Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.
Sale : Completion On Or Before The Completion Date
a. Within ninety (90) days from the date of successful sale (the expiry date of which period referred to as “the Completion Date”), the Purchaser shall deposit with the Assignee’s Solicitors simultaneously:-
(i) The balance of the purchase price i.e a sum equivalent to 90% of the successful bid price (referred to as “the Balance Sum”) either by way of IBG or XXXXXX or bank draft or cashier’s order crossed “A/C PAYEE ONLY” made payable to HONG XXXXX BANK BERHAD. The amount of the bank draft or cashier’s order shall include outstation clearing charges which shall be borne by the Purchaser, failing which the deficiency shall be recoverable from the Purchaser; and
(ii) A copy of the requisite consents or confirmations (as the case may be) of the Developer and/or Proprietor and/or State Authorities and/or relevant bodies approving the sale (including transfer or assignment) in favour of the Purchaser, if necessary and/or required, subject firstly to the Assignee being satisfied with the conditions if imposed, otherwise the Assignee may elect to terminate the sale under Xxxxxx 11. - Extension
b. The Completion Date will not be extended unless the Purchaser shall have at least fourteen (14) days before the Completion Date applied in writing for an extension of time to the Assignee and the Assignee may at its absolute discretion without assigning any reason whatsoever either:-
(i) Reject such request in which event all monies paid by the Purchaser hitherto including the Deposit shall be forfeited absolutely and immediately for which the Purchaser shall not be entitled to nor have any or further reimbursements, claims and demands whatsoever in nature and howsoever caused against the Assignee, the Assignee’s Solicitors, the Auctioneer or their respective servants or agents and any other party on account thereof; or
(ii) Agree to grant an extension of time subject to conditions imposed by the Assignee including but not limited to the imposition of non- refundable late payment charges / compensation charges on the balance unpaid or outstanding purchase price at such rate as the Assignee shall determine and to be calculated on a daily basis for the whole duration of the extended period granted and also to pay such sum within the time and in the manner as stipulated by the Assignee. Such decision by the Assignee shall be binding on the Purchaser. - Charges
c. Notwithstanding any contrary terms and conditions which may be imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto on the Assignee in granting the consent or confirmation (as the case may be) to the sale herein, it is hereby agreed that only arrears of quit rent, assessment rate and service charges (collectively referred to as “the Outstanding Charges”) within a period of six (6) years prior to the date of successful sale of the Property which are lawfully and rightfully due and payable to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto up to the date of successful sale of the Property shall be deducted from the purchase price upon receipt of the Balance Sum PROVIDED THAT the Assignee reserves the right to refuse to pay nor shall the Assignee be obliged to pay:-
(i) Any Outstanding Charges that are time-barred i.e. charges which have remained unpaid for more than six (6) years prior to the date of successful sale of the Property irrespective of any payment or acknowledgement or judgment made or obtained on the said charges;
(ii) Any Outstanding Charges that are excessively charged resulted from eg duplicate or double counting, wrong calculation or any other similar circumstances;
(iii) Any Outstanding Charges wrongfully imposed including but not limited to being charged without any basis whatsoever; and/or
(iv) Any bills issued by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto for the Outstanding Charges but only received by the Assignee or the Assignee’s Solicitors more than seventy-five (75) days from the date of the successful sale. Such decision by Assignee on what is due and payable shall be binding on the Purchaser of which the Purchaser hereby expressly agrees.
d. The Outstanding Charges due and payable immediately after the date of successful sale of the Property shall be solely borne and paid by the Purchaser.
e. Where applicable, it shall be the duty of the Purchaser to obtain at the Purchaser’s own costs the particulars as stated in Section 22D(4) of the Housing Development (Control and Licensing) Act 1966 and to obtain copies of the charges payable from the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto and to forward copies thereof together with the calculations as to the apportionment of the respective parties’ liability thereof to the Assignee’s Solicitors for the Assignee’s approval. For this purpose, the Purchaser shall also furnish the Assignee’s Solicitors with the Purchaser’s account details in order for the Assignee to process payment of the Assignee’s portion of the Outstanding Charges pursuant to and in accordance with Clause 8(c) above.
