Renewal and Termination A. This Agreement shall become effective on the date written below and shall continue in effect for one (1) year thereafter, unless sooner terminated as hereinafter provided and shall continue in effect thereafter for periods not exceeding one (1) year so long as such continuation is approved at least annually (i) by a vote of a majority of the outstanding voting securities of the Fund or by a vote of the Board of Trustees of the Trust, and (ii) by a vote of a majority of the Trustees of the Trust who are not parties to the Agreement (other than as Trustees of the Trust) or “interested persons” of any such party, cast in person at a meeting called for the purpose of voting on the Agreement. B. This Agreement: (i) may at any time be terminated without the payment of any penalty either by vote of the Board of Trustees of the Trust or by vote of a majority of the outstanding voting securities of the Fund on sixty (60) days’ written notice to the Adviser; (ii) shall immediately terminate with respect to the Fund in the event of its assignment; and (iii) may be terminated by the Adviser on sixty (60) days’ written notice to the Fund. C. As used in this Paragraph the terms “assignment,” “interested person” and “vote of a majority of the outstanding voting securities” shall have the meanings set forth for such terms in the 1940 Act. D. Any notice under this Agreement shall be given in writing addressed and delivered, or mailed post-paid, to the other party at any office of such party.
Scope of Services and Term Subject to the provisions for early termination as set forth herein, the Contractor agrees that it will perform the Services enumerated in the scope of services attached hereto as Exhibit A and incorporated herein by reference (the “Scope of Services”) for a term of three (3) years beginning , 2024 through , 2027 (the “Term”). The Authority in its sole discretion may extend the Agreement for two (2) additional one-year periods, for a potential maximum term of five (5) years. The Authority will provide any such renewal notice in writing at least thirty (30) days prior to expiration of the Agreement. The maximum payment for the Term is set forth in Section II(a). All work shall be diligently performed by the Contractor in an economical, expeditious and professional manner.
Term Renewal and Termination 14.1. This Agreement shall, with respect to the Portfolio, become effective as of the date first above written and shall remain in force for two years thereafter, and for successive annual periods thereafter but only so long as each such continuance is specifically approved at least annually by (1) a majority of the Directors of the Company who are not parties to this Agreement or interested persons of any such parties (other than as Directors of the Company), by vote cast in person at a meeting called for the purpose of voting on such approval; or
Employment and Term The Company hereby agrees to employ the Executive and the Executive hereby agrees to serve the Company on the terms and conditions set forth herein.
Commencement and Term This Agreement shall commence upon the Effective Date and continue for the Agreement Term.
Agreement and Term This Agreement records the Parties' agreement that:
Premises and Term a. Landlord, in consideration of the Rent hereinafter reserved to be paid and of the covenants, conditions and agreements to be kept and performed by Tenant, hereby leases, lets and demises to Tenant, and Tenant hereby leases and hires from Landlord, the Project. Upon the Commencement Date for Phase 1, Tenant shall be entitled to the exclusive use and occupancy of Phase 1 and that portion of the Parking Area allocated for Phase 1 plus such spaces in addition to the spaces allocated for Phase 1, if any, that may be constructed by Landlord at the time, so long as Tenant’s use of such spaces in addition to the spaces allocated for Phase 1 does not interfere with the construction of the remainder of the Project by Landlord. Upon the Commencement Date for Phase 2, Tenant shall be entitled to the exclusive use and occupancy of Phase 2 and the entire Parking Area, and at which time Tenant will have the exclusive use and occupancy of the entire Project. b. Promptly after the actual Commencement Date for each Phase, the parties shall execute an instrument in which the Commencement Date and expiration date for such Phase will be specified, as well as any adjustments to the Rentable Area of the Premises as described above and any corresponding adjustments to the Base Rent. c. Notwithstanding anything to the contrary contained in this Lease, although Landlord has estimated a completion date for Phase 1 of October 1, 1999, the parties agree that if Landlord has not achieved Substantial Completion of Phase 1 on or before November 1, 1999 (the “Phase 1 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 1999, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 1, such credit to be equal to one (1) day’s Base Rent for Phase 1 for each day of Landlord’s delay beyond the Phase 1 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. d. If Landlord has not achieved Substantial Completion of Phase 1 on or before November 15, 1999 (the “Phase 1 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 1999, the Base Rent credit available to Tenant for Phase 1 shall be increased to two (2) days’ Base Rent for each day of Landlord’s delay beyond the Phase 1 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. e. If Landlord has not achieved Substantial Completion of Phase 1 on or before December 17, 1999 (the “Phase 1 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 1999, (x) the Base Rent credit available to Tenant for Phase 1 shall be decreased back to one (1) day’s Base Rent for each day of Landlord’s delay beyond the Phase 1 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below. f. If Landlord has not achieved Substantial Completion of Phase 1 on or before January 17, 2000 (the “Phase 1 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 1 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. g. