Referral Procedures Section 1. For Local Unions now having a job referral system as contained in their Collective Bargaining Agreement, the Contractor agrees to utilize such system and it shall be used exclusively by such Contractor, except as it may be modified by this Article. Referrals shall not be affected by obligations of Union membership or the lack thereof. Where airport security clearance requirements apply to work to be performed, the Contractor shall inform the Union’s hiring hall dispatcher of those requirements when requesting workers. Section 2. In the event that Local Unions are unable to fill any request for employees within the time specified by the local CBAs the Contractor may employ applicants from any other available source. The Contractor shall inform the Union of the name and social security number of any applicants hired from other sources and shall refer the applicant to the Local Union for dispatch to the projects prior to the commencement of work. Section 3. There shall be no discrimination against any employee or applicant for employment because of his/her membership or non-membership in the union or based upon race, creed, color, sex, age or national origin, or any other legally protected class of such employee or applicant. Section 4. No employee covered by this Agreement shall be required to join any Union as a condition of being employed on the project; provided, however, that an employee who is a member of the referring union at the time of the referral shall maintain that membership while employed under the Agreement. All employees shall, however, be required to comply with the union security provision of the applicable Collective Bargaining Agreement, for the period during which they are performing on-site work, except as modified by this Agreement. The Contractor agrees to deduct union dues or representation fees, whichever is applicable, from the pay of any employee who executes a voluntary authorization for such deductions and to remit the dues to the Union or Council. Section 5. The parties agree that where a Contractor is not party to a current Collective Bargaining Agreement with the Union having jurisdiction over the affected work, the Contractor may request by name, and the Local will honor, referral of up to a maximum of five (5) persons per each contractor (“core” employees), provided that the Contractor first demonstrate that those persons possess the following qualifications: (1) Any license required by state or federal law for the project work to be performed; (2) Have worked a total of at least one thousand (1,000) hours in the construction craft during the prior three (3) years; (3) Were on the Contractor’s active payroll for at least sixty (60) out of the one hundred eighty (180) calendar days prior to the contract award; (4) Have the ability to perform the work safely. The Contractor may elect to hire its first “core” employee to be a xxxxxxx. After the contractor hires his first core employee, the Union will refer to such contractor one journeyman employee from the hiring hall out-of–work list for the affected trade or craft, then refer one of such Contractor’s “core” employees as a journeyman, and shall, alternate, one core employee and one employee from the out-of-work list, until such Contractor’s crew requirements are met or until such Contractor has hired five (5) “core” employees, whichever occurs first. Thereafter, all additional employees in the affected trade or craft shall be hired exclusively from the hiring hall out-of-work list(s). For the duration of the Contractor’s work the ratio of “core” employees to hiring hall referrals shall be maintained and when the Contractor’s workforce is reduced, employees shall be reduced in the same ratio as was applied in the initial hiring. All employees, core and union, shall be dispatched from the appropriate union. Trust benefits shall be paid on all employees, core and union. Section 6. Upon referral or dispatch from a Union, “turnaround” or refusal of any worker by the Contractors, requires written explanation from the Contractor that shall be communicated from the Prime Contractor to the Port and affected Union within 48 hours. Section 7. Individual seniority will not be recognized or applied to employees working on the project. This provision will not interfere with or supersede the use by individual Contractors of “call lists” maintained by such Contractor pursuant to addenda to the local Collective Bargaining Agreement between such Contractor and a Union signatory to this Agreement. Section 8. The selection of craft foremen and/or general foremen and the number of such foremen and/or general foremen required shall be entirely the responsibility of the Contractor. Craft foremen shall be designated working foremen at the request of the Contractor. Craft workers covered by this Agreement will, in the normal day- to-day operations, take their direction and supervision from their xxxxxxx.
Procedure for Third Party Claims The obligations and liabilities of each Party with respect to Third-Party Claims shall be subject to the following terms and conditions: (i) Promptly upon receiving a written notice of a Third-Party Claim, the Indemnifying Party may elect, at its sole option, to undertake the defense thereof by outside counsel of its own choosing, which outside counsel shall be reasonably satisfactory to the Indemnified Party, by sending written notice of its election to the Indemnified Party; provided however, that if, in the Indemnified Party’s and the Indemnifying Party’s reasonable judgment, a conflict of interest exists between the Indemnified Party and the Indemnifying Party with respect to such Third-Party Claim, or if the Indemnifying Party elects not to defend or otherwise does not promptly defend such Third-Party Claim, such Indemnified Party shall be entitled to undertake the defense of, and to compromise or settle, such Third-Party Claim on behalf, for the account, and at the risk of the Indemnifying Party, to the extent that the Indemnifying Party is determined to be obligated to indemnify the Indemnified Party under this Agreement with respect to such Third-Party Claim. The written notice of the Third-Party Claim shall contain all material information known to the Indemnified Party with respect to such Third-Party Claim and shall include copies of materials submitted to Indemnified Party by the Third-Party with respect to such Third-Party Claim. (ii) If the Indemnifying Party elects to undertake and diligently pursue the defense of a Third-Party Claim hereunder, the Indemnifying Party shall control all aspects of the defense and settlement of such Third-Party Claim and may settle, compromise or enter into a judgment with respect to such Third-Party Claim; provided that the Indemnifying Party shall not enter into any such settlement, compromise or judgment without the prior written consent of the Indemnified Party if such settlement, compromise or judgment would result in the imposition of any non-monetary liability or obligation on the Indemnified Party. If the Indemnifying Party assumes control of the defense under this Article 9, the Indemnified Party shall fully cooperate with the Indemnifying Party in connection therewith and may employ, at any time, a separate outside counsel to represent it; provided however, that the Indemnified Party shall be solely responsible for the costs and expenses of any such separate outside counsel. If the Indemnified Party undertakes the defense of a Third-Party Claim hereunder, the Indemnified Party shall not settle, compromise, or enter into any judgment with respect to such Third-Party Claim for which it is seeking or shall seek indemnification hereunder without the prior written consent of Indemnifying Party, which written consent shall not be unreasonably withheld, conditioned or delayed. (iii) The Indemnified Party shall provide the Indemnifying Party with access to all reasonably requested records and documents of the Indemnified Party relating to any Third-Party Claim, other than documents for which the Indemnified Party has claimed or shall claim a legal privilege.