f. In the event the Purchaser shall pay such arrears (if any) of the Outstanding Charges in advance to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto:-
(i) The Purchaser is not entitled to deduct the payment towards the arrears (if any) from the Balance Sum;
(ii) Due apportionment and reimbursement for the payment (if any) made by the Purchaser towards the arrears shall only be made after the Assignee has received the Balance Sum and subject to the Assignee’s approval and other provisions of these Conditions of Sale. For this purpose, the Purchaser shall produce receipts evidencing payment together with the Purchaser’s account details in order for the Assignee to reimburse the Purchaser in accordance with this Clause 8(f)(ii) accordingly.
g. Nothing herein shall impose any obligation on the part of the Assignee to pay any outstanding water, electricity, telephone, utilities, gas, sewerage, taxes, rates, bills, any type of interest, fine, penalty, losses incurred by reason of any breach of written laws, late payment charges, damages, compensation, other form of maintenance or management charges (including but not limited to security charges, charges incurred in relation to car park / accessory parcel, deposits, sinking / building / common / maintenance / management fund), costs for renovation / alteration / additional works, contribution, subscription, licence, dues, levies, insurance, premium, rents, commission, fees, costs and expenses (including but not limited to legal fees, disbursements, stamp duty, registration fees, administrative or vetting fees and transfer costs), other outgoings and charges in any form whatsoever (including for any increase in area of the Property imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto irrespective of whether the same was imposed or incurred before the date of successful auction, any penalty thereof in connection with incidental to or pursuant to the Assignment the Memorandum of Transfer and all other documents necessary for affecting the transfer or subsequent transfer [as the case may be] or assigning the beneficial ownership of the Property to the Purchaser or that as may be due to or imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto notwithstanding that the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto may require such payments to be made by the Assignee). The Purchaser hereby expressly agrees that such costs and expenses shall be solely borne and paid by the Purchaser.
h. Any other costs, expenses and charges not specifically mentioned and/or specified in Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f and Clause 8.g hereof which are outstanding shall be solely borne and paid by the Purchaser.
i. Upon payment of all monies mentioned and/or specified in Clause 6.d, Clause 7.a, Clause 8.a(i), Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f, Clause 8.g and Clause 8.h above and subject to the fulfillment of Clause 9 below by the Purchaser, the Assignee shall:-
(i) Execute or cause to be executed as soon as possible at the Purchaser’s own costs and expenses (including legal fees, stamp duty and registration fees) an Assignment (in the form and substance acceptable to and upon the terms and conditions stipulated by the Assignee at its absolute discretion) in favour of the Purchaser of all the rights title interests and benefits under the Sale and Purchase Agreement entered into between the Developer and/or Proprietor of the Property and the Assignor or the original purchaser(s) when the Assignor is not the original purchaser of the Property. Where applicable, the Assignee shall be entitled to have a sufficient covenant of indemnity inserted in the Assignment in order for the Purchaser to assume all liabilities and obligations pertaining to the Property. The Assignee shall not be required to assign the Property to any person other than the Purchaser; and
(ii) Deliver to the Purchaser or the Purchaser’s Solicitors the duly executed Assignment and certified true copy(ies) of the Sale and Purchase Agreement and previous Assignment within the Assignee’s custody. If any of the aforesaid documents is not available, the Assignee shall use its best endeavors to provide certified true copy(ies) or such other acceptable documentary evidence of previous transactions thereof.
