Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Condition of the Contractor’s Property or Equipment The Contractor shall make the Property and/or equipment available to the Judicial Council, pursuant to the terms and conditions set forth in this Agreement. The Contractor shall immediately remedy any problem with the Property’s physical plant or equipment that impairs or diminishes the quality of the Program. The Contractor shall ensure the appropriate hot water, heating, and ventilation is provided at the Property during the Program, inclusive in the prices set forth herein.
Mortgaged Property Undamaged; No Condemnation Proceedings There is no proceeding pending or threatened for the total or partial condemnation of the Mortgaged Property. The Mortgaged Property is undamaged by waste, fire, earthquake or earth movement, windstorm, flood, tornado or other casualty so as to affect adversely the value of the Mortgaged Property as security for the Mortgage Loan or the use for which the premises were intended and each Mortgaged Property is in good repair. There have not been any condemnation proceedings with respect to the Mortgaged Property and the Seller has no knowledge of any such proceedings in the future;
Condition of Tangible Assets All buildings, structures, facilities, equipment and other material items of tangible property and assets included in the Assets are in good operating condition and repair, subject to normal wear and maintenance, are usable in the regular and ordinary course of business and conform to all applicable laws, ordinances, codes, rules and regulations relating to their construction, use and operation.
Insurance; Damage to or Destruction of Collateral (a) The Credit Parties shall, at their sole cost and expense, maintain the policies of insurance described on Disclosure Schedule 3.18 as in effect on the date hereof or otherwise in form and amounts and with deductibles as is customary for similarly situated businesses and with insurers reasonably acceptable to Agent. Agent and the Lenders confirm that the form, amounts and insurers described on Disclosure Schedule 3.18 are acceptable as of the Closing Date, and shall continue to be acceptable to Agent until not less than 30 days' prior written notice by Agent to Borrower to the contrary. Such policies of insurance (or the loss payable and additional insured endorsements delivered to Agent) shall contain provisions pursuant to which the insurer agrees to provide 30 days prior written notice to Agent in the event of any non-renewal, cancellation or amendment of any such insurance policy. If any Credit Party at any time or times hereafter shall fail to obtain or maintain any of the policies of insurance required above, or to pay all premiums relating thereto, Agent may at any time or times thereafter obtain and maintain such policies of insurance and pay such premiums and take any other action with respect thereto that Agent deems advisable. Agent shall have no obligation to obtain insurance for any Credit Party or pay any premiums therefor. By doing so, Agent shall not be deemed to have waived any Default or Event of Default arising from any Credit Party's failure to maintain such insurance or pay any premiums therefor. All sums so disbursed, including reasonable attorneys' fees, court costs and other charges related thereto, shall be payable on demand by Borrower to Agent and shall be additional Obligations hereunder secured by the Collateral.
(b) Agent reserves the right at any time (but not to be exercised more than once per Fiscal Year) upon (i) any material change in any Credit Party's risk profile (including any change in the product mix maintained by any Credit Party or any laws affecting the potential liability of such Credit Party), as determined by Agent in its commercially reasonable judgment, and (ii) not less than 30 days' prior written notice to Borrower, to require additional forms and limits of insurance to, in Agent's commercially reasonable judgment, adequately protect both Agent's and Lender's interests in all or any portion of the Collateral and to ensure that each Credit Party is protected by insurance in amounts and with coverage customary for its industry. If reasonably requested by Agent, each Credit Party shall deliver to Agent from time to time a report of a reputable insurance broker, reasonably satisfactory to Agent, with respect to its insurance policies.
(c) Each Credit Party shall deliver to Agent, in form and substance reasonably satisfactory to Agent, endorsements to (i) all "All Risk" and business interruption insurance naming Agent, on behalf of itself and Lenders, as lender loss payee or mortgagee (as the case may be), and (ii) all general liability and other liability policies naming Agent, on behalf of itself and Lenders, as additional insured. Each Credit Party irrevocably makes, constitutes and appoints Agent (and all officers, employees or agents designated by Agent), so long as any Event of Default has occurred and is continuing or the anticipated insurance proceeds exceed $1,000,000, as such Credit Party's true and lawful agent and attorney-in-fact for the purpose of making, settling and adjusting claims under such "All Risk" policies of insurance, endorsing the name of such Credit Party on any check or other item of payment for the proceeds of such "All Risk" policies of insurance and for making all determinations and decisions with respect to such "All Risk" policies of insurance. Agent shall have no duty to exercise any rights or powers granted to it pursuant to the foregoing power-of-attorney. Borrower shall promptly notify Agent of any loss, damage, or destruction to the Collateral in
(i) Borrower shall request a Revolving Credit Advance be made to Borrower in the amount requested to be released; (ii) so long as the conditions set forth in Section 2.2 have been met, Lenders shall make such Revolving Credit Advance; and (iii) in the case of insurance proceeds applied against the Revolving Loan, the Reserve established with respect to such insurance proceeds shall be reduced by the amount of such Revolving Credit Advance. To the extent not used to replace, repair, restore or rebuild the Collateral, such insurance proceeds shall be applied in accordance with Section 1.3(c).