Referral to Arbitration: Provincial Matters a. If the grievance is not resolved at Step Three within ten (10) working days of the meeting referred to in Article A.6.4, the BCTF or BCPSEA where applicable may refer a “provincial matters grievance,” as defined in Appendix 1 and Addenda, to arbitration within a further fifteen (15) working days. b. The referral to arbitration shall be in writing and should note that it is a “provincial matters grievance.” The parties shall agree upon an arbitrator within ten (10) working days of such notice.
Referral Procedure Section 4.01 In the interest of maintaining an efficient system of production in the Industry, providing for an orderly procedure of referral of applicants for employment, preserving the legitimate interests of the employees in their employment status within the area and of eliminating discrimination in employment because of membership or non-membership in the Union, the parties hereto agree to the following system of referral of applicants for employment. Section 4.02 The Union shall be the sole and exclusive source of referral of applicants for employment. Section 4.03 The Employer shall have the right to reject any applicant for employment. Section 4.04 The Union shall select and refer applicants for employment without discrimination against such applicants by reason of membership or non-membership in the Union and such selection and referral shall not be affected in any way by rules, regulations, by-laws, constitutional provisions or any other aspect or obligation of Union membership policies or requirements. All such selection and referral shall be in accord with the following procedure. Section 4.05 The Union shall maintain a register of applicants for employment established on the basis of the Classifications and Groups listed below. Each applicant for employment shall be registered in the highest priority Group in the classification or classifications for which he qualifies. GROUP - I. All applicants for employment who have three and one-half (3 1/2) or more years’ experience in the trade, are residents of the geographical area constituting the normal construction labor market, have passed a Journeyman Lineman's examination given by a duly constituted Outside Construction Local Union of the IBEW or have been certified as a Journeyman Lineman by any Outside Joint Apprenticeship and Training Committee, and who have been employed in the trade for a period of at least one (1) year in the last three and one-half (3 1/2) years in the geographical area covered by the collective bargaining agreement. Group I status shall be limited to one Local Union at one time. An applicant who qualifies for Group I in a local union shall be so registered electronically and remain on Group I in that local union unless and until the applicant designates another local union as his or her Group I local union. If an applicant qualifies for Group I status in a local union other than his or her home local union and designates that local as his or her Group I local union, the business manager of the new group 1 status local union shall by electronic means notify the business manager of the applicant’s former Group I status local union.
Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.
000 GRIEVANCE PROCEDURE 7. 100 It is agreed that it is the spirit and intent of this Agreement to adjust grievances promptly. All grievances, including discharge for just cause, but not those pertaining to jurisdictional disputes that may arise on any work covered by this Agreement, must be initiated within fifteen (15) working days of the incident by either the employee in Step I or the Local Union in Step II and shall be handled in the following manner:
Purpose; Incorporation by Reference of Auction Procedures and Settlement Procedures (a) The Statement for each series of MuniPreferred will provide that the Applicable Rate for such series for each Subsequent Rate Period thereof shall, except under certain conditions, be the rate per annum that a bank or trust company appointed by the Fund advises results from implementation of the Auction Procedures for such series. The Board of Directors or Board of Trustees, as the case may be, of the Fund has adopted a resolution appointing the Auction Agent as auction agent for purposes of the Auction Procedures for each series of MuniPreferred. The Auction Agent accepts such appointment and agrees to follow the procedures set forth in this Section 2 and the Auction Procedures for the purpose of determining the Applicable Rate for each series of MuniPreferred for each Subsequent Rate Period thereof for which the Applicable Rate is to be determined by an Auction. Each periodic implementation of such procedures is hereinafter referred to as an "Auction." (b) All of the provisions contained in the Auction Procedures and the Settlement Procedures are incorporated herein by reference in their entirety and shall be deemed to be a part hereof to the same extent as if such provisions were fully set forth herein.
