Development of the Property Except as modified by this Agreement, the Development and the Property will be developed in accordance with all applicable local, state, and federal regulations, including but not limited to the City’s ordinances and the zoning regulations applicable to the Property, and such amendments to City ordinances and regulations that that may be applied to the Development and the Property under Chapter 245, Texas Local Government Code, and good engineering practices (the “Applicable Regulations”). If there is a conflict between the Applicable Regulations and the Development Standards, the Development Standards shall control.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
Cooperation of the Parties The Seller undertakes to notify the Buyer of any obstacles on his part, which may negatively influence proper and timely delivery of the Equipment.
AGREEMENT OF THE PARTIES The language used in this Agreement will be deemed to be the language chosen by the parties hereto to express their mutual intent, and no rule of strict construction will be applied against any party hereto. Neither Executive nor the Company shall be entitled to any presumption in connection with any determination made hereunder in connection with any arbitration, judicial or administrative proceeding relating to or arising under this Agreement.
Research Matters By entering into this Agreement, the Placement Agent does not provide any promise, either explicitly or implicitly, of favorable or continued research coverage of the Company and the Company hereby acknowledges and agrees that the Placement Agent’s selection as a placement agent for the Offering was in no way conditioned, explicitly or implicitly, on the Placement Agent providing favorable or any research coverage of the Company. In accordance with FINRA Rule 2711(e), the parties acknowledge and agree that the Placement Agent has not directly or indirectly offered favorable research, a specific rating or a specific price target, or threatened to change research, a rating or a price target, to the Company or inducement for the receipt of business or compensation.
Collaboration 31.1 If the Buyer has specified in the Order Form that it requires the Supplier to enter into a Collaboration Agreement, the Supplier must give the Buyer an executed Collaboration Agreement before the Start date.
31.2 In addition to any obligations under the Collaboration Agreement, the Supplier must:
31.2.1 work proactively and in good faith with each of the Buyer’s contractors
31.2.2 co-operate and share information with the Buyer’s contractors to enable the efficient operation of the Buyer’s ICT services and G-Cloud Services
MANAGEMENT OF THE BUSINESS Pursuant to Section 00-00-000 of the Act, and as stated in its Articles, the Company’s day to day affairs are managed by the Member. The Member is responsible for the daily operations of the business.
Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever.
(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties.
(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority.
(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i).
(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party.
(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway.
(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Development Activities The Development activities referred to in item “b” of paragraph 3.1 include: studies and projects of implementation of the Production facilities; drilling and completion of the Producing and injection xxxxx; and installation of equipment and vessels for extraction, collection, Treatment, storage, and transfer of Oil and Gas. The installation referred to in item “c” includes, but is not limited to, offshore platforms, pipelines, Oil and Gas Treatment plants, equipment and facilities for measurement of the inspected Production, wellhead equipment, production pipes, flow lines, tanks, and other facilities exclusively intended for extraction, as well as oil and gas pipelines for Production Outflow and their respective compressor and pumping stations.
Commercial Activities Neither Contractor nor its employees shall establish any commercial activity or issue concessions or permits of any kind to Third Parties for establishing commercial activities on the Site or any other lands owned or controlled by Owner.
