Supply of Product 4.1 DAEWOONG shall manufacture and supply Product to AEON in a primary packaged and labeled form. Product packaging shall display the logo of DAEWOONG (to the extent required by applicable law) and AEON and the outer label shall be marked using English language in accordance with applicable laws and Product’s Regulatory Approvals.
4.2 AEON’s estimate sales forecast of the Product during the Term of Agreement in the Territory in the Field is set forth in Annex D. Within ninety (90) days after the Effective Date, AEON shall provide DAEWOONG with a non-binding twelve (12) month rolling forecast of its requirements of Product, which the Parties agree is not a commitment to buy any stated quantity. Thereafter, on at least a quarterly basis, AEON shall provide DAEWOONG with an updated twelve (12) month rolling forecast, together with a binding six (6) month forecast to the extent AEON has requested Safety Stock as described in Article 4.10 below. Each such forecast shah be referred to herein as a “Forecast.”
4.3 AEON may from time to time submit Purchase Orders to DAEWOONG for Product in accordance with the forecasting requirements in Article 4.2. Orders will be shipped on CIF Los Angeles port.
4.4 Once a Purchase Order for Product and Product Samples has been received by DAEWOONG, it shall be considered as irrevocable.
4.5 AEON agrees herein to place an Order for Product not later than [***] from receipt of Regulatory Approval.
4.6 Individual Purchase Orders of Product shall be placed at least [***] in advance of the required delivery date.
4.7 For the purpose of Commercialization, AEON will store and maintain the full quantity of Product in a clean, secured area in accordance with the reasonable directions and specifications provided by DAEWOONG in writing in connection thereof in the Territory. AEON will advise DAEWOONG on the applicable requirements specifically deriving from the laws and regulations in the Territory.
4.8 AEON agrees that DAEWOONG and its collaborators and agents, in DAEWOONG’s sole discretion, which collaborators and Agents will be subject to appropriate obligations of confidentiality, will have the right upon reasonable prior notice, to observe and to inspect and to audit AEON’s facility to ascertain compliance by AEON with the terms of this Agreement, including without limitation (a) the holding facilities for Product, and (b) AEON’s compliance with applicable law, including cGMP (if applicable). Following any such audit, DAEWOONG will discuss its observations and conclusions with AEON and corrective actions, if any, will be agreed upon by the Parties, and executed by AEON using Commercially Reasonable Efforts.
4.9 In addition to any other rights and remedies available to AEON, AEON shall have the right to recover lost profits in the event that DAEWOONG fails to deliver at least [***] in any [***] (a “Supply Default Event”). For purposes of this provision, lost profits would be equal to [***] of AEON operating profit (sales less direct expenses and the puce paid by AEON for such Products) on Products that have not been shipped against firm Purchase Orders during the period leading up to the Supply Default Event and bona fide Purchase Orders submitted by AEON that are consistent with the Forecast during the Supply Default Period (as defined below). Such payment shall be made with respect to all Product not shipped in the period giving rise to the Supply Default and for the period until DAEWOONG is again timely shipping Product to meet AEON’s needs (the “Supply Default Period”). The first such payment shall be made within [***] of the Supply Default Event, and every [***] thereafter. AEON agrees to permit full disclosure to DAEWOONG of AEON’s accounting records, solely related to the calculation of lost profits, for the [***] ending on the first day of the month in which the Supply Event Default occurred. In the event that DAEWOONG is unable to supply both AEON’s requirements of Product and its own and third parties’ requirements for Product, DAEWOONG shall allocate Product that DAEWOONG has in inventory and that DAEWOONG is able to Product, so that AEON receives its requirements of Product in priority to DAEWOONG and third parties.
4.10 At the request of AEON, DAEWOONG shall at its own cost and expense during the Term, maintain an amount of inventory of Product equal to AEON’s requirements for Product for [***] based on AEON’s most recent forecast (“Safety Stock”). The Safety Stock shall be (i) maintained for the sole benefit of AEON and its Affiliates, (ii) shall be stored at a secure facility in compliance with GMP, and (iii) shall not be used for the benefit of any other customer of DAEWOONG. DAEWOONG shall rotate the Safety Stock on a “First Expiry-First Out” basis for routine fulfillment of firm orders, subject to Article 7.
