Indemnification for Third Party Claims
(a) Seller shall defend, indemnify and hold harmless Buyer, its shareholders and Affiliates, and their respective directors, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance by any Project Party of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Seller, the Contractor, any Subcontractor, and its respective employees or agents.
(b) Buyer shall defend, indemnify and hold harmless Seller and its managers, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Buyer, its employees or agents.
(c) Either Party seeking indemnification under this Agreement (the “Indemnified Party”) shall give notice to the Party required to provide indemnification hereunder (the “Indemnifying Party”) promptly after the Indemnified Party has actual knowledge of any Claim as to which indemnity may be sought hereunder, and the Indemnified Party shall permit the Indemnifying Party (at the expense of the Indemnifying Party) to assume the defense of any Claim or litigation resulting therefrom; provided that:
(i) counsel for the Indemnifying Party who shall conduct the defense of such Claim or litigation shall be reasonably satisfactory to the Indemnified Party;
(ii) the Indemnified Party may participate in such defense at its own expense, except the Indemnifying Party shall reimburse the Indemnified Party for its participation in such defense to the extent that the Indemnifying Party requests the Indemnified Party to participate in its own defense; and
(iii) the omission by the Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligations hereunder except to the extent that such omission results in a failure of actual notice to the Indemnifying Party and Indemnifying Party is damaged as a result of such failure to give notice. Notwithstanding the foregoing, the Indemnifying Party may not settle any Claim related to the indemnity being provided hereunder without the consent of the Indemnified Party, such consent not to be unreasonably withheld.
(d) With regard to any Claim or Liability which is the result of the joint or concurrent fault or negligence of Seller and Buyer, the Parties agree to jointly defend any Claim with respect thereto that is based on such joint or concurrent fault or negligence of Buyer and Seller. Any Claim of contribution or indemnification between Buyer and Seller relating to such Claims shall be resolved on the basis of the percentage of fault or negligence and the Parties agree to reserve the determination of such percentage until after resolution of such Claim. Such pro rata share shall be based upon a final judicial determination of the Parties’ comparative fault or negligence or, in the absence of such determination, by mutual agreement.
(e) Nothing in this Section 26.1 is intended to allow any Indemnified Party to be indemnified from and against any third party Claims and Liabilities caused by, arising out of, or in connection with the performance of this Agreement to the extent any of such Claims or Liabilities were caused by, arose out of, or were in any way incidental to or in connection with its own negligence or intentional misconduct.
Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
1.2 Our obligations under this Section G(1) will not apply to the extent the claim or adverse final judgment is based on your use of the Tyler Software in contradiction of this Agreement, including with non-licensed third parties, or your willful infringement.
1.3 If we receive information concerning an infringement or misappropriation claim related to the Tyler Software, we may, at our expense and without obligation to do so, either: (a) procure for you the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent, in which case you will stop running the allegedly infringing Tyler Software immediately. Alternatively, we may decide to litigate the claim to judgment, in which case you may continue to use the Tyler Software consistent with the terms of this Agreement.
1.4 If an infringement or misappropriation claim is fully litigated and your use of the Tyler Software is enjoined by a court of competent jurisdiction, in addition to paying any adverse final judgment (or settlement to which we consent), we will, at our option, either: (a) procure the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent. This section provides your exclusive remedy for third party copyright, patent, or trademark infringement and trade secret misappropriation claims.
Indemnification by Licensor Licensor shall defend, indemnify and hold harmless Licensee and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensee Parties”) from and against any claim, suit, demand or action (“Action”), and any and all direct losses suffered or incurred by Licensee in connection with any third party claims (a) arising out of or resulting from any breach by Licensor of any provision of this Agreement or (b) that use of the Licensed Marks by Licensee in accordance with the terms and conditions of this Agreement infringes or otherwise violates a third party’s Trademarks. Licensor’s obligation to indemnify Licensee shall be conditioned on (a) Licensee’s provision to Licensor of prompt notice of such an Action (except where any delay does not materially prejudice Licensor); (b) Licensee’s reasonable cooperation with Licensor in the defense and settlement of such an Action at Licensor’s cost; and (c) Licensor having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensor may not settle any Action in a manner that adversely affects Licensee without Licensee’s prior written consent, not to be unreasonably withheld or delayed).
