Information Security Requirements In cases where the State is not permitted to manage/modify the automation equipment (server/computer/other) that controls testing or monitoring devices, the Contractor agrees to update and provide patches for the automation equipment and any installed operating systems or applications on a quarterly basis (at minimum). The Contractor will submit a report to the State of updates installed within 30 days of the installation as well as a Plan of Actions and Milestones (POA&M) to remediate any vulnerabilities ranging from Critical to Low. The contractor will provide an upgrade path or compensatory security controls for any operating systems and applications listed as beyond “end-of-life” or EOL, within 90 days of the EOL and complete the EOL system’s upgrade within 90 days of the approved plan.
Electronic and Information Resources Accessibility and Security Standards a. Applicability: The following Electronic and Information Resources (“EIR”) requirements apply to the Contract because the Grantee performs services that include EIR that the System Agency's employees are required or permitted to access or members of the public are required or permitted to access. This Section does not apply to incidental uses of EIR in the performance of the Agreement, unless the Parties agree that the EIR will become property of the State of Texas or will be used by HHSC’s clients or recipients after completion of the Agreement. Nothing in this section is intended to prescribe the use of particular designs or technologies or to prevent the use of alternative technologies, provided they result in substantially equivalent or greater access to and use of a Product.
Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse.
Data Security Requirements A. Data Transport. When transporting Confidential Information electronically, including via email, the data will be protected by:
Subsidy Requests and Reporting Requirements 1. The Grantee or Management Company shall complete a CRF Subsidy Request Report - Recap of Tenant Income Certification, which provides a unit-by-unit listing of all units in the Development for whom assistance is being requested and gives detailed information including the occupants’ eligibility, set-aside requirements, amount of household rent paid, utility allowance and amount of CRF Rental Subsidy requested.
EDD Independent Contractor Reporting Requirements Effective January 1, 2001, the County of Orange is required to file in accordance with subdivision (a) of Section 6041A of the Internal Revenue Code for services received from a “service provider” to whom the County pays $600 or more or with whom the County enters into a contract for $600 or more within a single calendar year. The purpose of this reporting requirement is to increase child support collection by helping to locate parents who are delinquent in their child support obligations. The term “service provider” is defined in California Unemployment Insurance Code Section 1088.8, subparagraph B.2 as “an individual who is not an employee of the service recipient for California purposes and who received compensation or executes a contract for services performed for that service recipient within or without the state.” The term is further defined by the California Employment Development Department to refer specifically to independent Contractors. An independent Contractor is defined as “an individual who is not an employee of the ... government entity for California purposes and who receives compensation or executes a contract for services performed for that ... government entity either in or outside of California.” The reporting requirement does not apply to corporations, general partnerships, limited liability partnerships, and limited liability companies. Additional information on this reporting requirement can be found at the California Employment Development Department web site located at xxxx://xxx.xxx.xx.xxx/Employer_Services.htm
Child Abuse Reporting Requirement Grantee will:
How Do I Get More Information? For more information, including the full Notice, Claim Forms and Settlement Agreement go to xxx.xxxxxxxxxxxxxxxxxxxx.xxx, contact the settlement administrator at 0-000-000-0000, or call Class Counsel at 1-866-354-3015. Exhibit E UNITED STATES DISTRICT COURT FOR THE SOUTHERN DISTRICT OF FLORIDA Xxxxx v. AvMed, Inc., Case No. 10-cv-24513 If You Paid for or Received Insurance from AvMed, Inc. at Any Time Through December of 2009, You May Be Part of a Class Action Settlement. IMPORTANT: PLEASE READ THIS NOTICE CAREFULLY. THIS NOTICE RELATES TO THE PENDENCY OF A CLASS ACTION LAWSUIT AND, IF YOU ARE A MEMBER OF THE SETTLEMENT CLASSES, CONTAINS IMPORTANT INFORMATION ABOUT YOUR RIGHTS TO MAKE A CLAIM UNDER THE SETTLEMENT OR TO OBJECT TO THE SETTLEMENT (A federal court authorized this notice. It is not a solicitation from a lawyer.) Your legal rights are affected whether or not you act. Please read this notice carefully. YOUR LEGAL RIGHTS AND OPTIONS IN THIS SETTLEMENT SUBMIT A CLAIM FORM This is the only way to receive a payment. EXCLUDE YOURSELF You will receive no benefits, but you will retain any rights you currently have to xxx the Defendant about the claims in this case. OBJECT Write to the Court explaining why you don’t like the Settlement. GO TO THE HEARING Ask to speak in Court about your opinion of the Settlement. DO NOTHING You won’t get a share of the Settlement benefits and will give up your rights to xxx the Defendant about the claims in this case. These rights and options – and the deadlines to exercise them – are explained in this Notice. QUESTIONS? CALL 0-000-000-0000 TOLL FREE, OR VISIT XXX.XXXXXXXXXXXXXXXXXXXX.XXX PARA UNA NOTIFICACIÓN EN ESPAÑOL, LLAMAR O VISITAR NUESTRO WEBSITE BASIC INFORMATION
Security Requirements 11.1 The Supplier shall comply, and shall procure the compliance of the Suppliers Personnel, with the Security Policy and the Security Plan and the Supplier shall ensure that the Security Plan produced by the Supplier fully complies with the Security Policy.
Requirement to Utilize HUB Compliance Reporting System Pursuant to Texas Administrative Code, Title 34, Part 1, Sections 20.285(f) and 20.287(b), TFC administers monthly administration HSP-PAR compliance monitoring through its HUB Compliance Reporting System commonly known as B2G. PSP and PSP’s subcontractors/subconsultants shall submit required PAR information into the B2G system. Any delay in the timely submission of PAR information into the B2G system will be treated as an invoicing error subject to dispute under Texas Government Code Section 2251.042.
