Infringement and Defense of Licensee SAP shall defend Licensee against claims brought against Licensee in the Territory by any third party alleging that Licensee's Use of the Software, in accordance with the terms and conditions of this Agreement, constitutes a direct infringement or misappropriation of such third party’s patent claim(s), copyright or trade secret rights, and SAP will pay damages finally awarded against Licensee (or the amount of any settlement SAP enters into) with respect to such claims. This obligation of SAP shall not apply if the alleged infringement or misappropriation results from (i) Use of the Software in conjunction with any other software; (ii) Use of the Software with an apparatus other than a Designated Unit; (iii) failure to promptly use an update provided by SAP if such infringement or misappropriation could have been avoided by use of the update; or (iv) any Use not permitted by this Agreement. This obligation of SAP also shall not apply if Licensee fails to timely notify SAP in writing of any such claim; however Licensee’s failure to provide or delay in providing such notice shall not relieve SAP of its obligations under this Section except to the extent SAP is prejudiced by Licensee’s failure to provide or delay in providing such notice. SAP is permitted to control fully the defense and any settlement of any such claim as long as such settlement shall not include a financial obligation on or admission of liability by Licensee. In the event Licensee declines SAP’s proffered defense, or otherwise fails to give full control of the defense to SAP’s designated counsel, then Licensee waives SAP’s obligations under this Section 8.1. Licensee shall reasonably cooperate in the defense of such claim and may appear, at its own expense, through counsel reasonably acceptable to SAP. SAP expressly reserves the right to cease such defense of any claim(s) in the event the Software is no longer alleged to infringe or misappropriate, or is held not to infringe or misappropriate, the third party’s rights. SAP may settle or mitigate damages from any claim or potential claim by substituting alternative substantially equivalent non-infringing programs and supporting documentation for the Software. Licensee shall not undertake any action in response to any infringement or misappropriation, or alleged infringement or misappropriation of the Software that is prejudicial to SAP’s rights.
Defense of Third Party Claims Upon receipt by the Indemnifying Party of a notice from the Indemnified Party with respect to any claim of a third party against the Indemnified Party, for which the Indemnified Party seeks indemnification hereunder, the Indemnifying Party shall have the right to assume the defense of such claim, and the Indemnified Party shall cooperate to the extent reasonably requested by the Indemnifying Party in defense or prosecution thereof and shall furnish such records, information and testimony and attend all such conferences, discovery proceedings, hearings, trials and appeals as may be reasonably requested by the Indemnifying Party in connection therewith. If the Indemnifying Party shall elect to assume the defense of such claim, the Indemnified Party shall have the right to employ its own counsel in any such case, but the fees and expenses of such counsel shall be at the expense of the Indemnified Party. If the Indemnifying Party has assumed the defense of any claim against the Indemnified Party, the Indemnifying Party shall have the right to settle any claim for which indemnification has been sought and is available hereunder; provided that, to the extent that such settlement requires the Indemnified Party to take, or prohibits the Indemnified Party from taking, any action or purports to obligate the Indemnified Party, then the Indemnifying Party shall not settle such claim without the prior written consent of the Indemnified Party, such consent not to be unreasonably withheld, conditioned or delayed. If the Indemnifying Party does not assume the defense of a third party claim and disputes the Indemnified Party’s right to indemnification, the Indemnified Party shall have the right to assume control of the defense of such claim through counsel of its choice, the reasonable costs of which shall be at the Indemnifying Party’s expense in the event that the Indemnified Party’s right of indemnification is ultimately established through settlement, compromise or other legal proceeding. In no circumstance may the Indemnified Party compromise or settle a claim with a third party for which it seeks indemnification from the Indemnifying Party without first obtaining the prior written consent of the Indemnifying Party, such consent not to be unreasonably withheld, conditioned or delayed.
