Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
No Duty to Collect Amounts Due From Dividend and Transfer Agent The Custodian shall not be under any duty or obligation to take action to effect collection of any amount due to the Trust from any Dividend and Transfer Agent of the Trust nor to take any action to effect payment or distribution by any Dividend and Transfer Agent of the Trust of any amount paid by the Custodian to any Dividend and Transfer Agent of the Trust in accordance with this Agreement.
Reports; Payment of Royalty During the Term following the First Commercial Sale of a Product, Merck shall furnish to Ambrx a quarterly written report for the Calendar Quarter showing the Net Sales of all Royalty Products subject to royalty payments sold by Merck and its Related Parties in the Territory for use in the Field during the reporting period and the royalties payable under this Agreement. Reports shall be due on the [***] day following the close of each Calendar Quarter. Royalties shown to have accrued by each royalty report shall be due and payable on the date such royalty report is due. Merck shall keep complete and accurate records in sufficient detail to enable the royalties payable hereunder to be determined.
Default Not Exceeding 10% of Firm Units If any Underwriter or Underwriters shall default in its or their obligations to purchase the Firm Units and if the number of the Firm Units with respect to which such default relates does not exceed in the aggregate 10% of the number of Firm Units that all Underwriters have agreed to purchase hereunder, then such Firm Units to which the default relates shall be purchased by the non-defaulting Underwriters in proportion to their respective commitments hereunder.
Up-Front Payment Connetics shall issue to Genentech upon the Original Closing Date (as defined in the Stock Agreement) shares of Connetics Common Stock (“Original Issuance Shares” as defined in the Stock Agreement) with a fair market value equal to two million dollars ($2,000,000), on the terms and conditions set forth in the Stock Agreement. If, on the Second Closing Date (as defined in the Stock Agreement), the aggregate market value of the Original Issuance Shares (based on the Second Issuance Price (as defined in the Stock Agreement)) is less than four million dollars ($4,000,000), Connetics shall issue to Genentech upon the Second Closing Date the number of additional shares of Connetics Common Stock (the “Second Issuance Shares,” as defined in the Stock Agreement) equal to the lesser of: (i) the number of shares necessary to increase the aggregate market value of the Original Issuance Shares (based on the Second Issuance Price) plus the Second Issuance Shares (based on the Second Issuance Price) to four million dollars ($4,000,000) or (ii) the number of shares necessary to increase the aggregate number of the Company’s shares of Common Stock held by Genentech (exclusive of any shares that Genentech has purchased from parties other than the Company) to 9.9% of the Company’s total outstanding shares of Common Stock as of the close of business on the third trading day before the Second Closing Date, on the terms and conditions set forth in the Stock Agreement. In lieu of all or any portion of the Second Issuance Shares that the Company is obligated to issue to Genentech on the Second Closing Date, the Company may elect to pay Genentech the cash value of such Second Issuance Shares (based on the Second Issuance Price). The Original Closing and the Second Closing of the stock issuances shall take place as described in the Stock Agreement. In the event that Connetics does not issue to Genentech all of the Second Issuance Shares or the cash value of the Second Issuance Shares, Genentech may, in addition to other remedies available to it by law or in equity, immediately terminate this Agreement and the licenses granted to Connetics hereunder. Such termination by Genentech of the Agreement and the licenses hereunder does not discharge Connetics’ obligation to issue all of the Second Issuance Shares or to pay to Genentech the cash value of the Second Issuance Shares. The up-front payment shall not be creditable against any royalty payments owed by Connetics under Sections 8.3 and 8.4 below.
Payment of normal interest Subject to the provisions of this Agreement, interest on the Loan in respect of each Interest Period shall be paid by the Borrower on the last day of that Interest Period.
Obligation to Keep Company Informed During the period of my employment and for six (6) months after termination of my employment with the Company, I will promptly disclose to the Company fully and in writing all Inventions authored, conceived or reduced to practice by me, either alone or jointly with others. In addition, I will promptly disclose to the Company all patent applications filed by me or on my behalf within a year after termination of employment. At the time of each such disclosure, I will advise the Company in writing of any Inventions that I believe fully qualify for protection under Section 2870; and I will at that time provide to the Company in writing all evidence necessary to substantiate that belief. The Company will keep in confidence and will not use for any purpose or disclose to third parties without my consent any confidential information disclosed in writing to the Company pursuant to this Agreement relating to Inventions that qualify fully for protection under the provisions of Section 2870. I will preserve the confidentiality of any Invention that does not fully qualify for protection under Section 2870.
