Claims A. To accept HHSC's reimbursement rates as payment in full for the services specified in this Contract to the persons for whom a payment is received, and to make no additional charge to the individual, any member of their family or to any other source for any supplementation for such services, unless specifically allowed by HHSC rules.
Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.
Disputed Claims 4.1 Notwithstanding paragraph 4.5 of this Schedule, payment by the Authority of all or any part of any invoice rendered or other claim for payment by the Contractor shall not signify approval of such invoice/claim. The Authority reserves the right to verify invoices/claims after the date of payment and subsequently to recover any sums which have been overpaid.
Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.
Product Claims You acknowledge that Company, not an App Distributor, is responsible for addressing any claims of yours or any third party relating to the Company application or your possession and/or use of the Company application, including, but not limited to: (i) product liability claims; (ii) any claim that the Company application fails to conform to any applicable legal or regulatory requirement; and (iii) claims arising under consumer protection or similar legislation. (5)
Warranty Claims This Contractual Warranty is provided by Xxxxxxxxx Electric and covers defects in workmanship and materials in your Product. This warranty period lasts from the date of purchase at the point of sale to you, the original end user, unless otherwise agreed in writing (the "Warranty Period"). This Contractual Warranty is transferable to subsequent owners but only for the unexpired portion of the Warranty Period.
LIENS, CLAIMS AND ENCUMBRANCES The Contractor warrants and represents that all materials, equipment or services delivered herein are free and clear of all liens, claims, or encumbrances of any kind.
Unknown Claims Executive acknowledges that Executive has been advised to consult with legal counsel and that Executive is familiar with the principle that a general release does not extend to claims that the releaser does not know or suspect to exist in his or her favor at the time of executing the release, which, if known by him or her, must have materially affected his or her settlement with the releasee. Executive, being aware of this principle, agrees to expressly waive any rights Executive may have to that effect, as well as under any other statute or common law principles of similar effect.]3
Product Warranty Claims When we receive a valid warranty claim for an HP hardware or software product, HP will either repair the relevant defect or replace the product. If HP is unable to complete the repair or replace the product within a reasonable time, Customer will be entitled to a full refund upon the prompt return of the product to HP (if hardware) or upon written confirmation by Customer that the relevant software product has been destroyed or permanently disabled. HP will pay for shipment of repaired or replaced products to Customer and Customer will be responsible for return shipment of the product to HP.
