THE COMPLETION CERTIFICATE definition

THE COMPLETION CERTIFICATE means the certificate to be issued by the designated Mine Manager or his nominee, when the works have been completed to his satisfaction.
Sample 1Sample 2Sample 3
THE COMPLETION CERTIFICATE means the certificate to be issued by RAILTEL or RAILTEL- ln-Charge when the works have been completed to their satisfaction and in accordance with the criteria stipulated in the Contract. This certificate shall only be tentative and subject to the final certificate as below
Sample 1

Examples of THE COMPLETION CERTIFICATE in a sentence

  • Note: SUPPORTING DOCUMENTS TO BE FURNISHED AS CLAIM AGAINST THE ABOVE ELIGIBILITY CRITERIA : COPY OF PURCHASE ORDER DETAILS & SERVICE COMPLETION CERTIFICATE ISSUED BY THE PARTIES TO WHOM THE SERVICE HAS BEEN PROVIDED DULY SIGNED & STAMPED BY THE AGENCY ISSUING THE COMPLETION CERTIFICATE TO BE FURNISHED.

  • IF YOU MEET THE ELIGIBILITY REQUIREMENTS AS STATED ON THE D.S.C REQUEST FORM ON THE REVERSE SIDE, THEN YOU ARE RESPONSIBLE FOR COMPLETING THE COURSE AND REMITTING THE COURT COPY OF THE COMPLETION CERTIFICATE TO THE COURT.

  • IF YOU MEET THE ELIGIBILITY REQUIREMENTS AS STATED ON THE DSC REPLY FORM, THEN YOU ARE RESPONSIBLE FOR COMPLETING THE COURSE, REMITTING THE COMPLETION CERTIFICATE TO THE COURT, AND SUBMITTING A CERTIFIED COPY OF YOUR DRIVING RECORD.

  • ONLY QUALIFIED ARCHITECTS ARE ALLOWED TO SUBMIT PLANS AND SUPERVISE CONSTRUCTION AND ISSUE THE COMPLETION CERTIFICATE.

  • ONLY DULY QUALIFIED & REGISTERED ARCHITECTS ARE ALLOWED TO SUBMIT PLANS, SUPERVISE CONSTRUCTION & ISSUE THE COMPLETION CERTIFICATE.

  • IF YOU HAVE COMPLIED WITH THE ABOVE REQUIREMENTS, YOU ARE ELIGIBLE FOR THE COURSE AND ARE RESPONSIBLE FOR COMPLETING AN APPROVED COURSE AND REMITTING THE SIGNED COURT COPY OF THE COMPLETION CERTIFICATE TO THE COURT BEFORE THE EXPIRATION OF THE 90-DAY EXTENSION.

Related to THE COMPLETION CERTIFICATE

  • Completion Certificate means the certificate to be issued by the Engineer-in- Charge when the work/s have been completed to his satisfaction as per terms of the contract.

  • Final Completion Certificate has the meaning set forth in Section 11.6.

  • Construction Completion Certificate means a certificate of the I-Bank to the effect that the construction of the Project is complete.

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Inspection Certificate means a report prepared by an independent authority or third party assessor who is qualified by experience and/or education to declare the Produce unfit for human consumption, unsuitable for sale or not meeting a particular specification or standard.

  • Satisfaction Certificate means the certificate materially in the form of the document contained in the Appendix to schedule 4 granted by the Customer when the Supplier has Achieved a Milestone;

  • Allocation Certificate has the meaning set forth in Section 1.12(b).

  • Option Certificate means the certificate, substantially in the form set out as Schedule “A” hereto, evidencing an Option;

  • Occupation Certificate means any occupation certificate as referred to in s 6.4 of the Act in respect of the Development Consent;

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Exemption Certificate is defined in clause (e) of Section 4.6.

  • Tax Exemption Certificate means the Tax Exemption Certificate approved under the terms of this Resolution and to be executed by the Treasurer and delivered at the time of issuance and delivery of the Notes.

  • Certificate of Completion means the certificate of completion given by the Engineer-in- charge pursuant to clause 40 of these conditions;

  • Information Certificate means the Information Certificate of Borrower constituting Exhibit A hereto containing material information with respect to Borrower, its business and assets provided by or on behalf of Borrower to Lender in connection with the preparation of this Agreement and the other Financing Agreements and the financing arrangements provided for herein.

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Occupancy Certificate means the occupancy certificate, or such other certificate by whatever name called, issued by the competent authority permitting occupation of any building, as provided under local laws, which has provision for civic infrastructure such as water, sanitation and electricity;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Supplemental Perfection Certificate means a certificate substantially in the form of Exhibit G or any other form approved by the Administrative Agent.

  • Punch List means the list of items, prepared in connection with the inspection of the Project by the Owner’s Representative or Architect in connection with Substantial Completion of the Work or a portion of the Work, which the Owner’s Representative or Architect has designated as remaining to be performed, completed or corrected before the Work will be accepted by the Owner.

  • registration certificate means the certificate of registration or other documents in lieu thereof establishing that the Goods supplied under the Contract are registered for use in the Purchaser’s country in accordance with the applicable law.

  • Perfection Certificate is defined in Section 5.1.