Final Acceptance When the Project/Service or any portion thereof, as designated by the COUNTY, is ready for its intended use, the COUNTY and any other invited parties shall make an inspection of the Project/Service, to verify its completeness and develop a punch list of items needing completion or correction before final payment will be made. CONTRACTOR shall have ten (10) calendar days to correct all deficiencies. An eighty-dollar ($80.00) re-inspection fee shall be applied for the third inspection and any required re-inspection thereafter. The COUNTY shall have the right to exclude CONTRACTOR from those portions of the work designated as complete after the inspection; provided, however, that CONTRACTOR will have reasonable access for the time allotted by the COUNTY to complete or correct items on the punch list. When the work provided for under this Agreement has been completely performed by CONTRACTOR, and the final inspection has been made by the COUNTY, a final invoice will be prepared by the CONTRACTOR. The amount of this invoice, less any sums that may have been deducted or retained under the provisions of this Agreement, will be paid to CONTRACTOR in accordance with this Agreement, and after CONTRACTOR has agreed in writing to accept the balance due, as determined by the COUNTY, as full settlement of the account under the contract and of all claims in connection therewith. Occupancy by the COUNTY alone does not constitute final acceptance.
361 Acceptance of Specified Roads Specified Road work may be accepted subject to completion of clearing work that does not affect the road structure when completion is delayed for reasons beyond control of Purchaser, such as adverse weather. Specified Road work may be accepted subject to completion of planting and seeding for soil stabilization when completion is delayed for reasons beyond control of Purchaser, such as seasonal limitations. Purchaser shall complete planting or seeding on such road during the next suitable planting season. Specified Road work may be conditionally accepted prior to the application of dust palliatives when application is not necessary to prevent dusting of the road surface due to climatic conditions. Purchaser shall apply dust palliative on such roads prior to use during periods when dusting may occur. Prior to request for final inspection, Specified Road work, roadways, borrow pits, and quarries, occupied and no longer needed by Purchaser in connection with Purchaser’s Operations, shall be cleared of all rubbish, excess materials, and temporary structures.
Inspection and Final Acceptance District may, at its discretion, inspect and accept or reject any of Consultant’s work under this Agreement, either during performance or when within sixty (60) days after submitted to District. If District does not reject work by a timely written explanation, Consultant’s work shall be deemed to have been accepted. District’s acceptance shall be conclusive as to such work except with respect to latent defects, fraud and such gross mistakes as amount to fraud. Acceptance of any of Consultant’s work by District shall not constitute a waiver of any of the provisions of this Agreement including, but not limited to indemnification and insurance provisions.
Requesting Price Increase/Required Documentation Contractor must submit a written notification at least thirty (30) calendar days prior to the requested effective date of the change, setting the amount of the increase, along with an itemized list of any increased prices, showing the Contractor’s current price, revised price, the actual dollar difference and the percentage of the price increase by line item. Price change requests must include H-GAC Forms D Offered Item Pricing and E Options Pricing, or the documentation used to submit pricing in the original Response and be supported with substantive documentation (e.g. manufacturer's price increase notices, copies of invoices from suppliers, etc.) clearly showing that Contractor's actual costs have increased per the applicable line item bid. The Producer Price Index (PPI) may be used as partial justification, subject to approval by H-GAC, but no price increase based solely on an increase in the PPI will be allowed. This documentation should be submitted in Excel format to facilitate analysis and updating of the website. The letter and documentation must be sent to the Bids and Specifications manager, Xxxxxxx Xxxxxx, at Xxxxxxx.Xxxxxx@x-xxx.xxx Review/Approval of Requests If H-GAC approves the price increase, Contractor will be notified in writing; no price increase will be effective until Contractor receives this notice. If H-GAC does not approve Contractor’s price increase, Contractor may terminate its performance upon sixty (60) days advance written notice to H-GAC, however Contractor must fulfill any outstanding Purchase Orders. Termination of performance is Contractor’s only remedy if H-GAC does not approve the price increase. H-GAC reserves the right to accept or reject any price change request.
Order Acceptance All orders are subject to acceptance only at Seller’s facility in Farmington, Connecticut. These Terms of Sale shall be deemed accepted by Buyer upon Seller’s receipt of Purchase Order from Buyer. No condition stated by Buyer shall be binding upon Seller if in conflict with, inconsistent with or in addition to the Terms of Sale, unless expressly accepted in a writing signed by Seller. In the event of conflict or differences in the terms or conditions of Buyer’s Purchase Order and the Terms of Sale herein, the Terms of Sale shall govern.
REQUEST FOR REVIEW Within sixty (60) days after receiving notice from the Plan Administrator that a claim has been denied (in part or all of the claim), then claimant (or their duly authorized representative) may file with the Plan Administrator, a written request for a review of the denial of the claim. The claimant (or his duly authorized representative) shall then have the opportunity to submit written comments, documents, records and other information relating to the claim. The Plan Administrator shall also provide the claimant, upon request and free of charge, reasonable access to, and copies of, all documents, records and other information relevant (as defined in applicable ERISA regulations) to the claimant’s claim for benefits.
Terms of Acceptance for Orders It is your sole responsibility to clearly indicate the terms of an order when entered, whether it is a market order, limit order, stop loss order or any other type of order, including the relevant price and lot size. You acknowledge and agree that, despite our best efforts, the price at which execution occurs may be materially different to the price specified in your order. This may result from sudden price movements in the underlying assets that are beyond our control. The Company shall have no liability for failure to execute orders. The Company shall have the right, but not the obligation, to reject any order in whole or in part prior to execution, or to cancel any order, where your Account contains margin that is insufficient to support the entire order or where such order is illegal or otherwise improper. Execution Policy We are required to have an execution policy and to provide our clients with appropriate information in relation to our execution policy. Where you place orders with us, the execution factors that we consider and their relative importance is as set out below:
ACCEPTANCE OF NONCONFORMING WORK If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.
NON-ACCEPTANCE OF SETTLEMENT AGREEMENT 33. If, for any reason whatsoever, this Settlement Agreement is not accepted by the Hearing Panel or an Order in the form attached as Schedule “A” is not made by the Hearing Panel, each of Staff and the Respondent will be entitled to any available proceedings, remedies and challenges, including proceeding to a disciplinary hearing pursuant to sections 20 and 24 of By- law No. 1, unaffected by this Settlement Agreement or the settlement negotiations.
Acceptance Procedure Lessor hereby authorizes one or more employees of the related Lessee, to be designated by such Lessee, as the authorized representative or representatives of Lessor to accept delivery on behalf of Lessor of that Leased Property identified on the applicable Funding Request. Each Lessee hereby agrees that such acceptance of delivery by such authorized representative or representatives and the execution and delivery by such Lessee on each Closing Date for property to be leased hereunder of a Lease Supplement in substantially the form of Exhibit A hereto (appropriately completed) shall, without further act, constitute the irrevocable acceptance by such Lessee of that Leased Property which is the subject thereof for all purposes of this Lease and the other Operative Documents on the terms set forth therein and herein, and that such Leased Property, together with, in the case of Land, any Building or other improvements thereon or to be constructed thereon pursuant to the Construction Agency Agreement, shall be deemed to be included in the leasehold estate of this Lease and shall be subject to the terms and conditions of this Lease as of such Closing Date. The demise and lease of each Building pursuant to this Section 2.2 shall include any additional right, title or interest in such Building which may at any time be acquired by Lessor, the intent being that all right, title and interest of Lessor in and to such Building shall at all times be demised and leased to the related Lessee hereunder.