WAIVER OF NEGOTIATIONS The Board and Union acknowledge that during negotiations resulting in this Agreement, each party had the right and opportunity to make demands and proposals with respect to any matter and that this Agreement was arrived at by the parties after the exercise of that right and opportunity. The Board and the Union shall voluntarily waive, during the life of this Agreement said rights and each agrees that the other shall not be obligated to negotiate with respect to any subject or matter irrespective of whether such matters or subject is specifically referred to or covered in this agreement, even though such subject or matter may not have been within the knowledge or contemplation of either or both parties at the time negotiations were being conducted or at the time the party signed this Agreement.
Certification Regarding Prohibition of Boycotting Israel (Tex Gov. Code 2271) If (a) Vendor is not a sole proprietorship; (b) Vendor has ten (10) or more full-time employees; and (c) this Agreement or any agreement with a TIPS Member under this procurement has value of $100,000 or more, the following certification shall apply; otherwise, this certification is not required. Vendor certifies, where applicable, that neither the Vendor, nor any affiliate, subsidiary, or parent company of Vendor, if any, boycotts Israel, and Vendor agrees that Vendor and Vendor Companies will not boycott Israel during the term of this Agreement. For purposes of this Agreement, the term “boycott” shall mean and include refusing to deal with, terminating business activities with, or otherwise taking any action that is intended to penalize, inflict economic harm on, or limit commercial relations with Israel, or with a person or entity doing business in Israel or in an Israeli-controlled territory but does not include an action made for ordinary business purposes. When applicable, does Vendor certify? Yes
Claims relating to Intellectual Property Rights 29.1. The Contractor must not infringe any Intellectual Property Rights of any third party in providing the Services or otherwise performing its obligations under the Framework Agreement and must ensure that the provision of the Services and the use or possession of the Deliverables does not infringe such Intellectual Property Rights.
Scope of Negotiations The District and SEIU/FPSU agree to negotiate those items as prescribed by law.
Extent of Cooperation (1) Prior to December 31, 2017, Counsel for the Settling Defendants met with Class Counsel in Canada or the United States, to provide an oral evidentiary proffer which included information originating with the Settling Defendants that was not covered by privilege relating to the allegations in the Proceedings. Notwithstanding any other provision of this Settlement Agreement, and for greater certainty, it is agreed that all statements made and information provided by Counsel for the Settling Defendants are privileged, will be kept strictly confidential, may not be directly or indirectly disclosed to any other Person, unless disclosure is ordered by a Court. Further, absent a Court order, Class Counsel will not attribute any factual information obtained from the proffer to the Settling Defendants and/or Counsel for the Settling Defendants. Notwithstanding the foregoing, Class Counsel may: (i) use information obtained from the proffer in the prosecution of the Proceedings, including for the purpose of developing an allocation plan relating to any settlement or judgment proceeds, except the prosecution of any claims against Releasees; and (ii) may rely on such information to certify that, to the best of Class Counsel’s knowledge, information and belief, such information has evidentiary support or will likely have evidentiary support after reasonable opportunity for further investigation or discovery, but, absent a Court Order, the Plaintiffs shall not introduce any information from a proffer into the record or subpoena any Counsel for the Settling Defendants related to a proffer.
Exclusion de garanties A. Si vous êtes un client qui est un consommateur (quelqu’un qui utilise le Logiciel Apple en dehors de son commerce, son entreprise ou sa profession), il se peut que vous bénéficiez, dans votre pays de résidence, de droits selon lesquels les limitations suivantes ne s’appliqueraient pas à vous.Dans les pays où ces limitations sont interdites, elles ne s’appliquent pas. Pour en savoir plus sur vos droits, prenez contact avec un organisme local de conseil aux consommateurs.
INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
The Contracts (Rights of Third Parties) Xxx 0000 A person who is not party to this Contract has no right under the Contracts (Rights of Third Parties) Xxx 0000 to enforce any term of this Contract but this does not affect any right or remedy of any person which exists or is available otherwise than pursuant to that Act.