j. Where applicable, the Purchaser undertakes to forward to the Developer the duly stamped Assignment, the duly stamped Proclamation of Sale and the Memorandum together with the full payment of all sums and outgoings due to the Developer under the Sale and Purchase Agreement as required by Section 22D(2) of the Housing Development (Control and Licensing) Act 1966 within fourteen (14) days from the date of stamping of the Assignment and to forward a copy of the cover letter or acknowledgment of receipt by the Developer to the Assignee or the Assignee’s Solicitors within seven (7) days after the issuance of the cover letter or acknowledgment of receipt. - Charge / Transfer
k. If the separate document of title or strata title for the Property has been issued whether before on or after the date of auction sale, the Assignee shall not be required to procure a Memorandum of Transfer nor to register its charge as prescribed by the National Land Code 1965 or Sarawak Land Code or the Land Ordinance Cap. 68 of the Laws of Sabah (where applicable) in favour of the Purchaser from the Developer and/or Proprietor (as the case may be).
l. The transfer of the Property from the Developer and/or Proprietor (as the case may be) shall be prepared and procured by the Purchaser at the Purchaser’s own costs (including costs of transfer from the Developer and/or Proprietor to the Assignor where necessary) and expenses who undertakes to pay such sums and comply with the conditions (if any) imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies pertaining to the registration of such transfer of the Property.
m. The Purchaser undertakes to inform the local authority of the change of ownership and to file the necessary form within fourteen (14) days from the date of stamping of the Assignment.
PROGRESS AND COMPLETION 8.2.1 All time limits stated in the Contract Documents are material terms and time is the essence of the Contract. A failure by Contractor to do what is required by the time specified in the Contract Documents is a breach of the contract.
8.2.2 The Contractor shall begin the Work on the date of commencement as defined in
8.2.3 If in the sole opinion of the State, the Contractor fails to commence work on the project or to complete the work of said project within the time specified above, or to prosecute the work in such a manner that it appears that the completion date can be assured, the State shall have the right to notify the Contractor by Certified Mail that the terms of the Contract have been violated, and that effective immediately the Contract is terminated and the State has the right to and in fact is taking over and attending to completion of the project without prejudice to the State's remedies for any losses sustained
Final Completion The full and final completion of all Work in accordance with the Contract Documents.
Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:
Approval and Completion If any dispute regarding the design of the Tenant Improvements is not settled within 10 business days after notice of such dispute is delivered by one party to the other, Tenant may make the final decision regarding the design of the Tenant Improvements, provided (i) Tenant acts reasonably and such final decision is either consistent with or a compromise between Landlord’s and Tenant’s positions with respect to such dispute, (ii) that all costs and expenses resulting from any such decision by Tenant shall be payable out of the TI Fund (as defined in Section 5(d) below), and (iii) Tenant’s decision will not affect the base Building, structural components of the Building or any Building systems (in which case Landlord shall make the final decision). Any changes to the TI Construction Drawings following Landlord’s and Tenant’s approval of same requested by Tenant shall be processed as provided in Section 4 hereof.
Completion a) Within 120 days from the date of the auction sale (“Payment Due Date”), the Purchaser shall deposit with the Solicitors appointed by the Assignee simultaneously:
i) A sum equivalent to 90% of the successful bid (“Balance Sum”) by way of the bank draft or cashier’s order crossed “A/C PAYEE ONLY” made payable to OCBC BANK (MALAYSIA) BERHAD, The amount of the cheque shall include outstation clearing charges which shall be borne by the Purchaser, failing which the deficiency shall be recoverable from the Purchaser; and
ii) A copy of the requisite consents of the Developer, Proprietor and / or State Authorities or relevant bodies approving the sale in favour of the Purchaser, if necessary, subject firstly to the Assignee being satisfied with the conditions if any imposed (otherwise the Assignee may terminate the sale under Clause 9) Then the Assignee will execute an assignment (in form and substance acceptable to the Assignee) and deliver up the Related Documents to the Purchaser, but such sale and assignment of the chose in action shall be prepared by and at the expense of the Purchaser. Where applicable, the Assignee shall be entitled to have a sufficient covenant of indemnity inserted in the assignment in order for the Purchaser to assume all liabilities and obligations pertaining to the property. The Assignee shall not be required to assign the property to any person other than the Purchaser.
