Opinion of Probable Cost Any opinions of probable Project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer’s experience and qualifications and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s’) methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual Project or construction cost will not vary from opinions of probable cost Engineer prepares.
Payment of Project Costs The Grantee agrees that it will provide for payment of its full share of Project costs and that all costs connected with the Project will be paid by the Grantee on a timely basis.
Project Cost a. The estimated cost of the Project is $ 97,740.00. This amount is based upon the Schedule of Financial Assistance in Exhibit "B", attached to and incorporated in this Agreement. Exhibit “B” may be modified by mutual execution of an amendment as provided for in paragraph 5.i.
Overall Project Schedule The Construction Progress Schedule that is approved by the Owner.
Project Cost Overruns In the event that the Recipient determines that the moneys granted pursuant to Section II hereof, together with the Local Subdivision Contribution, are insufficient to pay in full the costs of the Project, the Recipient may make a request for supplemental assistance to its District Committee. The Recipient must demonstrate that such funding is necessary for the completion of the Project and the cost overrun was the result of circumstances beyond the Recipient's control, that it could not have been avoided with the exercise of due care, and that such circumstances could not have been anticipated at the time of the Recipient's initial application. Should the District Committee approve such request the action shall be recorded in the District Committee's official meeting minutes and provided to the OPWC Director for the execution of an amendment to this Agreement.
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.
Total Project Cost The total cost of the Project is $36,378,683, of which (i) a match is being contributed in the amount of $21,000,000 shall be Matching Funds, and (ii) $15,378,683 shall be provided by the Grant. The total estimated cost of the Project is based upon the Budget. To the extent that the actual cost of the Project exceeds $36,378,683, Grantee shall be solely responsible for such excess. Grantee shall monitor the Budget and submit an amended Budget to Triumph in the event that (a) the total cost of the Project increases or decreases by greater than five percent (5%), (b) total the Budget increases or decreases by greater than five percent (5%), (c) the Budget increases or decreases by greater than five percent (5%) within a particular Budget category, and/or (d) Grantee’s portion of the Matching funds decreases by greater than five percent (5%). If Grantee proposes an increase or decrease by greater than five percent (5%) as described above as compared to the most recently approved Budget, such proposal shall be submitted to Triumph in writing along with a proposed amended Budget, and Triumph shall have the right to approve or disapprove both the proposed Budget category increase or decrease and the proposed amended Budget. If Grantee fails to obtain Triumph's approval, that failure shall be sufficient cause for nonpayment by Triumph as provided in Section 4.2(f). Using the Grant, its own funds, and funds from other sources (including, but not limited to, the Matching Funds), Grantee agrees to bear the entire cost and expense of the Project, including but not limited to, all costs and all expenses in excess of the total estimated cost of the Project, it being expressly understood and agreed that the Grant shall operate only to pay, on and subject to the terms and conditions set forth herein, a portion of the costs and expenses of the Project. Furthermore, Grantee agrees to spend all of the Matching Funds as contemplated in the Budget, and agrees that its failure to do so shall be deemed a material breach of this Agreement.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Construction Cost Estimate At 50% completion of the contract documents, the design team will present and submit copies of the project plans and manual. The Construction Administrator will prepare and issue the fourth of five construction cost estimates. The estimate shall be derived from actual takeoffs, subcontractor and vendor input, and material and labor cost data. All quantitative systems information shall be provided in detail.