Satisfaction of Completion Criteria and Issuance of Completion Certificate Sample Clauses

Satisfaction of Completion Criteria and Issuance of Completion Certificate. (a) Project Co shall give the Independent Certifier, the Design and Construction Compliance Consultant and HMQ each not less than thirty (30) Business Days’ notice of the date on which it anticipates the Project Works will be in the condition necessary to satisfy the Completion Criteria and the dates on which it is intended that the Independent Certifier carry out the inspection of the Project Works with a view to issuing the Completion Certificate; (b) The Independent Certifier shall inspect the Project Facilities (including any re- inspections thereof) in accordance with the procedures for certification set forth in Schedule D (Completion Certification) and shall prepare a Minor Matters List, if applicable, and otherwise comply with the procedure for certification set forth in Schedule D (Completion Certification); (c) The Independent Certifier’s decision to issue or not to issue the Completion Certificate shall be final and binding on the parties solely in respect of determining the Payment Commencement Date and a dispute between the parties in relation to the Payment Commencement Date shall not be subject to resolution pursuant to the Dispute Resolution Procedure, provided, however, that any other dispute between the parties in relation to the Independent Certifier’s decision to issue or not issue the Completion Certificate may be referred for resolution pursuant to the Dispute Resolution Procedure. (d) If any deficiencies in the Project Works with respect to the Completion Criteria or any part thereof are identified by the Independent Certifier during the course of the inspection referred to in Section 4.8(a) (as conducted in accordance with the requirements set forth in Schedule D (Completion Certification)) as requiring attention so as to enable the Completion Criteria to be achieved, Project Co shall attend to the matters contained in the Independent Certifier’s report delivered pursuant to Schedule D (Completion Certification) forthwith. Project Co shall as soon as possible thereafter give notice of re-inspection and (i) the provisions of Sections 4.8(a) and 4.8(b) shall apply also to such re-inspection except that the reference to thirty (30) Business Days shall be construed as five (5) Business Days and a new Minor Matters List, as required to be delivered pursuant to Schedule D (Completion Certification), shall be prepared and delivered prior to any re-inspection by the Independent Certifier; and (ii) the provisions of Section 4.8(a) shall also...
Sample 1
AutoNDA by SimpleDocs

Related to Satisfaction of Completion Criteria and Issuance of Completion Certificate

  • Evidence of Compliance with Conditions Precedent The Guarantor shall provide to the Guarantee Trustee such evidence of compliance with such conditions precedent, if any, provided for in this Guarantee Agreement that relate to any of the matters set forth in Section 314(c) of the Trust Indenture Act. Any certificate or opinion required to be given by an officer pursuant to Section 314(c)(1) may be given in the form of an Officers' Certificate.

  • Completion Certificate (i) Upon completion of all Works forming part of the Project Highway, and the Authority’s Engineer determining the Tests to be successful and after the receipt of notarized true copies of the certificate(s) of insurance, copies of insurance policies and premium payment receipts in respect of the insurance defined in Article 20 and Schedule P of this Agreement, it shall, at the request of the Contractor forthwith issue to the Contractor and the Authority a certificate substantially in the form set forth in Schedule-L (the “Completion Certificate”). (ii) Upon receiving the Completion Certificate, the Contractor shall remove its equipment, materials, debris and temporary works from the Site within a period of 30 (thirty) days thereof, failing which the Authority may remove or cause to be removed, such equipment, materials, debris and temporary works and recover from the Contractor an amount equal to 120% (one hundred and twenty per cent) of the actual cost of removal incurred by the Authority. (iii) Without prejudice to the obligations of the Contractor specified in Articles 14 and 17, the property and ownership of all the completed Works forming part of the Project Highway shall vest in the Authority.

  • Performance of Covenants and Satisfaction of Conditions To use its reasonable best efforts to do and perform all things required to be done or performed under this Agreement by the Company prior to each Closing Date and to satisfy all conditions precedent to the delivery of the Firm Stock and the Optional Stock.