GRIEVANCE AND ARBITRATION PROCEDURES A. A grievance is a dispute, claim, or complaint arising under this Agreement, filed by either an authorized representative of or an employee in the Bargaining Unit, or the County, involving the interpretation or application of this Agreement. All discipline shall be for just cause. B. Grievances will be processed in the following manner and strictly in accordance with the following stated time limits: Step 1. The aggrieved employee shall be accorded fifteen (15) working days from the occurrence of the action or event or when the employee has knowledge or should have had knowledge of the action or the event giving rise to the complaint to seek resolution on an informal basis. The Employee must discuss his alleged grievance with the Airport Fire Chief and the Fire Rescue Division Director. If informal resolution is not accomplished, the employee, if a Union member, must present the proposed grievance in writing to a Union officer on or before the fifteenth (15th) working day for consideration by the Union Grievance committee. If, in the Committee's opinion, no reasonable grievance exists, no further action may be taken. Step 2. If the Committee wishes to pursue the member's complaint, a written grievance shall be presented to the Director of the Fire Rescue Division or his designee within twenty (20) working days from the occurrence of the action or event giving rise to the grievance or from the date on which the employee reasonably should have had knowledge of that occurrence. A written grievance must be presented on a grievance form provided by the County in Appendix A. Upon receipt of a formal grievance or a class action submitted by the Union, the Fire Rescue Division Director or his designee shall investigate the facts and conduct a meeting within five (5) working days with the aggrieved employee and any other persons possessing knowledge considered critical by the Director. The aggrieved employee may be accompanied at this meeting by a local Union representative. The Fire Rescue Division Director or his designee shall notify the grievant of his decision no later than five (5) working days following the date of the meeting. Step 3. If the grievance is not resolved at the second step, the aggrieved employee shall present the written grievance within five (5) working days of the Step 2 decision to the Department Head. The Department Head or his designee shall investigate the facts and may conduct a hearing within five
NOTIFICATION OF PUBLIC EVENTS AND MEETINGS 2 A. CONTRACTOR shall notify ADMINISTRATOR of any public event or meeting funded in 3 whole or in part by the COUNTY, except for those events or meetings that are intended solely to serve 4 clients or occur in the normal course of business. 5 B. CONTRACTOR shall notify ADMINISTRATOR at least thirty (30) business days in advance 6 of any applicable public event or meeting. The notification must include the date, time, duration, 7 location and purpose of the public event or meeting. Any promotional materials or event related flyers 8 must be approved by ADMINISTRATOR prior to distribution. 9
Complaints Procedure (a) A formal complaint must be submitted in writing within six months of the last alleged occurrence. (b) A complaint must be submitted through the Union and/or directly to the Executive Director (or the equivalent or designate). When the Executive Director has received a complaint, they will notify the respondent and the union staff representative of the substance of the complaint in writing within 15 days. (c) The complaint must contain the specific instance(s) and date(s) that the alleged harassment occurred, the names of any witnesses, an explanation of how the action constitutes a violation of Article 29 (Harassment), and the remedy sought. (d) The Executive Director or their designate will investigate the complaint and will complete their report in writing within 30 days. (e) The Employer will take action to resolve the complaint within 10 days of receiving the investigator's report. (f) The Employer will advise the respondent, the complainant and the Union in writing of the substance of the investigator's report and the resolution of the complaint. (g) If the resolution involves separating employees, reasonable efforts will be made to relocate or reschedule the respondent. The complainant may agree in writing to be transferred or rescheduled. (h) If the resolution involves separating an employee and a respondent who is not an employee, reasonable efforts will be made to remedy the situation. (i) If the respondent is the Executive Director (or equivalent), or where there are possible systemic issues or multiple complaints, the following process will be used: (1) The complainant will contact the Union. (2) As soon as possible but within 30 days the Union will notify the Executive Director (or equivalent) and CSSEA. Clause 29.4 (a) and (c) apply to the notice. CSSEA will inform the Employer's Board of Directors. (3) CSSEA and the Union will appoint either Xxxxx Xxxxx or Xxxxxx Xxxx to resolve the complaint. (The person appointed is referred to below as "the Appointee".) (4) After consultation with the parties involved, the Appointee will establish the process to resolve the complaint. The process may include - at the Appointee's discretion - any of the following (or any combination of them): fact-finding, mediation, making recommendations or a full report, or conducting an expedited arbitration. In exercising their discretion with respect to the process, the Appointee will consider the parties' desire that the process be fair and expeditious, that it minimizes disruption in the workplace, that it respects individual privacy to the degree possible in the circumstances, and that it keeps costs to a reasonable level. The Appointee will submit any report or recommendations to CSSEA and the Union. The report and recommendations will remain confidential, except for distribution to the Employer's Board of Directors, the complainant and the respondent. The Appointee may stipulate conditions she/he deems appropriate with respect to distribution. Any outcomes of the process are without prejudice or precedent for other proceedings. (5) The Appointee's fees and expenses will be shared by the Employer and the Union. (j) The Employer may take appropriate action, including discipline, against a complainant if the investigation determines that the complaint is frivolous, vindictive or vexatious.
