Sales No Partnerships Delay Rentals
Sales No Partnerships Delay Rentals Sample Clauses
Related to Sales No Partnerships Delay Rentals
Basic Rental Tenant agrees to pay to Landlord during the ------------- Term hereof, at Landlord's office or to such other person or at such other place as directed from time to time by written notice to Tenant from Landlord, the initial monthly and annual sums as set forth in Article 1.C of the Basic Lease Provisions, payable in advance on the first day of each calendar month, without demand, setoff or deduction, and in the event this Lease commences or the date of expiration of this Lease occurs other than on the first day or last day of a calendar month, the rent for such month shall be prorated. Notwithstanding the foregoing, the first full month's Basic Rental shall be paid to Landlord in accordance with Article 1.J. of the Basic Lease Provisions.
Base Rental (a) Lessee hereby agrees to pay to Lessor, without setoff or deduction whatsoever, a monthly installment of $3,284.00. Lessee shall also pay, as additional rent, all such other sums of money as shall become due from and payable by Lessee to Lessor under this Lease (Base Rental, any adjustment thereto pursuant to Section 4 hereof, and all such other sums of money due from and payable by Lessee pursuant to this Lease are sometimes hereinafter collectively called "rent"), for the nonpayment of which Lessor shall be entitled to exercise all such rights and remedies as are herein provided in the case of the nonpayment of Base Rental. The Base Rental, together with any adjustment or increase thereto then in effect, shall be due and payable in advance in twelve (12) equal installments on the first (lst) day of each calendar month during the term of this Lease, and Lessee hereby agrees so to pay such Base Rental and any adjustment or increase thereto to Lessor at Lessor's address provided herein (or such other address as may be designated by Lessor in writing from time to time) monthly, in advance, and without demand. If the term of this Lease commences on a day other than the first (lst) day of a month or terminates on a day other than the last day of a month, then the installments of Base Rental and any adjustments thereto for such month or months shall be prorated, and the installment or installments so prorated shall be paid in advance.
PARTNERSHIP TENANT If Tenant, or a permitted assignee of this Lease pursuant to Article 16, is a partnership, or is comprised of two or more Persons, individually or as partners of a partnership (any such partnership and such Persons are referred to in this Article 29 as “Partnership Tenant”), the following shall apply: (i) the liability of each of the general partners (excluding Persons solely holding interests as limited partners), each of the partners in a limited liability partnership or Persons comprising Partnership Tenant (the “Partners”) shall be joint and several (subject to the inherent limitations of liability of such business organization); (ii) each of the Partners hereby consents in advance to, and agrees to be bound by, any written instrument which may hereafter be executed by Partnership Tenant or any of the Partners, which shall modify, extend or discharge this Lease, in whole or in part, or surrender all or any part of the Premises to Landlord; (iii) any bills, statements, notices, demands, requests or other communications given or rendered to Partnership Tenant; (iv) if Partnership Tenant shall admit new Partners, all new Partners shall, by their admission to Partnership Tenant, be deemed to have assumed joint and several liability for the performance of all of the terms, covenants and conditions of this Lease on Tenant’s part to be observed and performed (subject to the inherent limitations of liability in such business organization; (v) Partnership Tenant shall give prompt notice to Landlord of the admission of any new Partners, and upon demand of Landlord, shall cause each new Partner to execute and deliver to Landlord an agreement in form and substance satisfactory to Landlord, wherein each new Partner shall assume joint and several liability (subject to the inherent limitations of liability in such business organization) for the performance of all the terms, covenants and conditions of this Lease on Tenant’s part to be observed and performed (but neither Landlord’s failure to request any such agreement nor the failure of any new Partner to execute or deliver any such agreement to Landlord shall vitiate the provisions of this Section 29.1); and (vi) no change in the Partners of Partnership Tenant resulting from the admission of a new Partner, or the death, retirement or withdrawal of a Partner shall release Partnership Tenant or any Partner or former Partner from their obligations under this Lease.
