Litigation; Claims Any rights (including indemnification) and claims and recoveries under litigation of Seller against third parties arising out of or relating to events prior to the Closing Date;
Employment Claims Any claim relating to any (a) violation by Kraft or the Eligible Recipients, or their respective officers, directors, employees, representatives or agents, of Federal, state, provincial, local, international or other Laws or regulations or any common law protecting persons or members of protected classes or categories, including laws or regulations prohibiting discrimination or harassment on the basis of a protected characteristic, (b) liability arising or resulting from a Transitioned Employee’s employment with Kraft prior to the Employment Effective Date with Supplier, (c) payment or failure to pay any salary, wages or other cash compensation due and owing to (i) any Kraft employee who does not become a Transitioned Employee or (ii) any Transitioned Employee prior to such Transitioned Employee’s Employment Effective Date with Supplier, (d) (i) all accrued employee pension or other benefits of any Kraft employee who does not become a Transitioned Employee and (ii) those employee pension or other benefits of any Transitioned Employee accruing prior to such Transitioned Employee’s Effective Employment Date with Supplier, (e) other aspects of any Transitioned Employee’s employment relationship with Kraft or the termination of such relationship, including claims for breach of an express or implied contract of employment, and/or (f) liability resulting from representations (oral or written) to the Kraft employees identified on the applicable Supplement by Kraft or the Eligible Recipients (or their respective officers, directors, employees, representatives or agents) with respect to their employment by Supplier or its Subcontractors or Affiliates (other than representations made with the authorization or approval of Supplier, representations that Supplier knew to be inaccurate and failed to correct and/or representations made by Supplier in this Agreement), except, in each case, to the extent resulting from the wrongful actions of Supplier, Supplier Affiliates or Subcontractors or their failure to comply with Supplier’s responsibilities under this Agreement, or involving any matters for which Supplier has an indemnity obligation under Section 17.1.11; and
Retention Award The Company shall pay the Executive $785,000, plus interest at the rate specified below (the “Retention Award”) in a lump-sum cash payment in July 2014, provided that the Executive remains employed through December 31, 2013. The Retention Award shall be credited with interest based on the Prime Rate of SunTrust Bank, Atlanta. For the avoidance of doubt, if the Executive is employed through December 31, 2013, the Company shall pay the Retention Award in July 2014 without regard for the Executive’s termination of employment for any reason between December 31, 2013 and July 2014.
Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
Indemnity Claims A claim for indemnification for any matter not involving a third-party claim may be asserted by notice to the party from whom indemnification is sought.
Release of Employment Claims Executive agrees, as a condition to receipt of the termination payments and benefits provided for in this Section 4, that he/she will execute a release agreement, a form of which is attached hereto as Exhibit A, releasing any and all claims arising out of Executive’s employment.
Indemnification Claim Procedures (a) If any Action is commenced or threatened that may give rise to a claim for indemnification (an “Indemnification Claim”) by any person entitled to indemnification under this Agreement (each, an “Indemnified Party”) against any person obligated to indemnify an Indemnified Party (an “Indemnitor”), then such Indemnified Party will promptly give notice to the Indemnitor. Failure to notify the Indemnitor will not relieve the Indemnitor of any liability that it may have to the Indemnified Party, except to the extent the defense of such Action is materially and irrevocably prejudiced by the Indemnified Party’s failure to give such notice. An Indemnitor may elect at any time to assume and thereafter conduct the defense of the Indemnification Claim with counsel of the Indemnitor’s choice reasonably satisfactory to the Indemnified Party; provided, however, that the Indemnitor will not approve of the entry of any judgment or enter into any settlement with respect to the Indemnification Claim without the Indemnified Party’s prior written approval (which must not be withheld unreasonably). Until an Indemnitor assumes the defense of the Indemnification Claim, the Indemnified Party may defend against the Indemnification Claim in any manner the Indemnified Party reasonably deems appropriate. If the Indemnified Party gives an Indemnitor notice of an Indemnification Claim and the Indemnitor does not, within ten (10) days after such notice is given, give notice to the Indemnified Party of its election to assume the defense of such Indemnification Claim and thereafter promptly assume such defense, then the Indemnitor will be bound by any judicial determination made with respect to such Indemnification Claim or any compromise or settlement of such Indemnification Claim effected by the Indemnified Party.
Employee Claims Without limiting in any way the breadth of this Clause G2, Contractor specifically acknowledges its obligation to indemnify and defend the Covered Parties from and against any claim which may be asserted by or on behalf of any employee of Contractor, Subcontractors and suppliers alleging bodily injury, sickness, disease or death, or injury to or destruction of tangible property sustained by said employee in connection with the Work, unless caused by the sole negligence of the Covered Parties.
Insured Claims To indemnify Indemnitee for expenses or liabilities of any type whatsoever (including, but not limited to, judgments, fines, ERISA excise taxes or penalties, and amounts paid in settlement) to the extent such expenses or liabilities have been paid directly to Indemnitee by an insurance carrier under a policy of officers’ and directors’ liability insurance maintained by the Company; or
Released Claims In consideration of these additional benefits, you, on behalf of your heirs, spouse and assigns, hereby completely release and forever discharge Ikanos, its past and present affiliates, agents, officers, directors, shareholders, employees, attorneys, insurers, successors and assigns (collectively referred to as the “Company”) from any and all claims, of any and every kind, nature and character, known or unknown, foreseen or unforeseen, based on any act or omission occurring prior to the date of you signing this Release Agreement, including but not limited to any claims arising out of your offer of employment, your employment or termination of your employment with the Company or your right to purchase, or actual purchase of shares of stock of the Company (including, but not limited to, all rights related to or associated with stock options and restricted stock units), including, without limitation, any claims for fraud, misrepresentation, breach of fiduciary duty, breach of duty under applicable state corporate law, and securities fraud under any state or federal law. The matters released include, but are not limited to, any claims under federal, state or local laws, including claims arising under the Age Discrimination in Employment Act of 1967 (“ADEA”) as amended by, including but not limited to, the Older Workers’ Benefit Protection Act (“OWBPA”) and any common law tort contract or statutory claims, and any claims for attorneys’ fees and costs. You understand and agree that this Release Agreement extinguishes all claims, whether known or unknown, foreseen or unforeseen, except for those claims expressly described below. You expressly waive any rights or benefits under Section 1542 of the California Civil Code, or any equivalent statute. California Civil Code Section 1542 provides as follows: “A GENERAL RELEASE DOES NOT EXTEND TO CLAIMS WHICH THE CREDITOR DOES NOT KNOW OR SUSPECT TO EXIST IN HIS FAVOR AT THE TIME OF EXECUTING THE RELEASE, WHICH IF KNOWN BY HIM MUST HAVE MATERIALLY AFFECTED HIS SETTLEMENT WITH THE DEBTOR.” You fully understand that, if any fact with respect to any matter covered by this Release Agreement is found hereafter to be other than or different from the facts now believed by you to be true, you expressly accept and assume that this Release Agreement shall be and remain effective, notwithstanding such difference in the facts.