  • Effect of Completion This agreement shall, as to any of its provisions remaining to be performed or capable of having or taking effect following Completion, remain in full force and effect notwithstanding Completion.

  • Evidence of Compliance with Conditions Precedent, Certificates to Trustee Upon any application or demand by the Issuer to the Trustee to take any action under any of the provisions of this Indenture, the Issuer shall furnish to the Trustee an Officers’ Certificate stating that all conditions precedent, if any, provided for in this Indenture relating to the proposed action have been complied with, and, if requested by the Trustee, an Opinion of Counsel stating that, in the opinion of such counsel, all such conditions precedent have been complied with. Each certificate or opinion provided for in this Indenture and delivered to the Trustee with respect to compliance with a condition or covenant provided for in this Indenture shall include: (1) a statement that the person making such certificate or opinion has read such covenant or condition; (2) a brief statement as to the nature and scope of the examination or investigation upon which the statement or opinion contained in such certificate or opinion is based; (3) a statement that, in the opinion of such person, such person has made such examination or investigation as is necessary to enable such person to express an informed opinion as to whether or not such covenant or condition has been complied with; and (4) a statement as to whether or not, in the opinion of such person, such condition or covenant has been complied with; provided, however, that with respect to matters of fact an Opinion of Counsel may rely on an Officers’ Certificate or certificates of public officials.

  • Notice of Completion; Copy of Record Set of Plans Within fifteen (15) days after completion of construction of the Improvements, Tenant shall cause a Notice of Completion to be recorded in the office of the Recorder of the county in which the Building is located in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and shall furnish a copy thereof to Landlord upon such recordation. If Tenant fails to do so, Landlord may execute and file the same as Tenant’s agent for such purpose, at Tenant’s sole cost and expense. At the conclusion of construction, (i) Tenant shall cause the Architect and Contractor (A) to update the Approved Working Drawings as necessary to reflect all changes made to the Approved Working Drawings during the course of construction, (B) to certify to the best of their knowledge that the “record-set” of as-built drawings are true and correct, which certification shall survive the expiration or termination of this Lease, and (C) to deliver to Landlord two (2) sets of copies of such record set of drawings within ninety (90) days following issuance of a certificate of occupancy for the Premises, and (ii) Tenant shall deliver to Landlord a copy of all warranties, guaranties, and operating manuals and information relating to the improvements, equipment, and systems in the Premises.

  • Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.

  • Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain. (b) Employees shall not be required to start a concrete pour in Inclement Weather. (c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear. (d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay. (e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.

  • Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.

  • Evidence of Compliance with Conditions Precedent; Certificates and Opinions of Counsel to Trustee Upon any application or demand by the Company to the Trustee to take any action under any of the provisions of this Indenture, the Company shall furnish to the Trustee an Officer’s Certificate and Opinion of Counsel stating that in the opinion of the signors, all conditions precedent and covenants, if any, provided for in this Indenture relating to the proposed action have been satisfied. Each Officer’s Certificate and Opinion of Counsel provided for, by or on behalf of the Company in this Indenture and delivered to the Trustee with respect to compliance with this Indenture (other than the Officer’s Certificates provided for in Section 4.09) shall include (i) a statement that the Person making such certificate has read such covenant or condition; (ii) a brief statement as to the nature and scope of the examination or investigation upon which the statement contained in such certificate is based; (iii) a statement that, in the judgment of such person, he or she has made such examination or investigation as is necessary to enable him or her to express an informed judgment as to whether or not such covenant or condition has been complied with; and (iv) a statement as to whether or not, in the judgment of such Person, such covenant or condition has been complied with. Notwithstanding anything to the contrary in this Section 17.06, if any provision in this Indenture specifically provides that the Trustee shall or may receive an Opinion of Counsel in connection with any action to be taken by the Trustee or the Company hereunder, the Trustee shall be entitled to such Opinion of Counsel.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!