Special Correction Period Requirements Sample Clauses

Special Correction Period Requirements. 9.5.1. Whenever the Owner undertakes Partial Use of any portion of the Work specifically designated as eligible for Partial Use in the Contract Documents, the warranties for all materials and equipment incorporated into that portion of the Work shall remain in full force and effect between the start of such Partial Use and the date when the Correction Period starts. If no separate price for such special correction period was requested in Section 00300 Bid Form and made part of the Contract Documents, the Owner will appropriately adjust the Contract Price. 9.5.2. Whenever the Owner undertakes Partial Use of any portion of the Work because any act or omission within the control of the Contractor Delays completion of the Work, or any portion of the Work, within a designated Contract Time, the warranties for all materials and equipment incorporated into that portion of the Work shall, at no adjustment in Contract Price, be maintained in full force and effect between the beginning date of such Partial Use and the date when the Correction Period stars. 9.5.3. The correction period for any Defective Work that is corrected or rejected and replaced within the last three (3) months of the Correction Period shall be extended by an additional six (6) months, starting on the date such Work was made non-Defective. 9.5.4. The Contract Documents may require the Correction Period to start on a date later than the date of Substantial Completion of the entire Work. If such is the case, and the Owner advances or defers the start of the Correction Period, the Contractor shall maintain the warranties for materials and equipment until the revised starting date of the Correction Period. If no separate price for such advance or deferment was requested in Section 00300 Bid Form and made part of the Contract Documents, the Owner will amend the Contract Documents to appropriately adjust the Contract Price.
AutoNDA by SimpleDocs
Special Correction Period Requirements. Whenever the Owner undertakes any portion of the Work because the DB Entity’s act or omission Delays completion of the Work or it is eligible for Partial Use, the warranties for all materials and equipment incorporated into that portion of the Work shall remain in full force and effect between the start of such Partial Use and the date when the Correction Period starts. The Correction Period for any Defective Work that is corrected or rejected and replaced within the last three months of the Correction Period shall be extended by an additional six months, starting on the date such Work was made non-Defective.

Related to Special Correction Period Requirements

  • Testing Requirements 12.1. Workplaces - 12.2. On workplaces where the value of the Commonwealth’s contribution to the project that includes the building work is at least $5,000,000, and represents at least 50% of the total construction project value or the Commonwealth’s contribution to the project that includes the building work is at least $10,000,000 (irrespective of its proportion of the total construction project value) the following minimum testing requirements must be adhered to.

  • Forecasting Requirements 19.5.1 The Parties shall exchange technical descriptions and forecasts of their Interconnection and traffic requirements in sufficient detail necessary to establish the Interconnections necessary for traffic completion to and from all Customers in their respective designated service areas.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Operating Requirements Any operating and technical requirements that may be applicable due to Regional Transmission Organization, Independent System Operator, control area, or the Connecting Transmission Owner’s requirements, including those set forth in the Small Generator Interconnection Agreement. Operating Requirements shall include Applicable Reliability Standards.

  • Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse. B. Grantee shall use the Texas Abuse Hotline Website located at xxxxx://xxx.xxxxxxxxxxxxxx.xxx/Login/Default.aspx as required by the System Agency. Grantee shall retain reporting documentation on site and make it available for inspection by the System Agency.

  • Coverage Requirements (08/19) Contractor shall comply with the following insurance requirements:

  • GAAP Compliance Contractor maintains an adequate system of accounting and internal controls that meets Generally Accepted Accounting Principles.

  • Reporting Covenant Required Complies Quarterly consolidating financial statements Quarterly within 45 days Yes No Annual financial statement (CPA Audited) FYE within 150 days Yes No 10‑Q, 10‑K and 8-K Within 5 days after filing with SEC Yes No Quarterly Compliance Certificate Contemporaneously with delivery ofthe 10-Q and 10-K Yes No Annual operating budgets and annual financial projections FYE within 45 days Yes No

  • Post-Closing Requirements Borrowers shall complete each of the post-closing obligations and/or provide to Agent each of the documents, instruments, agreements and information listed on Schedule 7.4 attached hereto on or before the date set forth for each such item thereon, each of which shall be completed or provided in form and substance satisfactory to Agent.

  • Time Requirements The Independent Contractor will not be required to follow or establish a regular or daily work schedule, but shall devote during the term of this Agreement the time, energy and skill as necessary to perform the services of this engagement and shall, periodically or at any time upon the request of the Company, submit information as to the amount of time worked and scope of work performed.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!