Additional Rental Lessee shall pay and discharge, as additional rental (“Additional Rental”), all sums of money required to be paid by Lessee under this Lease which are not specifically referred to as Rental. Lessee shall pay and discharge any Additional Rental when the same shall become due, provided that amounts which are billed to Lessor or any third party, but not to Lessee, shall be paid within thirty (30) days after Lessor’s demand for payment thereof or, if later, when the same are due. In no event shall Lessee be required to pay to Lessor any item of Additional Rental that Lessee is obligated to pay and has paid to any third party pursuant to any provision of this Lease.
Minimum Rental Beginning with the Commencement Date and continuing through the Expiration Date or earlier termination of this Lease, Tenant shall pay Minimum Rental in accordance with the schedule set forth in Section 1(g) in equal monthly installments each in advance on or before the first day of each month. If the Commencement Date is a date other than the first day of a calendar month, the Minimum Rental shall be prorated daily from such date to the first day of the next calendar month and paid on or before the Commencement Date.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Basic Rent The periodic rent payable for the Aircraft throughout the Basic Term pursuant to Section 3.02 of the Lease, adjusted pursuant to Article 3 of the Lease. Basic Term. The period commencing at the beginning of the day on the Delivery Date and ending at the end of the day on July 15, 2023, or such earlier date on which the Lease shall be terminated as provided therein.
Common Area Operating Expenses Lessee shall pay to Lessor during the term hereof, in addition to the Base Rent, Lessee's Share (as specified in Paragraph 1.6(b)) of all Common Area Operating Expenses, as hereinafter defined, during each calendar year of the term of this Lease, in accordance with the following provisions:
Additional Rent In addition to Base Rent, Tenant agrees to pay to Landlord as additional rent (“Additional Rent”): (i) Tenant’s Share of “Operating Expenses” (as defined in Section 5), and (ii) any and all other amounts Tenant assumes or agrees to pay under the provisions of this Lease, including, without limitation, any and all other sums that may become due by reason of any default of Tenant or failure to comply with the agreements, terms, covenants and conditions of this Lease to be performed by Tenant, after any applicable notice and cure period.
Fixed Rent Tenant agrees to pay to Landlord, on the Rent Commencement Date, and thereafter monthly, in advance, on the first day of each and every calendar month during the Original Lease Term, a sum equal to one-twelfth (1/12th) of the Annual Fixed Rent specified in Section 1.1 hereof. Until notice of some other designation is given, fixed rent and all other charges for which provision is herein made shall be paid by remittance to or for the order of Boston Properties Limited Partnership, as agent of Landlord. All remittances received by BOSTON PROPERTIES LIMITED PARTNERSHIP, as agent as aforesaid, or by any subsequently designated recipient, shall be treated as a payment to Landlord. Annual Fixed Rent for any partial month shall be paid by Tenant to Landlord at such rate on a pro rata basis, and, if the Rent Commencement Date shall be other than the first day of a calendar month, the first payment of Annual Fixed Rent which Tenant shall make to Landlord shall be a payment equal to a proportionate part of such monthly Annual Fixed Rent for the partial month from the Rent Commencement Date to the first day of the succeeding calendar month. Additional Rent payable by Tenant on a monthly basis, as elsewhere provided in this Lease, likewise shall be prorated, and the first payment on account thereof shall be determined in similar fashion and shall commence on the Rent Commencement Date and other provisions of this Lease calling for monthly payments shall be read as incorporating this undertaking by Tenant. Notwithstanding that the payment of Annual Fixed Rent payable by Tenant to Landlord shall not commence until the Rent Commencement Date, Tenant shall be subject to, and shall comply with, all other provisions of this Lease as and at the times provided in this Lease. The Annual Fixed Rent and all other charges for which provision is made in this Lease shall be paid by Tenant to Landlord without setoff, deduction or abatement.
