access to services; iv. Client/participant continuum of care; and v. Accuracy of data reported to the state. 4. participate in continuous quality improvement (CQI) activities as defined and scheduled by the state including, but not limited to data verification, performing self-reviews; submitting self-review results and supporting documentation for the state’s desk reviews; and participating in the state’s onsite or desk reviews. 5. submit plan of improvement or corrective action plan and supporting documentation as requested by System Agency. 6. participate in and actively pursue CQI activities that support performance and outcomes improvement. 7. respond to consultation recommendations by System Agency, which may include, but are not limited to the following: i. Staff training; ii. Self-monitoring activities guided by System Agency, including use of quality management tools to self-identify compliance issues; and iii. Monitoring of performance reports in the System Agency electronic clinical management system.
Removal or Replacement of a Manager Any Manager may be removed or replaced without “Cause” at any time by a majority of the Board and each Manager may be removed and or replaced and our Board can be reconstituted for any reason by the Class C Member, if any.
Quality Management System Supplier hereby undertakes, warrants and confirms, and will ensue same for its subcontractors, to remain certified in accordance with ISO 9001 standard or equivalent. At any time during the term of this Agreement, the Supplier shall, if so instructed by ISR, provide evidence of such certifications. In any event, Supplier must notify ISR, in writing, in the event said certification is suspended and/or canceled and/or not continued.
