Common use of Shutters Clause in Contracts

Shutters. Verify measurements/dimensions and total number of openings to receive new shutters. Relocate required electrical /cable wires, to facilitate shutters installation. All exposed anchoring screws shall be the same color as the frame or concealed. Accordion storm shutters. The shutters and its components shall be installed in strict compliance with the Florida building code product approval (or Miami/Dade). The shutters shall be permanently attached. Homeowner and/or homeowner association will select the color of the new shutters. Remove all previously installed shutters, awnings and attachment hardware including makeshift shutters. Repair adjacent surfaces to match existing. 6.4 Contractor covenants to furnish its best skill and judgment in furthering the interests of the City. Contractor agrees to furnish efficient business administration and superintendence and use its best efforts to complete the Project in the best and soundest way and in the most expeditious and economical manner consistent with the interests of the City. 6.5 The reports, documents, and data to be provided shall represent an accurate assessment of the current status of the Project and of the Work remaining to be accomplished and it shall provide a sound basis for identifying variances and problems and for making management decisions. It shall be prepared and available to the City on a monthly basis. 6.6 Contractor shall be responsible for technically deficient Drawings, designs, reports, or studies due to Contractor’s errors and omissions, and shall promptly correct or replace all such deficient Work without cost to City. The Contractor shall also be responsible for all damages resulting from such errors and omissions. Payment in full by the City for Services performed does not constitute a waiver of this representation. 6.7 Contractor shall take into consideration such factors as natural and practical lines of severability, sequencing effectiveness, access and availability constraints, total time for completion, construction market conditions, availability of local labor and materials, community relations and any other factors pertinent to saving time and cost, considering fully the goal of increased local business and workforce participation. 6.8 Contractor shall take such measures as appropriate to provide that construction requirements will be covered in the separate subcontracts performed without duplication or overlap, sequenced to maintain completion of all Work on schedule. 6.9 Work which the Contractor shall provide includes but is not limited to, the following: 6.9.1 Develop and implement procedures to monitor, record, review and approve all submittals, Drawings, pay requests and field orders for budget and schedule impact and compliance with the Contract Documents. 6.9.2 Provide inspection of all Work, materials and tests prior to Substantial Completion and final inspections by appropriate certified inspectors and Permitting Authorities. 6.9.3 Ensure the replacement of nonconforming or substandard Work on the Project. 6.9.4 Assist the City in the warranty inspections and completion of all required warranty Work generated by the inspections. 6.10 Contractor shall supervise and direct the Work, using the highest quality established by industry standards. The Contractor shall be solely responsible for and have control over construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Agreement, unless Contract Documents give other specific instructions concerning these matters. 6.11 Contractor shall be responsible to the City for the acts and omissions of the Contractor’s employees, Subcontractors and their agents and any employees and other persons performing portions of the Work under contract with the Contractor. 6.12 Contractor shall not be relieved of obligations to perform the Work in accordance with the Contract Documents either by activities or duties of the architect-engineer (if any), or by tests, inspections or approvals required or performed by persons other than the Contractor. The Contractor shall be responsible for inspections or portions or Work already performed under this Agreement (if any) and to determine that such portions are in proper condition. 6.13 Contractor shall inspect all materials delivered to the site and shall reject any materials that do not conform to the Contract Documents. 6.14 Contractor shall be responsible for and coordinate any and all inspections required by the Permitting Authorities having jurisdiction over the Project. Failure to obtain any required approval because of failure of the Contractor to conform to the Contract Documents shall not extend the Term of Agreement, and the Contractor shall not be entitled to an increase in the Project Amount. 6.15 Contractor shall employ sufficient, competent personnel who shall be in attendance at the Project site during the performance of the Work. 6.16 Contractor shall secure all necessary permits from the Permitting Authority, the cost of which shall be obtained by the Contractor and included in the Project Amount. 6.17 Contractor shall arrange for all Worksite facilities necessary to enable the Contractor, Subcontractors, and Project Manager to perform their respective duties in the management, conduct, inspection, and supervision of Work. 6.18 Unless otherwise provided in the Contract Documents, the Contractor shall provide and pay for all labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation and other facilities and services necessary for the proper execution and completion of the Project, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. 6.19 Contractor shall develop and maintain a program to assure quality control of the Work. Contractor shall supervise the Work of all Subcontractors providing instructions to each when their Work does not conform to the requirements of the Contract Documents and shall continue to exert its influence and control over each Subcontractor to ensure that corrections are made in a timely manner so as to not affect the efficient progress of the Work. The City shall be the final judge of performance and acceptability. 6.20 Contractor shall enforce strict discipline and good order among the Contractor’s employees and Subcontractors, while on the Worksite. The Contractor shall not permit employment of unfit persons or persons not skilled in tasks assigned to them. 6.21 Contractor shall perform the Work in accordance with the Contract Documents. If the Contractor performs Work knowing it to be contrary to laws, statutes, ordinances, building codes, and rules and regulations without such notice to the City, it shall assume full responsibility for such Work, and shall bear the attributable costs. 6.22 All inspections shall be made for conformance with the applicable building codes, compliance with Drawings and specifications, and quality. Costs for any re-inspections of Work found defective and subsequently repaired shall be borne by the Contractor. 6.23 Contractor warrants and accepts that any and all repair work required at any phase of the Project, irrespective of the cause, shall be deemed the responsibility of the Contractor at no additional cost to the City. 6.24 Contractor shall confine operations at the Worksite to areas permitted by law, ordinances, permits and Contract Documents, and shall not unreasonably encumber the Worksite with personnel, materials or equipment. 6.25 Contractor shall keep the Worksite premises and surrounding areas free from accumulation of waste materials or rubbish caused by the Work. At completion, the Contractor shall remove from the Worksite all waste materials, debris, rubbish, tools, equipment, machinery and surplus materials. 6.26 Finally, the Contractor accepts, understands and agrees that these provisions of the Agreement constitute a material inducement for the City to enter into this Agreement and that the City has indeed relied on these particular provisions in making its decision to enter into this Agreement with Contractor.