Schedule of Performance and Progress Reports Sample Clauses

Schedule of Performance and Progress Reports. Subject to Developer’s right to elect whether and/or when to Commence Construction of any Project Phase(s) pursuant to Section 703(1) above, the parties acknowledge and agree that the Schedule of Performance reflects the parties’ mutual desire to consummate the transaction(s) contemplated hereunder, including the processing and consideration of Project Approval(s), the Closing, and the Commencement of Construction and Substantial Completion of the Project (assuming City approves the Project after complying with CEQA), and thus the purpose of the Schedule of Performance is to reflect a good faith estimate of anticipated timing to achieve key milestones rather than discrete and absolute deadlines unless otherwise expressly indicated. Accordingly, the Schedule of Performance shall: (A) identify each key milestone; (B) identify the anticipated timeline for each milestone; and (C) confirm whether the anticipated timeline shall be treated as (i) merely a guideline that shall be adjusted from time to time as requested by either party so long as the requesting party is acting in a commercially reasonable and diligent manner to achieve the milestone at issue (each, a “Performance Guideline”), or (ii) a deadline that shall be achieved by the relevant party(ies) unless extended pursuant to subsection (3) below or due to the occurrence of Excused Delay(s) (each, a “Performance Deadline”). During the Term of this Agreement, the parties shall keep each other reasonably informed of their efforts to achieve the identified milestones in the Schedule of Performance. If after Closing, Developer elects, in its sole and absolute discretion, to Commence Construction of a Project Phase pursuant to Section 703(1) above, then Developer shall notify City accordingly and thereafter shall keep City reasonably informed of the progress towards Substantial Completion of said phase.
Sample 1
AutoNDA by SimpleDocs

Related to Schedule of Performance and Progress Reports

  • Schedule of Performance Consultant shall commence the services pursuant to this Agreement upon receipt of a written notice to proceed and shall perform all services within the time period(s) established in the “Schedule of Performance” attached hereto as Exhibit “D” and incorporated herein by this reference. When requested by the Consultant, extensions to the time period(s) specified in the Schedule of Performance may be approved in writing by the Contract Officer but not exceeding one hundred eighty (180) days cumulatively.

  • Assessment of Performance The assignment of a teacher to a TLS position will be subject to review by the school district’s administration at least annually. The first review must be completed no later than five (5) work days before the beginning of the transfer process. The review shall include peer feedback on the effectiveness of the teacher’s performance of duty specific to the teacher’s TLS position. A teacher who completes an assignment in a TLS position may apply for assignment to a new TLS position.

  • Review of Performance The Board of Directors shall periodically review and evaluate the performance of Employee under this Employment Agreement with Employee.

  • Xxxxxxx to Meet Timelines Failure by the Union to comply with the timelines will result in the automatic withdrawal of the grievance. Failure by the Employer to comply with the timelines will entitle the Union to move the grievance to the next step of the procedure.

  • Evaluation of Performance School, in conjunction with Company personnel, is responsible for and shall make arrangements for evaluating Student’s performance during the clinical program.

  • Quarterly Contractor Performance Reporting Customers shall complete a Contractor Performance Survey (Exhibit I) for each Contractor on a Quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated in Contract Exhibit D, Section 17, Additional Special Contract Conditions. The completed Contractor Performance Survey(s) will be used by the Department as a performance-reporting tool to measure the performance of Contractors. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MyFloridaMarketPlace or on the Department's website).

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • PROGRESS SCHEDULE The Contractor, within ten (10) working days of receiving notice of the award of the contract, shall prepare and submit for the State's and Architect's information an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work.

  • SCHEDULE FOR PERFORMANCE REVIEWS 8.1 The performance of each Employee in relation to his/her performance agreement shall be reviewed on the following dates with the understanding that reviews in the first and third quarter may be verbal if performance is satisfactory:

  • Work Progress Schedule Refer to Special Conditions and Division 1 General Administration Specifications for additional schedule requirements. Unless indicated otherwise in those documents, Contractor shall submit to the ODR and the A/E its initial Work Progress Schedule for the Work in relation to the entire Project not later than twenty-one (21) days after the effective date of the Notice to Proceed. Unless otherwise indicated in the Contract Documents, the Work Progress Schedule shall be based upon a computerized Critical Path Method (CPM) with full reporting capability. This initial schedule shall indicate the dates for starting and completing the various aspects required to complete the Work, including mobilization, procurement, installation, testing, inspection, and acceptance of all the Work of the Contract. When acceptable to the Owner, the initially accepted schedule shall be the Baseline Schedule for comparison to actual conditions throughout the contract duration.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!