Supply of Products
3.1 The Supplier warrants that the Products shall:
(a) correspond with their description and any applicable Product Specification;
(b) conform in all respects with the Order and any relevant sample;
(c) be of satisfactory quality and fit for any purpose held out by the Supplier or made known to the Supplier by Ornua, expressly or by implication, and in this respect Ornua relies on the Supplier's skill and judgement;
(d) be manufactured by properly trained and qualified personnel using all reasonable skill, care and diligence and in a good and workmanlike manner;
(e) where they are manufactured products, be free from defects in design, materials and workmanship and remain so for the period set out in the Product Specification or, if none is specified, for at least 12 months after delivery;
(f) comply with all applicable statutory and regulatory requirements relating to the manufacture, labelling, packaging, storage, handling and delivery of the Products;
(g) comply with all relevant standards including any UK Standards, European Standards or International Standards applicable in the UK and the country or State where the Products are to be used; and
(h) in the case of Products containing food stuffs, when delivered to Ornua, comply with all applicable food and hygiene legislation and regulations and best industry practice.
3.2 The Supplier shall ensure that at all times it has and maintains all licences, permissions, authorisations, consents and permits needed to carry out its obligations under the Contract in respect of the supply of Products. Breach of this Condition shall be deemed a material breach of the Contract.
3.3 Ornua may inspect and test the Products at any time before delivery. The Supplier shall remain fully responsible for the Products despite any such inspection or testing and any such inspection or testing shall not reduce or otherwise affect the Supplier's obligations under the Contract.
3.4 If following such inspection or testing Ornua considers that the Products do not comply or are unlikely to comply with the Supplier's undertakings at clause 3.1, Ornua shall inform the Supplier and the Supplier shall immediately take such remedial action as is necessary to ensure compliance.
3.5 Ornua may conduct further inspections and tests after the Supplier has carried out its remedial actions.
Conformity of production 8.1. Procedures concerning conformity of production shall comply with those set out in the 1958 Agreement, Schedule 1 (E/ECE/TRANS/505/Rev.3) and meet the following requirements:
8.2. A vehicle approved pursuant to this Regulation shall be so manufactured as to conform to the type approved by meeting the requirements of paragraph 5. above;
8.3. The Type Approval Authority which has granted approval may at any time verify the conformity of control methods applicable to each production unit. The normal frequency of such inspections shall be once every two years.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Manufacture of Products All Products marketed through Grantor's Web ------------------------- Site shall be manufactured, packaged, prepared, and shipped in accordance with the specifications and requirements described on Exhibit A hereto as it may be modified from time to time. Quality control standards relating to the Product's weight, color, consistency, micro-biological content, labeling and packaging are also set forth on Exhibit A. In the event that Exhibit A is incomplete, Products shall be manufactured and shipped in accordance with industry standards.
Reformulation of Products As of the Effective Date, and continuing thereafter, Products that Xxxxx directly manufactures, imports, distributes, sells, or offers for sale in California shall either: (a) be Reformulated Products pursuant to § 2.2, below; or (b) be labeled with a clear and reasonable exposure warning pursuant to §§ 2.3 and 2.4, below. For purposes of this Settlement Agreement, a “Reformulated Product” is a Product that is in compliance with the standard set forth in
Licensed Product The term “Licensed Product” shall mean any product (a) the manufacture, use, importation, sale or offer for sale of which would, in the absence of the license granted by this Agreement, infringe a Valid Claim of any of the Licensed Patent Rights, or (b) that is comprised of, utilizes or incorporates Licensed Biological Materials, or (c) that is discovered, developed or made using a Licensed Process.
Commercialization Reports Throughout the term of this Agreement and during the Sell-Off Period, and within thirty (30) days of December 31st of each year, Company will deliver to University written reports of Company’s and Sublicensees’ efforts and plans to develop and commercialize the innovations covered by the Licensed Rights and to make and sell Licensed Products. Company will have no obligation to prepare commercialization reports in years where (a) Company delivers to University a written Sales Report with active sales, and (b) Company has fulfilled all Performance Milestones. In relation to each of the Performance Milestones each commercialization report will include sufficient information to demonstrate achievement of those Performance Milestones and will set out timeframes and plans for achieving those Performance Milestones which have not yet been met.
Commercialization Intrexon shall have the right to develop and Commercialize the Reverted Products itself or with one or more Third Parties, and shall have the right, without obligation to Fibrocell, to take any such actions in connection with such activities as Intrexon (or its designee), at its discretion, deems appropriate.
Commercialization License Subject to the terms of this Agreement, including without limitation Section 2.2 and Theravance's Co-Promotion rights in Section 5.3.2, Theravance hereby grants to GSK, and GSK accepts, an exclusive license under the Theravance Patents and Theravance Know-How to make, have made, use, sell, offer for sale and import Alliance Products in the Territory.