Real Property Collateral; Judicial Reference Notwithstanding anything herein to the contrary, no dispute shall be submitted to arbitration if the dispute concerns indebtedness secured directly or indirectly, in whole or in part, by any real property unless (i) the holder of the mortgage, lien or security interest specifically elects in writing to proceed with the arbitration, or (ii) all parties to the arbitration waive any rights or benefits that might accrue to them by virtue of the single action rule statute of California, thereby agreeing that all indebtedness and obligations of the parties, and all mortgages, liens and security interests securing such indebtedness and obligations, shall remain fully valid and enforceable. If any such dispute is not submitted to arbitration, the dispute shall be referred to a referee in accordance with California Code of Civil Procedure Section 638 et seq., and this general reference agreement is intended to be specifically enforceable in accordance with said Section 638. A referee with the qualifications required herein for arbitrators shall be selected pursuant to the AAA’s selection procedures. Judgment upon the decision rendered by a referee shall be entered in the court in which such proceeding was commenced in accordance with California Code of Civil Procedure Sections 644 and 645.
Mortgaged Property Undamaged The Mortgaged Property is undamaged by waste, fire, earthquake or earth movement, windstorm, flood, tornado or other casualty so as to affect adversely the value of the Mortgaged Property as security for the Mortgage Loan or the use for which the premises were intended;
Required Liability Insurance; Personal Property During the full term of the Housing Agreement, Resident agrees to obtain and maintain at Resident’s expense a policy of personal liability insurance (i.e., renter’s liability insurance) from a licensed insurance carrier in the United States, with coverage of at least $100,000 per occurrence at actual replacement cost, covering Owner’s losses of any kind arising from fire, smoke or water and caused by Resident’s negligence and/or by Resident’s animal. The liability insurance requirement and the existence or limits of any such insurance will not reduce or supersede Resident’s obligations under this Housing Agreement, except to the extent Owner charges and Resident pays for a waiver of this insurance requirement as provided below. Resident is not obligated to purchase insurance from any specific provider and may arrange its own personal liability insurance policy from any insurer of Resident’s choosing meeting the requirements of this paragraph, in which case Resident agrees to provide written proof of the required personal liability insurance coverage, including causing Owner and Manager to be listed as named interested parties on such insurance coverage, by mailing the proof of insurance to P.O. Box 18999, Atlanta, GA 31126-1399. Owner will provide instructions prior to move-in for submitting proof of insurance or purchasing a compliant insurance policy; Resident’s failure to comply with these insurance requirements will be a breach by Resident with Owner reserving its remedies but will not give Resident any right of termination. If Resident fails or chooses not to provide sufficient proof of compliant personal liability insurance to Owner by the Start Date, or if Resident’s insurance is cancelled during the term of this Housing Agreement, then Owner may, at its option, waive Resident’s obligation to provide such insurance and obtain its own coverage in Owner’s name for the same limited risks (up to $100,000 per occurrence from fire, smoke or water damage caused accidentally by Resident’s negligence and/or by Resident’s animal) at Owner’s expense; in such case, Resident agrees to pay as consideration for this waiver to $15.00 per installment as additional Rent during the remaining term of this Agreement, of which Owner would retain up to $5.00 per installment as an administrative fee and use the remaining portion to procure such insurance for itself. This waiver is not insurance, does not release Resident from liability for other damage or causes and does not cover Resident’s personal property. Owner strongly recommends that Resident maintain insurance covering Resident’s personal property or belongings, which Resident may elect to purchase. Neither Owner nor any of its employees, representatives or agents assumes any liability, directly or indirectly, for loss or damage to the personal property of Resident or others by fire, theft or any other cause. Any personal property remaining in the bedroom space and/or apartment at the end of the Term or after earlier termination of this Agreement will be considered abandoned by Resident and may be disposed of by Owner at the risk and expense of Resident, with Owner maintaining a landlord’s lien for unpaid rent as provided by law. Owner will not be liable or responsible for storage or disposition of the Resident’s personal property. If there are multiple individuals comprising Resident, then all references to and obligations of Resident in this paragraph 8 will apply to each such individual, separately.
Access to Property, Property’s Management, Property Lender, and Property Tenants Potential Investor agrees to not seek to gain access to any non-public areas of the Property or communicate with Property’s management employees, the holder of any financing encumbering the Property, the Property’s tenants, and the Owner’s partners in the ownership of the Property, without the prior consent of Owner or JLL, which consent may be withheld in the Owner’s sole discretion.
