Construction Phase Services 3.1.1 – Basic Construction Services
Proper Instructions and Special Instructions “Proper Instructions,” which may also be standing instructions, as such term is used throughout this Agreement shall mean instructions received by the Custodian from a Fund, a Fund’s duly authorized investment manager or investment adviser, or a person or entity duly authorized by either of them. Such instructions may be in writing signed by the authorized person or persons or may be in a tested communication or in a communication utilizing access codes effected between electro-mechanical or electronic devices or may be by such other means and utilizing such intermediary systems and utilities as may be agreed from time to time by the Custodian and the person(s) or entity giving such instruction, provided that the Fund has followed any security procedures agreed to from time to time by the applicable Fund and the Custodian including, but not limited to, the security procedures selected by the Fund via the form of Funds Transfer Addendum hereto, the terms of which are hereby agreed to. Oral instructions will be considered Proper Instructions if the Custodian reasonably believes them to have been given by a person authorized to provide such instructions with respect to the transaction involved; the Fund shall cause all oral instructions to be confirmed in writing. For purposes of this Section, Proper Instructions shall include instructions received by the Custodian pursuant to any multi-party agreement which requires a segregated asset account in accordance with Section 2.9 hereof.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Special Instructions As used herein, the term "Special Instructions" shall mean Proper Instructions countersigned or confirmed in writing by the Treasurer or any Deputy or Assistant Treasurer of the applicable Fund or any other person designated by the Treasurer of such Fund in writing, which countersignature or confirmation shall be (i) included on the same instrument containing the Proper Instructions or on a separate instrument relating thereto, and (ii) delivered by hand, by facsimile transmission, or in such other manner as the applicable Fund and the Custodian agree in writing.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Framework Agreement 4.1.2.1 The Parties shall enter into a Framework Agreement within 28 days after the Contractor receives the Letter of Acceptance, unless the Particular Conditions establish otherwise. The Framework Agreement shall be based upon FORM No. 3 – FRAMEWORK AGREEMENT annexed to the Particular Conditions. The costs of stamp duties and similar charges (if any) imposed by law in connection with entry into the Framework Agreement shall be borne by the Procuring Entity. 4.1.2.2 The Framework Agreement establishes the terms and conditions that will govern the contract awarded during the term of the Framework Agreement. The Framework Agreement establishes for the procurement works by package as and when required, over the specified period of time. The Framework Agreement does not commit a Procuring Entity to procure, nor a Firm to supply. The Framework Agreement allows the Procuring Entity to call the Contractor to commence the works on a particular package in a specified location within the duration of the agreement. 4.1.2.3 This Framework Agreement does not guarantee the contractor of being called for a contract to start and no commitment is made with regard to possible number of packages to carry out. 4.1.2.4 This Framework Agreement does exclude the Procuring Entity from the right to procure the same Works from other firms. 4.1.2.5 This Framework Agreement does not stop the Procuring Entity from removing the contractor from the same Agreement. 4.1.2.6 FAs shall be established for a maximum period of three (3) years. The Procuring Entity may with the Consent of the Contractor extend this Agreement if the agreement period is less than three (3) years, if the initial engagement has been satisfactory. 4.1.2.7 Call-off Contracts; for work on a package to start, the Procuring Entity shall issue a notice of acceptance of a particular package requesting the contractor to furnish a Performance Security and to start the works thereafter, and providing the contractor with details of location where the works, are to be carried out. The call-off statement shall specify the objectives, tasks, deliverables, timeframes and price or price mechanism. The price for individual call-off contracts shall be based on the prices detailed in the Framework Agreement.
Actions of Custodian Based on Proper Instructions and Special Instructions So long as and to the extent that the Custodian acts in accordance with (a) Proper Instructions or Special Instructions, as the case may be, and (b) the terms of this Agreement, the Custodian shall not be responsible for the title, validity or genuineness of any property, or evidence of title thereof, received by it or delivered by it pursuant to this Agreement.
Collateral Access Agreements Such Grantor shall use commercially reasonable efforts to obtain a Collateral Access Agreement, from the lessor of each leased property, mortgagee of owned property or bailee or consignee with respect to the operator of any warehouse, processor or converter facility or other location (each of which is identified on Exhibit B hereto), where Collateral in excess of $1,000,000 is stored or located at any given time (other than (i) company-owned facilities and (ii) retail stores), which agreement or letter shall provide access rights, contain a waiver or subordination of all Liens or claims that the landlord, mortgagee, bailee or consignee may assert against the Collateral at that location, and shall otherwise be reasonably satisfactory in form and substance to the Administrative Agent. With respect to such locations or warehouse space leased as of the Effective Date and thereafter where Collateral in excess of $1,000,000 is stored or located (other than (i) company-owned facilities and (ii) retail stores), if the Administrative Agent has not received a Collateral Access Agreement as of the Effective Date (or, if later as of the date such location is acquired or leased), the Borrower’s Eligible Inventory at that location shall be subject to such Reserves as may be established by the Administrative Agent. After the Effective Date, no real property or warehouse space shall be leased by such Grantor (other than retail stores) and no Inventory shall be shipped to a processor or converter under arrangements established after the Effective Date, unless and until a satisfactory Collateral Access Agreement shall first have been obtained with respect to such location or if it has not been obtained, the Borrower’s Eligible Inventory at that location shall be subject to the establishment of Reserves acceptable to the Administrative Agent. Such Grantor shall timely and fully pay and perform its obligations under all leases and other agreements with respect to each leased location or third party warehouse where any Collateral is or may be located.
Customer Support and Training System Agency will provide support for the CMBHS, including problem tracking and problem resolution. System Agency will provide telephone numbers for Grantees to obtain access to expert assistance for CMBHS-related problem resolution. System Agency will provide initial CMBHS training. Grantee shall provide subsequent ongoing end-user training.
Intercreditor Agreement Governs Each Lender and Agent (a) hereby agrees that it will be bound by and will take no actions contrary to the provisions of the Pari Passu Intercreditor Agreement any other intercreditor agreement or subordination agreement entered into pursuant to the terms hereof, (b) hereby authorizes and instructs the Administrative Agent and the Collateral Agent to enter into the Pari Passu Intercreditor Agreement and each other intercreditor agreement or subordination agreement and any other intercreditor agreement or subordination agreement entered into pursuant to the terms hereof and to subject the Liens securing the Secured Obligations to the provisions thereof and (c) hereby authorizes and instructs the Administrative Agent and the Collateral Agent to enter into the Pari Passu Intercreditor Agreement and any other intercreditor agreement or subordination agreement that includes, or to amend the Pari Passu Intercreditor Agreement any then existing intercreditor agreement or subordination agreement to provide for, the terms described in the definition of the terms “Permitted First Priority Replacement Debt” or “Permitted Second Priority Replacement Debt” or other “First Lien Senior Secured Note” or the Collateral Agent, as applicable or as otherwise provided for by the terms of this Agreement; provided that in each case, such intercreditor agreement is substantially consistent with the terms set forth on Exhibit K-1 or K-2 annexed hereto together with (A) any immaterial changes and (B) changes implementing additional extensions of credit permitted under this Agreement, in each case in form and substance reasonably satisfactory to the Administrative Agent and/or Collateral Agent (it being understood that junior Liens are not required to be pari passu with other junior Liens, and that Indebtedness secured by junior Liens may secured by Liens that are pari passu with, or junior in priority to, other Liens that are junior to the Liens securing the Obligations).
