Substitution of the Developer Sample Clauses
Substitution of the Developer
Substitution of Key Personnel Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. As discussed below, any personnel who fail or refuse to perform the Services in a manner acceptable to the City, or who are determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project or a threat to the safety of persons or property, shall be promptly removed from the Project by the Consultant at the request of the City. The key personnel for performance of this Agreement are as follows: Xxxxx Xxxxx.
Substitution of Trustee Beneficiary may from time to time substitute a successor or successors to any Trustee named herein or acting hereunder to execute this Trust. Upon such appointment, and without conveyance to the successor trustee, the latter will be vested with all title, powers, and duties conferred upon any Trustee herein named or acting hereunder. Each such appointment and substitution is to be made by written instrument executed by Beneficiary, containing reference to this Deed of Trust and its place of record, which, when duly recorded in the proper office of the county or counties in which the Property is situated, will be conclusive proof of proper appointment of the successor trustee.
Substitution of Equipment In the event the Computer is inoperable, ASL has a limited number of spare laptops for use while the Computer is being repaired or replaced. This agreement remains in effect for such a substitute. The Student may NOT opt to keep a broken Computer or to avoid using the Computer due to loss or damage.
Substitution of Engines Upon the occurrence of an Event of Loss with respect to an Engine under circumstances in which an Event of Loss with respect to the Airframe has not occurred, the Owner shall promptly (and in any event within fifteen (15) days after such occurrence) give the Indenture Trustee written notice of such Event of Loss. The Owner shall have the right at its option at any time, on at least five (5) Business Days’ prior notice to the Indenture Trustee, to substitute, and if an Event of Loss shall have occurred with respect to an Engine under circumstances in which an Event of Loss with respect to the Airframe has not occurred, shall within one hundred and twenty (120) days of the occurrence of such Event of Loss substitute, a Replacement Engine for any Engine. In such event, immediately upon the effectiveness of such substitution and without further act, (i) the replaced Engine shall thereupon be free and clear of all rights of the Indenture Trustee and the Lien of this Trust Indenture and shall no longer be deemed an Engine hereunder and (ii) such Replacement Engine shall become subject to this Trust Indenture and be deemed part of the Aircraft for all purposes hereof to the same extent as the replaced Engine. Such Replacement Engine shall be an engine manufactured by Engine Manufacturer that is the same model as the Engine to be replaced thereby, or an improved model, and that is suitable for installation and use on the Airframe, and that has a value, utility and remaining useful life (without regard to hours and cycles remaining until overhaul) at least equal to the Engine to be replaced thereby (assuming that such Engine had been maintained in accordance with this Trust Indenture). The Owner’s right to make a replacement hereunder shall be subject to the fulfillment (which may be simultaneous with such replacement) of the following conditions precedent at the Owner’s sole cost and expense, and the Indenture Trustee agrees to cooperate with the Owner to the extent necessary to enable it to timely satisfy such conditions: (i) an executed counterpart of each of the following documents shall be delivered to the Indenture Trustee: (A) a Trust Indenture Supplement covering the Replacement Engine, which shall have been duly filed for recordation pursuant to the Act or such other applicable law of the jurisdiction other than the United States in which the Aircraft of which such Engine is a part is registered in accordance with Section 4.02(e), as the case may be; (B) a full warranty xxxx of sale (as to title), covering the Replacement Engine, executed by the former owner thereof in favor of the Owner (or, at the Owner’s option, other evidence of the Owner’s ownership of such Replacement Engine, reasonably satisfactory to the Indenture Trustee); and (C) UCC financing statements covering the security interests created by this Trust Indenture (or any similar statements or other documents required to be filed or delivered pursuant to the laws of the jurisdiction in which such Aircraft may be registered) as are deemed necessary or desirable by counsel for the Indenture Trustee to protect the security interests of the Indenture Trustee in the Replacement Engine; (ii) the Owner shall cause to be delivered to the Indenture Trustee an opinion of counsel to the effect that the Lien of this Trust Indenture continues to be in full force and effect with respect to the Replacement Engine and such evidence of compliance with the insurance provisions of Section 4.06 with respect to such Replacement Engine as the Indenture Trustee shall reasonably request; (iii) promptly after the filing of the Trust Indenture Supplement, the Owner shall have caused to be furnished to the Indenture Trustee an opinion of the Owner’s