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 1 on or before May 17, 2000 (the “Phase 1 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Extended Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2000 and May 1, 2000 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right. h. Although Landlord has estimated a completion date for Phase 2 of October 1, 2001, the parties agree that if Landlord has not achieved Substantial Completion of Phase 2 on or before November 1, 2001 (the “Phase 2 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 2001, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 2, such credit to be equal to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. i. If Landlord has not achieved Substantial Completion of Phase 2 on or before November 15, 2001 (the “Phase 2 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 2001, the Base Rent credit available to Tenant for Phase 2 shall be increased to two (2) days’ Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below. j. If Landlord has not achieved Substantial Completion of Phase 2 on or before December 17, 2001 (the “Phase 2 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 2001, (x) the Base Rent credit available to Tenant shall be decreased back to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below. k. If Landlord has not achieved Substantial Completion of Phase 2 on or before January 17, 2002 (the “Phase 2 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 2 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. l. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 2 on or before May 17, 2002 (the “Phase 2 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Extended Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2002 and May 1, 2002 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right. m. The abatements, liquidated damages and termination rights in favor of Tenant as described above shall be Tenant’s sole and exclusive remedies in the event of any late delivery of the Buildings by Landlord, and notwithstanding anything to the contrary contained in this Lease, in no event shall the entire liability of Landlord in connection with the total aggregate amounts of the Base Rent credits, plus the $10,000.00 per day damages, plus the out-of-pocket costs incurred by Tenant exceed a total amount of Seven Hundred Fifty Thousand and No/100 ($750,000.00) Dollars in the aggregate, regardless of the length of time such rent credits, and/or liquidated damages and/or out-of-pocket costs actually accrue and regardless of whether Tenant terminates this Lease. n. Although the completion date for Phase 2 is intended to be October 1, 2001, Tenant may notify Landlord in writing of Tenant’s election to have the Commencement Date for Phase 2 be on October 1, 2000. Tenant must provide such notice no later than April 1, 1999. If Tenant timely provides such notice, then the anticipated Commencement Date for Phase 2 will be deemed to be October 1, 2000, and subparagraphs 2.h through 2.I above will be deemed to be modified as follows: All references to the year “2001” in such subparagraphs will be deemed to be “2000,” and all references to the year “2002” in such subparagraphs will be deemed to be “2001.”
Employment Duties and Term (a) Company hereby employs Employee as the Chief Financial Officer, and Employee hereby accepts such employment with Company on the terms and conditions set forth in this Agreement. In such capacity, Employee shall perform the duties appropriate to such office or position, and such other duties and responsibilities as are assigned to him from time to time by the Board of Directors of Company (the “Board”) or the President and CEO of the Company. During the term of his/her employment with Company, Employee shall devote his/her full working time and best efforts to the performance of his/her duties under this Agreement for and on behalf of Company, and shall not work for anyone else without the express written consent of Company or engage in any activity in competition with or detrimental to Company or any affiliate of Company. Employee shall follow in all material respects all rules, policies and programs adopted from time to time by the Company and applicable to Employee. (b) This Agreement shall commence on the Effective Date and end when it is terminated in accordance with Paragraph 3 of this Agreement (the “Termination Date”). The period from the Effective Date to the Termination Date shall be referred to in this Agreement as the “Term.” (c) Employee’s services shall be performed primarily at a place of business of Company in the Kansas City, Missouri metropolitan area.
