Request for Review Within sixty (60) days after receiving notice from the Plan Administrator that a claim has been denied (in part or all of the claim), then claimant (or their duly authorized representative) may file with the Plan Administrator, a written request for a review of the denial of the claim. The claimant (or his duly authorized representative) shall then have the opportunity to submit written comments, documents, records and other information relating to the claim. The Plan Administrator shall also provide the claimant, upon request and free of charge, reasonable access to, and copies of, all documents, records and other information relevant (as defined in applicable ERISA regulations) to the claimant’s claim for benefits.
Notification of Acquisition Proposals If the Company or any of its Subsidiaries receives, or, to the knowledge of the Company, any of their respective Representatives, receives, any inquiry, proposal or offer that constitutes or may reasonably be expected to constitute or lead to an Acquisition Proposal, or any request for copies of, access to, or disclosure of, confidential information relating to the Company or any Subsidiary, the Company shall promptly notify the Purchaser, at first orally, and then within 24 hours, in writing, of such Acquisition Proposal, inquiry, proposal, offer or request, including a description of its material terms and conditions, the identity of all Persons making the Acquisition Proposal, inquiry, proposal, offer or request and shall provide the Purchaser with copies of all documents, correspondence or other material (whether in writing or electronic form) received in respect of, from or on behalf of any such Person. The Company shall keep the Purchaser promptly informed of the status of developments and negotiations with respect to any Acquisition Proposal or any inquiry, proposal, offer or request which may reasonably be expected to lead to an Acquisition Proposal, including any changes, modifications or other amendments to any such Acquisition Proposal, inquiry, proposal, offer or request and shall provide to the Purchaser copies of all material or substantive correspondence if in writing or electronic form, and if not in writing or electronic form, a description of the material terms of such correspondence sent or communicated to the Company by or on behalf of any Person making any such Acquisition Proposal, inquiry, proposal, offer or request.
Proposal Proposal means any information supplied by or on behalf of the insured, deemed to be a completed proposal form and medical questionnaire and other relevant information that the insurer may require.
Cost Proposal After the Approved Working Drawings are approved by Landlord and Tenant, and the Contractor and subcontractors have been selected pursuant to Section 4.1 above, Landlord shall provide Tenant with a cost proposal in accordance with the Approved Working Drawings setting forth the reconciled bids and copies of all sub-bids, which cost proposal shall include, as nearly as possible, the cost of all Tenant Improvement Allowance Items to be incurred in connection with the construction of the Tenant Improvements (the "COST PROPOSAL"). The Cost Proposal shall reflect bids that will be priced by Contractor on an individual item-by-item or trade-by-trade basis. Landlord and Tenant shall work together in good faith in an attempt to agree upon a mutually acceptable Cost Proposal as soon as reasonably possible. Notwithstanding the foregoing, portions of the cost of the Tenant Improvements may be delivered to Tenant as such portions of the Tenant Improvements are priced by Contractor (on an individual item-by-item or trade-by-trade basis), even before the Approved Working Drawings are completed (the "PARTIAL COST PROPOSAL") for purposes of facilitating the early purchase of items and construction of the same. Tenant shall approve and deliver the Cost Proposal to Landlord within seven (7) business days of the receipt of the same, or, as to a Partial Cost Proposal within five (5) business days of receipt of the same, and upon receipt of the same by Landlord, Landlord shall be released by Tenant to purchase the items set forth in the Cost Proposal or Partial Cost Proposal, as the case may be, and to commence the construction relating to such items. If Tenant disapproves the Cost Proposal or Partial Cost Proposal, Tenant shall provide Landlord with a reasonably sufficient explanation, and in such event, Landlord and Tenant shall use good faith, diligent efforts to work with each other and Contractor to address Tenant's reasons for disapproving the Cost Proposal or Partial Cost Proposal, whichever is the case and a new Cost Proposal (or Partial Cost Proposal, as applicable) shall be prepared and the process described in this Section 4.2 shall be repeated. The date by which Tenant must approve and deliver the Cost Proposal or the last Partial Cost Proposal to Landlord, as the case may be, shall be known hereafter as the "COST PROPOSAL DELIVERY DATE". The total of all Partial Cost Proposals, if any, shall be known as the Cost Proposal.
Notification of Unsolicited Acquisition Proposals (i) As promptly as practicable (but in any event within one business day) after any of Avanex or Oplink's respective officers, directors or representatives (including any investment banker, attorney or accountant retained by it or any of its subsidiaries) receives or becomes aware of the receipt of any Acquisition Proposal by Avanex or Oplink, as the case may be, or any request for nonpublic information or inquiry which Avanex or Oplink, as the case may be, reasonably believes could lead to an Acquisition Proposal, Avanex or Oplink, as the case may be, shall provide the other party hereto with written notice of the material terms and conditions of such Acquisition Proposal, request or inquiry, and the identity of the Person or group making any such Acquisition Proposal, request or inquiry and a copy of all written materials provided in connection with such Acquisition Proposal, request or inquiry. The recipient of the Acquisition Proposal, request or inquiry shall keep the other party hereto informed as promptly as practicable (but in any event within one (1) business day) in all material respects of the status and details (including all amendments or proposed amendments) of any such Acquisition Proposal, request or inquiry and shall promptly (but in any event within one (1) business day) provide to the other party hereto a copy of all written and electronic materials subsequently provided in connection with such Acquisition Proposal, request or inquiry.
Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Request for Advance Subject to the following conditions, the Borrower may request an Advance to be made by ensuring that the Lender receives a completed Drawdown Notice not later than 11.00 a.m. (London time) 2 Business Days prior to the intended Drawdown Date.
Other Proposals For the avoidance of doubt, nothing in this Agreement shall require Stockholder to vote in any manner with respect to any amendment to the Merger Agreement or the taking of any action that would reasonably be expected to result in the amendment, modification or waiver of a provision of the Merger Agreement, in any such case, in a manner that (i) decreases the Exchange Ratio (other than any such decrease in accordance with Section 1.5(b) of the Merger Agreement), decreases the amount of Merger Consideration or changes the form of the Merger Consideration, (ii) imposes any material restrictions or any additional material conditions on the consummation of the Merger or the payment of the Merger Consideration to stockholders or (iii) extends the End Date. Except as expressly set forth in this Section 3, Stockholder shall not be restricted from voting in any manner with respect to any other matters presented or submitted to the stockholders of the Company.
Acquisition Proposal “Acquisition Proposal” shall mean any offer or proposal (other than an offer or proposal made or submitted by Parent) contemplating or otherwise relating to any Acquisition Transaction.
Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