aviation law counsel reasonably satisfactory to the Indenture Trustee addressed to the Indenture Trustee as to the due filing for recordation of the Trust Indenture Supplement with respect to such Replacement Engine under the Act or such other applicable law of the jurisdiction other than the United States in which the Aircraft is registered in accordance with Section 4.02(e), as the case may be, and the registration (which the Owner shall have caused to be effected) with the International Registry of the sale to the Owner of such Replacement Engine (if occurring after February 28, 2006) and the International Interest granted under such Trust Indenture Supplement with respect to such Replacement Engine; and (iv) the Owner shall have furnished to the Indenture Trustee a certificate of a qualified aircraft engineer (who may be an employee of the Owner) or an independent appraiser certifying that such Replacement Engine has a value and utility and remaining useful life (without regard to hours and cycles remaining until overhaul) at least equal to the Engine so replaced (assuming that such Engine had been maintained in accordance with this Trust Indenture). Upon satisfaction of all conditions to such substitution, (x) the Indenture Trustee shall execute and deliver to the Owner such documents and instruments, prepared at the Owner’s expense, as the Owner shall reasonably request to evidence the release of such replaced Engine from the Lien of this Trust Indenture, (y) the Indenture Trustee shall assign to the Owner all claims it may have against any other Person relating to any Event of Loss giving rise to such substitution and (z) the Owner shall receive all insurance proceeds (other than those reserved to others under Section 4.06(b)) and proceeds in respect of any Event of Loss giving rise to such replacement to the extent not previously applied to the purchase price of the Replacement Engine as provided in Section 4.05(d).
for substitutions by Residential Funding It is understood and agreed that the obligation of the Company to cure such breach or to so purchase or substitute for any Mortgage Loan as to which such a breach has occurred and is continuing shall constitute the sole remedy respecting such breach available to the Certificateholders or the Trustee on behalf of the Certificateholders. Notwithstanding the foregoing, the Company shall not be required to cure breaches or purchase or substitute for Mortgage Loans as provided in this Section 2.03(b) if the substance of the breach of a representation set forth above also constitutes fraud in the origination of the Mortgage Loan.
Substitution of Members If unanimous written approval is received, the transferee shall:
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Substitution of Banks Upon the receipt by the Borrower from any Bank (an "AFFECTED BANK") of a claim for compensation pursuant to Section 3.01 or Section 3.03, or a notice to the Borrower through the Administrative Agent under Section 3.02(a), unless the Borrower and the Affected Bank have reached an agreement or are negotiating toward reaching an agreement relative to alleviating the impact of such claim for compensation or such notice on the Borrower, the Borrower may: (i) request one or more of the other Banks to acquire and assume all or part of such Affected Bank's Advances and Revolving Commitment, which request may be granted or denied in such Bank's sole discretion; or (ii) designate a replacement bank or financial institution (the "Substitute Bank") to acquire and assume all or part of such Affected Bank's Advances and Revolving Commitment. Any such designation of a Substitute Bank under clause (ii) shall be subject to the prior written consent of the Administrative Agent (which consent shall not be unreasonably withheld). In the event of the replacement of an Affected Bank, such Affected Bank agrees to assign without recourse its rights and obligations hereunder to the Substitute Bank upon payment by the Substitute Bank to the Affected Bank of the principal amount of such Affected Banks's outstanding Advances and any accrued and unpaid interest thereon, and any other amounts owed to such Affected Bank and to execute and deliver to the Administrative Agent an assignment and acceptance in form and substance reasonably satisfactory to the Administrative Agent and such Affected Bank evidencing such assignment and the acceptance by the Substitute Bank of such Affected Bank's obligations hereunder. The designation of a Substitute Bank shall not affect the Borrower's obligations to such Affected Bank hereunder.
Formation of the Company The Company was formed as a limited liability company under the Act on April 24, 2008. The Member hereby agrees that the person executing and filing the Certificate of Formation of the Company was and is an “authorized person” within the meaning of the Act, and that the Certificate of Formation filed by such authorized person is the Certificate of Formation of the Company.
RECOGNITION OF THE UNION 1. The BCPSEA recognizes the BCTF as the sole and exclusive bargaining agent for the negotiation and administration of all terms and conditions of employment of all employees within the bargaining unit for which the BCTF is established as the bargaining agent pursuant to PELRA and subject to the provisions of this Collective Agreement.