Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract.
b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Use of Attachment Facilities by Third Parties Purpose of Attachment Facilities. Except as may be required by Applicable Laws and Regulations, or as otherwise agreed to among the Parties, the Attachment Facilities shall be constructed for the sole purpose of interconnecting the Large Generating Facility to the New York State Transmission System and shall be used for no other purpose.
Retention or Repurchase of Assets Essential to Receiver (a) The Receiver may refuse to sell to the Assuming Institution, or the Assuming Institution agrees, at the request of the Receiver set forth in a written notice to the Assuming Institution, to assign, transfer, convey, and deliver to the Receiver all of the Assuming Institution's right, title and interest in and to, any Asset or asset essential to the Receiver as determined by the Receiver in its discretion (together with all Credit Documents evidencing or pertaining thereto), which may include any Asset or asset that the Receiver determines to be:
(i) made to an officer, director, or other Person engaging in the affairs of the Failed Bank, its Subsidiaries or Affiliates or any related entities of any of the foregoing;
(ii) the subject of any investigation relating to any claim with respect to any item described in Section 3.5(a) or (b), or the subject of, or potentially the subject of, any legal proceedings;
(iii) made to a Person who is an Obligor on a loan owned by the Receiver or the Corporation in its corporate capacity or its capacity as receiver of any institution;
(iv) secured by collateral which also secures any asset owned by the Receiver; or
(v) related to any asset of the Failed Bank not purchased by the Assuming Institution under this Article III or any liability of the Failed Bank not assumed by the Assuming Institution under Article II.
(b) Each such Asset or asset purchased by the Receiver shall be purchased at a price equal to the Repurchase Price thereof less the Related Liability Amount with respect to any Related Liabilities related to such Asset or asset, in each case determined as of the date of the notice provided by the Receiver pursuant to Section 3.6(a). The Receiver shall pay the Assuming Institution not later than the twentieth (20th) Business Day following receipt of related Credit Documents and Credit Files together with interest on such amount at the Settlement Interest Rate for the period from and including the date of receipt of such documents to and including the day preceding the day on which payment is made. The Assuming Institution agrees to administer and manage each such Asset or asset in accordance with usual and prudent banking standards and business practices until each such Asset or asset is purchased by the Receiver. All transfers with respect to Asset or assets under this Section 3.6 shall be made as provided in Section 9.6. The Assuming Institution shall transfer all such Asset or assets and Related Liabilities to the Receiver without recourse, and shall indemnify the Receiver against any and all claims of any Person claiming by, through or under the Assuming Institution with respect to any such Asset or asset, as provided in Section 12.4.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Licenses for Permanent Installation The contractor must comply with all State mandatory licensing requirements prior to installation. Questions on licensing requirements should be directed to the State Licensing Board. Contractor must furnish and install all furniture and materials in compliance with all applicable codes, whether local, state, or federal; and that all permits or licenses required for installation will be obtained without cost to the State.
Protection of Customer Data The Supplier shall not delete or remove any proprietary notices contained within or relating to the Customer Data. The Supplier shall not store, copy, disclose, or use the Customer Data except as necessary for the performance by the Supplier of its obligations under this Call Off Contract or as otherwise Approved by the Customer. To the extent that the Customer Data is held and/or Processed by the Supplier, the Supplier shall supply that Customer Data to the Customer as requested by the Customer and in the format (if any) specified by the Customer in the Call Off Order Form and, in any event, as specified by the Customer from time to time in writing. The Supplier shall take responsibility for preserving the integrity of Customer Data and preventing the corruption or loss of Customer Data. The Supplier shall perform secure back-ups of all Customer Data and shall ensure that up-to-date back-ups are stored off-site at an Approved location in accordance with any BCDR Plan or otherwise. The Supplier shall ensure that such back-ups are available to the Customer (or to such other person as the Customer may direct) at all times upon request and are delivered to the Customer at no less than six (6) Monthly intervals (or such other intervals as may be agreed in writing between the Parties). The Supplier shall ensure that any system on which the Supplier holds any Customer Data, including back-up data, is a secure system that complies with the Security Policy and the Security Management Plan (if any). If at any time the Supplier suspects or has reason to believe that the Customer Data is corrupted, lost or sufficiently degraded in any way for any reason, then the Supplier shall notify the Customer immediately and inform the Customer of the remedial action the Supplier proposes to take. If the Customer Data is corrupted, lost or sufficiently degraded as a result of a Default so as to be unusable, the Supplier may: require the Supplier (at the Supplier's expense) to restore or procure the restoration of Customer Data to the extent and in accordance with the requirements specified in Call Off Schedule 8 (Business Continuity and Disaster Recovery) or as otherwise required by the Customer, and the Supplier shall do so as soon as practicable but not later than five (5) Working Days from the date of receipt of the Customer’s notice; and/or itself restore or procure the restoration of Customer Data, and shall be repaid by the Supplier any reasonable expenses incurred in doing so to the extent and in accordance with the requirements specified in Call Off Schedule 8 (Business Continuity and Disaster Recovery) or as otherwise required by the Customer.
System Upgrade Facilities and System Deliverability Upgrades Connecting Transmission Owner shall design, procure, construct, install, and own the System Upgrade Facilities and System Deliverability Upgrades described in Appendix A hereto. The responsibility of the Developer for costs related to System Upgrade Facilities and System Deliverability Upgrades shall be determined in accordance with the provisions of Attachment S to the NYISO OATT.
Procurement of Recovered Materials In the performance of this contract, the Contractor shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired
PROHIBITION ON CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT To the extent applicable, Supplier certifies that during the term of this Contract it will comply with applicable requirements of 2 C.F.R. § 200.216.
