Major Damage In the event of Major Damage to a Property prior to the Closing Date, then the applicable Seller shall have no obligation to repair such Major Damage and shall notify Purchaser in writing of such damage or destruction (the “Damage Notice”). Within ten (10) days after Purchaser’s receipt of the Damage Notice, Purchaser may elect at its option to give a Termination Notice for the damaged Property to Seller’s Representative. If Purchaser does not elect to terminate this Agreement with respect to the damaged Property, this transaction shall be closed in accordance with the terms of this Agreement either, at the election of the applicable Seller, (a) for the full Purchase Price for the damaged Property notwithstanding any such damage or destruction, and Purchaser shall, at Closing, execute and deliver an assignment and assumption (in a form reasonably required by the applicable Seller) of such Seller’ rights and obligations with respect to the insurance claim and related to such casualty, and thereafter Purchaser shall receive all remaining insurance proceeds pertaining to such claim (plus a credit against the applicable Purchase Price at Closing in the amount of any deductible payable by the applicable Seller in connection therewith and not spent by such Seller for demolition, site cleaning, restoration or other repairs); or (b) Purchaser shall receive a credit against the Base Purchase Price for the damaged Property for the full replacement costs of repair to the subject Property, plus, to the extent covered by such Seller’s insurance policy, any costs required pursuant to local code or zoning requirements, as determined by an independent third party reasonably acceptable to such Seller and Purchaser. In the event a Seller elects to assign such Seller's rights and obligations with respect to the insurance claim and related casualty to Purchaser as provided above, and if an AIMCO employee is the adjuster for the claim related thereto, Sellers covenant and agree that the adjuster shall act in accordance with standard insurance industry protocols in processing such claim (including, without limitation, the time taken to process such claim).
Return or Destruction Upon termination of this Agreement or upon any earlier written request by Sponsor at any time, Institution shall return to Sponsor, or destroy, at Sponsor’s option, all Confidential Information other than Study Data.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Act of God Days Act of God" days beyond the allowance by Michigan Law and the Department of Education regulations will be made up by the students and assistants at the end of the school year or at other times as specified by the calendar. Assistants will only receive compensation for the "Act of God" days allowed. When a scheduled day of schoolwork is delayed, association members shall report as near as possible to their regular starting times. Assistants will receive their full day's pay when the school day is shortened due to weather or mechanical problems.
Casualty Damage 18.1 Tenant shall give immediate notice (by telephone, confirmed in writing) to Landlord of any damage caused to the Premises by fire or other casualty, and if Landlord does not elect to terminate this Lease as provided in Section 18.2, Landlord shall proceed with reasonable diligence and at its sole cost and expense to rebuild and repair the Building and/or the Premises, as the case may be, but Landlord shall not be obligated to expend for such rebuilding and repair any amount in excess of the amount of the insurance proceeds actually recovered by Landlord and made available by any Superior Lessor or Superior Mortgagee as a result of such loss. 18.2 If the Building or the Premises shall be destroyed or substantially damaged by a casualty not covered by Landlord’s insurance, or if 25% or more of the Premises is damaged or rendered untenantable by a casualty covered by Landlord’s insurance, or if the Premises are not affected but 25% of the Building or such portion of the Common Facilities as shall render the Premises or the Building untenantable is damaged or rendered untenantable, then in any such event Landlord may elect either to terminate this Lease or to proceed to rebuild and repair the Premises or that portion of the Building so damaged. Landlord shall give written notice to Tenant of such election within 90 days after the occurrence of such casualty, or within 30 days after the adjustment of the insurance settlement, whichever is later. In the event that such notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have commenced) with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights and remedies against Tenant under the terms of this Lease. If at any time prior to Landlord giving the aforesaid notice of termination or commencing the repair pursuant to Section 18.1, there shall be a Successor Landlord, such Successor Landlord shall have a further period of 60 days from the date of so taking possession to terminate this Lease by notice to Tenant and in the event that such a notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have been commenced) if Tenant is not occupying any portion of the Premises or otherwise as of the date provided in such notice, with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights against Tenant under the terms of this Lease. 18.3 Subject to the provisions of Section 18.1, Landlord’s obligation to rebuild and repair under this Article XVIII shall in any event be limited to restoring Landlord’s Work, as described in the Work Letter, to substantially the condition in which the same existed prior to the casualty, and to proceed, at the sole cost and expense of Tenant, to rebuild, repair and restore Tenant’s Work and any additional Improvements made by Tenant during the Term, all to substantially the condition existing prior to such casualty. 18.4 During the period from the occurrence of the casualty until Landlord’s repairs are completed, the Basic Rent payable pursuant to Article V and Additional Rent payable pursuant to Articles VI and VII shall be abated in that proportion which the Premises area rendered untenantable bears to the entire Premises area; provided, however, there shall be no abatement of any other charges or items of Additional Rent provided for herein to be paid by Tenant; and further provided, however, that should Tenant or anyone claiming through or under Tenant occupy a portion of the Premises during the period the repair work is taking place and prior to the date the Premises are no longer untenantable, the Rent allocable to such reoccupied portion, based upon the proportion which the reoccupied portion of the Premises bears to the total area of the Premises, shall be payable by Tenant from the date of such occupancy. 18.5 Landlord shall not the liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting in any way from any such damage by fire or other casualty or the repair thereof. 18.6 Notwithstanding any of the foregoing provisions of this Article, if, by reason of any negligence or willful act on the part of Tenant or any of its employees, agents, licensees, invitees or contractors, either (a) Landlord or the Superior Lessor or the Superior Mortgagee shall be unable to collect all of the insurance proceeds (including rent insurance proceeds) applicable to damage or destruction of the Premises or the Building or the Project by fire or other casualty or (b) the Premises or the Building or the Project shall be damaged or destroyed or rendered completely or partially untenantable on account of fire or other casualty then, without prejudice to any other remedy which may be available against Tenant, the abatement of rent provided for in Section 18.4 shall not be effective to the extent of the uncollected insurance proceeds.
Epidemic Failure Warranty Supplier warrants all Products against Epidemic Failure for a period of three years after DXC’s Acceptance. Epidemic Failure means the occurrence of the same failure, defect, or non-conformity with an Order in 2% or more of Products within any three-month period.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Equipment Failures In the event of equipment failures beyond the Administrator's control, the Administrator shall take reasonable and prompt steps to minimize service interruptions but shall have no liability with respect thereto. The Administrator shall develop and maintain a plan for recovery from equipment failures which may include contractual arrangements with appropriate parties making reasonable provision for emergency use of electronic data processing equipment to the extent appropriate equipment is available.
