Forecasting Requirements for Trunk Provisioning Within ninety (90) days of executing this Agreement, Reconex shall provide Verizon a two (2) year traffic forecast. This initial forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Local Interconnection Trunk groups over the next eight (8) quarters. The forecast shall be updated and provided to Verizon on an as-needed basis but no less frequently than semiannually. All forecasts shall comply with the Verizon CLEC Interconnection Trunking Forecast Guide and shall include, at a minimum, Access Carrier Terminal Location (“ACTL”), traffic type (Local Traffic/Toll Traffic, Operator Services, 911, etc.), code (identifies trunk group), A location/Z location (CLLI codes for Reconex-IPs and Verizon-IPs), interface type (e.g., DS1), and trunks in service each year (cumulative).
Initial Forecasts/Trunking Requirements Because Verizon’s trunking requirements will, at least during an initial period, be dependent on the Customer segments and service segments within Customer segments to whom CSTC decides to market its services, Verizon will be largely dependent on CSTC to provide accurate trunk forecasts for both inbound (from Verizon) and outbound (to Verizon) traffic. Verizon will, as an initial matter, provide the same number of trunks to terminate Reciprocal Compensation Traffic to CSTC as CSTC provides to terminate Reciprocal Compensation Traffic to Verizon. At Verizon’s discretion, when CSTC expressly identifies particular situations that are expected to produce traffic that is substantially skewed in either the inbound or outbound direction, Verizon will provide the number of trunks CSTC suggests; provided, however, that in all cases Verizon’s provision of the forecasted number of trunks to CSTC is conditioned on the following: that such forecast is based on reasonable engineering criteria, there are no capacity constraints, and CSTC’s previous forecasts have proven to be reliable and accurate.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Balance Requirements To be a member and maintain Accounts with Us You must purchase 1 share in the Credit Union. The par value of a share in this Credit Union is $10.00. If the balance in Your primary savings Account drops below 1 share ($10.00), at any time, We may, at Our option, close Your Account. Nonsufficient Funds Returns. Any check or pre-authorized transfer, or transaction made through the use of a debit card, or other electronic means, as is applicable (including any in-person transaction), that is presented to Us for payment on Your Account when Your Account lacks sufficient collected funds to pay any such item may, at Our option, be returned for nonsufficient funds or We may honor any such item and charge You a fee for doing so. Overdraft Balance Calculation. When processing transactions that debit or credit Your Account, We start each Business Day with Your final Account balance from the preceding Business Day. The final balance takes into Account all of the debit and credit transactions that were settled that Business Day pursuant to Our Funds Availability Policy, as well as any other debits or credits to Your Account that were finally settled that day, as described above in the "Deposit of Items" and "Collection and Processing of Items" sections of the Account Agreement. This starting balance at the beginning of a Business Day (the preceding Business Day's final balance) is sometimes referred to as Your "actual balance." As credits and debits to Your Account are received by Us, We add them to and subtract them from Your actual balance. Examples of credits include, but are not limited to, electronic direct deposits, check deposits that have been fully and finally collected, ACH credits that have settled that day, and cash deposits made to one of Our tellers. Examples of debits include, but are not limited to, checks drawn on Your Account that are presented to Us for payment together with such checks that are returned unpaid and subsequently represented for payment, electronic fund transfer (EFT) debit transactions (such as preauthorized payments and settled EFT debits) and all reinitiated electronic fund transfer (EFT) debit transactions (such as preauthorized payments), memo-posted EFT debits (EFT debits that We have authorized but which have not been settled), and all Credit Union fees and charges. As noted above, these examples are not an exhaustive list and should not be construed as such. The result of this calculation at any given point in time is called Your "available balance." For the purpose of determining whether an overdraft has occurred, We use Your available balance. First, We add all of the settled credit transactions to the beginning actual balance. Then, We subtract all of the debit transactions that settled that day. We also subtract all of the pending debit transactions. This determines the available balance for overdraft purposes. Each debit transaction that We process when Your Account has, or will have, a negative available balance is an overdraft, subject to an overdraft charge. Subject to applicable law, You are responsible for paying any overdraft fees and charges assessed in connection with Our payment of an overdraft, as well as any NSF fees charged to Your Account when We dishonor and return an item for non- sufficient funds. It is Your responsibility to know Your Account balance, and if You have any questions You should contact a Credit Union representative.
Unusual Job Requirements of Short Duration The nature of health care is such that at times it may be necessary for an employee to perform work not normally required in his/her job for the safety, health or comfort of a client or resident. It is understood that an employee shall not be expected to perform a task for which he/she is not adequately trained.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Trunk Forecasting Requirements 14.2.1 Initial trunk forecast requirements. At least ninety (90) days before initiating interconnection in a LATA, Alltel shall provide Verizon a two (2)-year traffic forecast that complies with the Verizon Interconnection Trunking Forecast Guide, as revised from time to time. This initial traffic forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Interconnection Trunk groups in the LATA over the next eight (8) quarters.
C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.