Licensee Indemnification Licensee will indemnify, defend and hold harmless UM, its trustees, officers, agents and employees (collectively, the “Indemnified Parties”), from and against any and all liability, loss, damage, action, claim or expense suffered or incurred by the Indemnified Parties which results from or arises out of third party claims in connection with (individually, a “Liability” and collectively, the “Liabilities”):
(a) breach by Licensee of any duty, covenant or agreement contained in this Agreement or a lawsuit, action, or claim brought by any third party that includes any allegation which, if proven true, would constitute a breach by Licensee of any duty, covenant or agreement contained in this Agreement;
(b) the development, use, manufacture, promotion, sale, distribution or other disposition of any Products by Licensee, its Affiliates, assignees, vendors or other third parties, for personal injury, including death, or property damage arising from any of the foregoing. The indemnification obligation under Article 6.3 shall not apply to any contributory negligence or product liability of the Indemnified Party which may have occurred prior to the execution of this Agreement. Licensee will indemnify and hold harmless the Indemnified Parties from and against any Liabilities resulting from:
(i) any product liability or other claim of any kind related to the use by a third party of a Product that was manufactured, sold, distributed or otherwise disposed by Licensee, its Affiliates, assignees, vendors or other third parties;
(ii) clinical trials or studies conducted by or on behalf of Licensee relating to any Products, including, without limitation, any claim by or on behalf of a human subject of any such clinical trial or study, any claim arising from the procedures specified in any protocol used in any such clinical trial or study, any claim of deviation, authorized or unauthorized, from the protocols of any such clinical trial or study, any claim resulting from or arising out of the manufacture or quality control by a third party of any substance administered in any clinical trial or study;
(iii) Licensee’s failure to comply with all prevailing laws, rules and regulations pertaining to the development, testing, manufacture, marketing and import or export of Products.
INDEMNIFICATION FOR INFRINGEMENT The terms of this Section 10 do not apply to the Community Edition Licensees. Licensor will defend or settle, at its own expense, any claim against Licensee asserting a copyright, trademark or trade secret which concerns the Product used within the scope of the Agreement hereunder. Licensor shall indemnify Licensee against any loss, expense or liability including reasonable attorney's fees from any damages alleged against Licensee. Licensor's obligations under this Section are conditioned on Licensee promptly notifying Licensor in writing after Licensee first receives notice of any such claim, action or allegation of infringement and, Licensor being given sole control of the defense of any action and all negotiations for its settlement or compromise, with the reasonable assistance of Licensee. Licensor shall not be liable for any costs or expenditures incurred by Licensee without Licensor's prior written consent. If an injunction or order is obtained against Licensee's use of the Product by reason of the allegations of infringement, or if in Licensor's opinion the Product is likely to become the subject of a claim of infringement, Licensor shall, at its expense:
(a) Procure for Licensee the right to continue using the Product; or
(b) Modify or replace the Product with a compatible, functionally equivalent, non-infringing Product(s); or
(c) If neither (a) nor (b) is reasonably practical in Licensor's judgment, remove the Product and issue Licensee a pro rata credit based upon the License fees paid for the Product prorated over a thirty-six (36) month period from the date of shipment of the Product. Thereafter, termination shall proceed in accordance with the terms of Section 4. Licensor shall have no obligation under this Section to the extent the alleged infringement results from (i) modification of the Product other than by Licensor; (ii) the combination of the Product with products not provided by Licensor; or (iii) use of any older version of the Product when use of a newer version made available to Licensee would have avoided the infringement. This Section 10 is Licensor's entire liability and Licensee's sole and exclusive remedy in the event of intellectual property infringement of any kind.
Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined).
