Fund's Right to Proceed Notwithstanding anything to the contrary contained herein, each Fund shall have, at its election upon reasonable notice to the Custodian, the right to enforce, to the extent permitted by any applicable agreement and applicable law, the Custodian's rights against any Subcustodian, Securities System, Eligible Securities Depository or other Person for loss, damage or expense caused such Fund by such Subcustodian, Securities System, Eligible Securities Depository or other Person, and shall be entitled to enforce the rights of the Custodian with respect to any claim against such Subcustodian, Securities System, Eligible Securities Depository or other Person, which the Custodian may have as a consequence of any such loss, damage or expense, if and to the extent that such Fund has not been made whole for any such loss or damage. If the Custodian makes such Fund whole for any such loss or damage, the Custodian shall retain the ability to enforce its rights directly against such Subcustodian, Securities System, Eligible Securities Depository or other Person. Upon such Fund's election to enforce any rights of the Custodian under this Section 5.05, such Fund shall reasonably prosecute all actions and proceedings directly relating to the rights of the Custodian in respect of the loss, damage or expense incurred by such Fund; provided that, so long as such Fund has acknowledged in writing its obligation to indemnify the Custodian under Section 5.03 hereof with respect to such claim, such Fund shall retain the right to settle, compromise and/or terminate any action or proceeding in respect of the loss, damage or expense incurred by such Fund without the Custodian's consent and provided further, that if such Fund has not made an acknowledgment of its obligation to indemnify, such Fund shall not settle, compromise or terminate any such action or proceeding without the written consent of the Custodian, which consent shall not be unreasonably withheld or delayed. The Custodian agrees to cooperate with each Fund and take all actions reasonably requested by such Fund in connection with such Fund's enforcement of any rights of the Custodian. Each Fund agrees to reimburse the Custodian for all reasonable out-of-pocket expenses incurred by the Custodian on behalf of such Fund in connection with the fulfillment of its obligations under this Section 5.05; provided, however, that such reimbursement shall not apply to expenses occasioned by or resulting from the negligence, misfeasance or misconduct of the Custodian.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Right to Offset If We make a claim payment to You or on Your behalf in error or You owe Us any money, You must repay the amount You owe Us. Except as otherwise required by law, if We owe You a payment for other claims received, We have the right to subtract any amount You owe Us from any payment We owe You.
MAXIMUM COST TO COUNTY In no event will the cost to County for the services to be provided herein exceed the maximum sum of $ including direct non-salary expenses. As set forth in section 14 of this Contract, should the funding source for this Contract be reduced, Contractor agrees that this maximum cost to County may be amended by written notice from County to reflect that reduction.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
Right to Set Off Notwithstanding anything to the contrary in this License Agreement, each Party has the right at all times to retain and set off against all amounts due and owing to the other Party as determined in a final judgment any damages recovered by such Party for any Losses incurred by such Party.
Landlord’s Right to Terminate Landlord shall have the option to terminate this Lease in the event any of the following occurs, which option may be exercised only by delivery to Tenant of a written notice of election to terminate within thirty days after the date of such damage or destruction:
(a) The Building is damaged by any peril covered by valid and collectible insurance actually carried by Landlord and in force at the time of such damage or destruction or by any peril which would have been covered by the insurance Landlord is required to maintain pursuant to Section 9.2 (an "Insured Peril") to such an extent that the estimated cost to restore the Building exceeds the lesser of (i) the insurance proceeds available from insurance actually carried by Landlord (or which Landlord was required to carry pursuant to Section 9.2(a) hereof) plus the amount of any deductible (up to a maximum amount of five percent (5%) of the replacement cost of the Building), plus any amount that the Tenant agrees in writing to contribute towards restoration, or (ii) fifty percent of the then actual replacement cost of the Building;
(b) The Building is damaged by an uninsured peril, which peril Landlord was not required to insure against pursuant to the provisions of Article 9 of this Lease, provided, however, that, subject to the requirements of the holder of any deed of trust encumbering the Property, Landlord shall not have the right to terminate this Lease if Tenant notifies Landlord, within thirty (30) days after Tenant receives Landlord's written notice of termination pursuant to this Section 10.3, that Tenant will pay for the cost of restoration of the Leased Premises, in excess of any insurance proceeds to be received by Landlord.
(c) The Building is damaged by any peril and, because of the laws then in force, the Building (i) cannot be restored at reasonable cost or (ii) if restored, cannot be used for the same use being made thereof before such damage.
Right to Proceed The Sponsor acknowledges the rights of Holders to institute a Direct Action as set forth in Section 2.8(d) hereto.
STUDENT’S RIGHT TO CANCEL You have the right to cancel this agreement and obtain a refund of charges paid through the attendance at the first class session, or the seventh day after enrollment, whichever is later.