b) If the separate document of title or strata title for the property has been issued whether before, on or after the date of the auction sale, the Assignee shall not be required to register its charge(s) nor to procure a transfer in Form 14A as prescribed by the National Land Code, 1965 in favour of the Purchaser from the Developer or the Proprietor (as the case may be). The transfer of the Property from the Developer or Proprietor (as the case may be) shall be procured and prepared by the Purchaser at the Purchaser’s expense who undertakes to pay such sums and comply with the conditions (if any) imposed by the Developer and / or Proprietor and / or their solicitors and / or relevant authorities pertaining to the registration of such transfer of the property.
c) “ Any arrears of Quit Rent, Assessment, service/maintenance charges, sinking fund including the late penalty interest (if any) which may be lawfully due to any relevant authority or the Developer up to the date of successful sale of the subject property shall be deducted from the purchase money upon receipt of the Balance sum, provided that the Assignee/Bank is in receipt of the itemized billing for Quit Rent, Assessment bills issued by the relevant authority and the Developer’s invoice/statement of account from the Purchaser within ninety (90) days from the date of sale. For avoidance of doubt, in the event such invoices and/or itemized xxxxxxxx are not submitted within the stipulated ninety (90) days from the auction date, any subsequent claims made thereunder will not be entertained by the Assignee/Bank and the same shall be borne by the Purchaser solely. All other charges as at the date of auction sale not specified in Clause 7(c) (including but not limited to water bills, electric bills, sewerage charges, telephone bills and/or other monies whatsoever outstanding to the Developer and/or other authority/parties) shall not be borne by the Assignee/Bank. The Purchaser shall bear and pay all fees and expenses including but not limited to all legal fees, stamp duty and registration fees in connection with, incidental to or pursuant to the Assignment and all other documents necessary for effecting the transfer or assigning the beneficial ownership in the property to the Purchaser
d) The Purchaser is responsible to make his own enquiries and all liabilities and encumbrances affecting the property and shall be deemed to purchase in all respects subject thereto whether or not he makes any enquiry and neither the Assignee nor the Auctioneer shall be required or bound to inform the Purchaser of any such matters whether known to them or not and the Purchaser shall raise no enquiry, requisition or objection thereon or thereto.
e) The stamp duty and registration fee for the Memorandum, the Assignment and subsequent transfer (as the case may be) shall be borne and paid by the Purchaser.
Commencement and Completion The Work shall commence on _______________, 20__ and shall be complete in accordance with this Agreement without delay on ______________, 20__. The term “day”, used throughout this Agreement, refers to calendar days. Contractor shall not be entitled to any additional compensation for any Permitted Delays. If this Agreement is not signed and returned to the Owner before any work commences, this Agreement will be considered as accepted as presented to the Contractor.
TIME OF COMPLETION This project’s start date is scheduled for June 15, 2015 and completion date is July 31, 2015. The Contractor agrees to proceed with the work expeditiously without any delay or cessation, except such as may reasonably be beyond his control, and to employ a force of workmen sufficient so to perform the work covered by this Contract in such manner as to expedite the work of such other Contractors as may be engaged upon the work, as further provided in the Instructions to Bidders, to the end that the work to be performed by the Contractor shall be fully completed on or before the 31st day of July, 2015, subject to such adjustment of said date as may be made in accordance with this Contract. It is specifically agreed that the Contractor shall be bounden for damages, as hereinafter provided, for each and every day's delay which may be due or traceable to the Contract. In case the Contractor shall fail to perform fully the Contract within the agreed time limit, he shall pay to the City of Milwaukee, as liquidated damages for such default, the sum of $250.00 per day for each and every day's delay in completing the performance thereof after such time limit.
Phase 2 Phase 2 is expected to consist of Member Nodes and a select number of Nodes operated by non-Members. The non-Member Nodes will be required to comply with Node hosting terms as set forth by the Council, which may be amended from time to time (the “General Node Terms”).