Demise and Term A. For and during the term established below, Sublessor leases to Sublessee the Demised Premises. The leasing of the Demised Premises by Sublessee shall include the right of Sublessee during the term of this Sublease (a) to access the Building common areas in common with the other tenants in the Building and (b) to use all fixtures, improvements and betterments owned or leased by Landlord which, at any time during the term of this Sublease, are attached to or installed in the Demised Premises, all subject to such restrictions, rules, regulations, security arrangements and charges (if any) as are provided for in the Lease or this Sublease. B. The term of this Sublease shall commence on the Effective Date (the "Commencement Date ") and expire on the applicable Delivery Date with respect to the Initial Space, the Second Space and each Partial Block delivered to Sublessor pursuant to the terms of the Assignment, as more particularly described on Exhibit B of the Assignment (as to each, the "Expiration Date"), unless sooner cancelled or otherwise terminated as provided in this Sublease, provided, however, that in any event this Sublease shall terminate no later than December 31, 2002 (the "Final Termination Date"). C. If for any reason the Lease is terminated prior to the Expiration Date of this Sublease, other than by reason of Sublessor's default thereunder (not due to Sublessee's default under this Sublease), this Sublease shall be deemed to have been terminated on the date that is one(1) day prior to the date of termination of the Lease and Sublessor shall not be liable to Sublessee by reason thereof for damages or otherwise, except that Sublessor shall return to Sublessee that portion of any Rent (hereinafter defined) paid in advance by Sublessee, if any, which is applicable to the period following the date of such termination.
Term and Termination 9.1 Unless earlier terminated as provided in this Agreement, the initial term of this Agreement shall commence as of the Effective Date and conclude on December 31, 2005. Thereafter, this Agreement will automatically renew for three (3) year periods. Notwithstanding the foregoing, this Agreement may be terminated at any time by BMS on three (3) years written notice to NA or by NA on six (6) months written notice to BMS. 9.2 Upon the happening of any of the following .events, either party shall have the right to terminate this Agreement upon written notice of such termination to the other party: (a) Any material breach by the other party of this Agreement, which material breach continues for a period of thirty (30) days after the non-defaulting party shall have given notice thereof to the defaulting party, or (b) The other party becomes insolvent, is adjudicated as bankrupt or otherwise seeks or receives protection under the bankruptcy laws of the United States, has a receiver or trustee appointed for all or part of its assets and business, executes and delivers an assignment for the benefit of its creditors or is liquidated, dissolved or wound-up or (c) The continuance of an event of force majeure for a period of more than sixty (60) days. 9.3 The objective of this Agreement is to realize in an economical and reasonable way the interests and requirements of both parties. If at any time during the term of this Ageement, this objective is no longer met due to: · (a) regulatory changes(s), or economic circumstances, which could not have been foreseen at the time of execution of this Agreement causing undue and prolonged hardship; or (b) any substantial increase in Seller’s direct or indirect cost relating to Uranium targets or radioactive waste disposal; (c) changes in the selling price effected by the entrance into the market of sellers capable of meeting the volume commitments contemplated under this Agreement; then the parties shall negotiate in good faith in an effort to modify this Agreement in accordance with any of the matters described above and such negotiations shall commence within **** (****) days of one party’s written notice to the other of (a) and/or (b) above. During any negotiation period, the pricing increments defined in Exhibit C will continue in effect. In the event the parties are unable to agree upon a satisfactory modification of this Agreement within **** (****) days of commencement of negotiations (“negotiation period”), the party requesting the modification may terminate this Agreement within **** (****) days following expiry of the negotiation period by providing **** (****) days written notice to the other party. 9.4 The warranties and indemnities contained in this Agreement shall survive any expiration or termination hereof, as shall the confidentiality obligations of the parties pursuant to Article 8 hereof. Otherwise, upon expiration or termination of this Agreement as provided in this Article 9, except as expressly provided herein, the parties shall have no further liabilities, duties or obligations under this Agreement, except for any liabilities, duties or obligations which may have arisen prior to such expiration or termination.