22.1.1 For purposes of this Section 22, Claim means any action, cause of action, suit, proceeding, claim, or demand of any third party (and all resulting judgments, bona fide settlements, penalties, damages, losses, liabilities, costs, and expenses including, but not limited to, reasonable costs and attorneys’ fees),
(a) based on allegations that, if true, would establish
(i) the Indemnifying Party’s breach of this Agreement;
(ii) the Indemnifying Party’s misrepresentation, fraud or other misconduct;
(iii) the Indemnifying Party’s negligent or willful misconduct or omissions;
(iv) infringement by the Indemnifying Party or by any Indemnifying Party product or service of any patent, copyright, trademark, service mark, trade name, right of publicity or privacy, trade secret, or any other proprietary right of any third party;
(v) the Indemnifying Party’s liability in relation to any wrongful disclosure of private or personal matters or material which is defamatory; or
(vi) the Indemnifying Party’s wrongful use or unauthorized disclosure of data; or
(b) that arises out of:
(i) any act or omission of the Indemnifying Party or its subcontractors or agents relating to the Indemnifying Party’s performance or obligations under this Agreement or the Indemnifying Party’s use of any services or facilities obtained from or provided by the other Party under this Agreement;
(ii) any act or omission of the Indemnifying Party’s customer(s) or End User(s) pertaining to the services or facilities provided under this Agreement;
(iii) the bodily injury or death of any person, or the loss or disappearance of or damage to the tangible property of any person, relating to the Indemnifying Party’s performance or obligations under this Agreement;
(iv) the Indemnifying Party’s design, testing, manufacturing, marketing, promotion, advertisement, distribution, lease or sale of services and/or products to its customers, or such customers’ use, possession, or operation of those services and/or products; or
(v) personal injury to or any unemployment compensation claim by one or more of the Indemnifying Party’s employees, notwithstanding any protections the Indemnifying Party might otherwise have under applicable workers’ compensation or unemployment insurance law, which protections the Indemnifying Party waives, as to the Indemnified Party and other persons and entities to be indemnified under this Section (other than applicable employee claimant(s)).
22.1.2 For purposes of this Section, Reasonable costs and attorneys’ fees, as used in this Section, includes without limitation fees and costs incurred to interpret or enforce this Section.
22.1.3 The Indemnified Party will provide the Indemnifying Party with reasonably prompt written notice of any Claim. At the Indemnifying Party’s expense, the Indemnified Party will provide reasonable cooperation to the Indemnifying Party in connection with the defense or settlement of any Claim. The Indemnified Party may, at its expense, employ separate counsel to monitor and participate in the defense of any Claim.
Exception to Right of Indemnification or Advancement of Expenses Notwithstanding any other provision of this Agreement, Indemnitee shall not be entitled to indemnification or advancement of Expenses under this Agreement with respect to any Proceeding, or any claim therein, brought or made by him against the Company.
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless the INFI Indemnitees from and against any and all losses, damages, fees, expenses, settlement amounts or costs (including reasonable legal expense, attorneys’ fees and witness fees) (“Losses”) relating to or in connection with a Third Party claim to the extent arising out of (a) the research, development, manufacture or commercialization of the IPI-145 Compound or the IPI-145 Product by Licensee, any Licensee Affiliate, any Sublicensee, INFI (to the extent properly acting in accordance with Licensee’s express direction) or any of their respective employees, consultants, contractors, subcontractors or agents after the Effective Date, including any actual or alleged death, personal bodily injury or damage to real or tangible personal property, or other product liability claimed to result from the IPI-145 Product Researched, Developed, Manufactured or Commercialized by or on behalf of Licensee or any of its Affiliates or any Sublicensee, (b) any breach by Licensee of any of its representations, warranties, covenants or obligations under this Agreement, or (c) any negligent act or omission or willful misconduct of Licensee, any of its Affiliates or any Sublicensee, or any of their respective employees, consultants, contractors, subcontractors or agents, in performing Licensee’s obligations or exercising Licensee’s rights under this Agreement; except that the foregoing indemnity shall not apply with respect to any INFI Indemnitee to the extent that any such Losses (x) are caused by the gross negligence or willful misconduct of any INFI Indemnitee, or (y) are otherwise subject to an obligation by INFI to indemnify the Licensee Indemnitees under Section 10.2.
Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.
