Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Payment Delay To the maximum extent permitted under section 409A of the Code, the severance benefits payable under this Agreement are intended to comply with the “short-term deferral exception” under Treas. Reg. §1.409A-1(b)(4), and any remaining amount is intended to comply with the “separation pay exception” under Treas. Reg. §1.409A-1(b)(9)(iii); provided, however, any amount payable to Executive during the six (6) month period following Executive’s Termination Date that does not qualify within either of the foregoing exceptions and constitutes deferred compensation subject to the requirements of section 409A of the Code, then such amount shall hereinafter be referred to as the “Excess Amount.” If at the time of Executive’s separation from service, the Company’s (or any entity required to be aggregated with the Company under section 409A of the Code) stock is publicly-traded on an established securities market or otherwise and Executive is a “specified employee” (as defined in section 409A of the Code and determined in the sole discretion of the Company (or any successor thereto) in accordance with the Company’s (or any successor thereto) “specified employee” determination policy), then the Company shall postpone the commencement of the payment of the portion of the Excess Amount that is payable within the six (6) month period following Executive’s Termination Date with the Company (or any successor thereto) for six (6) months following Executive’s Termination Date with the Company (or any successor thereto). The delayed Excess Amount shall be paid in a lump sum to Executive within ten (10) days following the date that is six (6) months following Executive’s Termination Date with the Company (or any successor thereto). If Executive dies during such six (6) month period and prior to the payment of the portion of the Excess Amount that is required to be delayed on account of section 409A of the Code, such Excess Amount shall be paid to the personal representative of Executive’s estate within sixty (60) days after Executive’s death.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Excusable Delays Neither Party shall be held liable for any delay or failure in performance of any part of this Services Agreement by reason of any cause beyond its reasonable control, including, but not limited to, acts of God, acts of civil or military authority, government regulations, embargoes, epidemics, war, terrorist acts, riots, fires, explosions, earthquakes, nuclear accidents, floods, strikes, power blackouts affecting facilities, inability to secure products or services of other persons or transportation facilities, or acts or omissions of transportation common carriers, provided that the Party so affected shall use reasonable commercial efforts to remove such causes of non-performance. Upon the occurrence of any event of force majeure, the Party whose performance is prevented shall promptly give written notice to the other Party and the Parties shall promptly confer in good faith to agree upon reasonable action to minimize the impact of such event on the Parties.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Unavoidable Delay Except for the monetary obligations of Tenant under this Lease, neither party shall be chargeable with, liable for, or responsible to the other for anything or in any amount for any Unavoidable Delay and any Unavoidable Delay shall not be deemed a breach of or default in the performance of this Lease, it being specifically agreed that any time limit provision contained in this Lease (other than the scheduled expiration of the Term) shall be extended for the same period of time lost by Unavoidable Delay.
Service Interruption Landlord shall not be liable in damages for any failure or interruption of any utility service to the Premises, except to the extent that any failure or interruption arises from the gross negligence or willful misconduct of Landlord. No failure or interruption of utility service for any reason shall entitle Tenant to terminate this Lease; provided, however, that if the failure or interruption of any Service to be repaired or maintained by Landlord and not the service provider continues for a period of forty-eight (48) hours or more, Tenant shall be entitled to an equitable abatement of Minimum Rent. Landlord shall not be obligated to provide any service or maintenance or to make any repairs pursuant to this Lease when such service, maintenance or repair is made necessary because of any wrongful act or misuse of any utility service by Tenant, Tenant's agents, employees, servants, contractors, subtenants or licensees. Landlord reserves the right to stop any Service when Landlord deems such stoppage necessary, whether by reason of accident or emergency, or for repairs or improvements or otherwise, provided, that any such period of stoppage shall be only so long as is reasonably required to effect any necessary repairs or maintenance. Landlord shall not be obligated to inspect the Premises and shall not be obligated to make any repairs or perform any maintenance hereunder unless first notified of the need thereof in writing or, in an emergency, verbally, followed by a written confirmation, by Tenant. Upon receipt of any such notice, Landlord shall commence any required repair work of an emergency nature as soon as possible and work as expeditiously as possible to complete such work. All other work of a non-emergency nature shall be performed as promptly as possible. If Landlord shall fail to commence emergency repairs or maintenance to be performed by Landlord and not the service provider within twenty-four (24) hours after said notice, or non-emergency repairs or maintenance within five (5) days after said notice, then Tenant shall be entitled to an equitable abatement of Minimum Rent for so long as such failure continues and an extension of the Lease Term for a period equal to the period of rent abatement.
Conversion Delays If the Company fails to deliver shares in accordance with the timeframe stated in Section 1.00(b), the Holder, at any time prior to selling all of those shares, may rescind any portion, in whole or in part, of that particular conversion attributable to the unsold shares. The rescinded conversion amount will be returned to the Principal Sum with the rescinded conversion shares returned to the Company, under the expectation that any returned conversion amounts will tack back to the Effective Date.
